Kanawha

Charleston Gazette-Mail Legal Advertisements for Aug. 12

1.CITY OF CHARLESTON
ADVERTISEMENT
FOR BIDS
STORM SEWER
REHABILITATION
PROJECT
CURED IN PLACE
PIPE (CIPP) LINING,
VARIOUS LOCATIONS
PROJECT NUMBER
E3 08/15-094
The City of Charleston, West Virginia will receive sealed bids for the installation of CIPP within storm sewer pipes at various locations until 10:00 a.m., Thursday, August 13, 2015 in the City Manager’s Office on the first floor of City Hall. Immediately following the scheduled closing time for the receipt of bids, all proposals which have been submitted in accordance with the project requirements will be publicly opened and read aloud. The City reserves the right to reject any or all bids, to waive any informalities in bidding, and to accept the bid considered to be in its best interest from the lowest responsible bidder. All interested parties are invited to attend the bid opening.

Plans and specifications may be obtained from the City Manager’s Office. Plans and specifications may be examined at the following locations:

Contractor’s Association
of West Virginia
2114 Kanawha Blvd.,
East
Charleston, WV 25311
City of Charleston
City Manager’s Office
501 Virginia St., East;
Room 101
Charleston, WV 25301

The Contractor will be required to comply with all applicable Federal requirements pertaining to Affirmative Action, Employment Opportunity, Federal Labor Standards, Copeland Anti-Kickback Act, and DBE/WBE goals as described in the Specifications.

A mandatory pre-bid conference for the purpose of discussing and clarifying the project plans and specifications will be held at 10:00 a.m. on Thursday, August 6, 2015, in the City Engineer’s Office located at 114 Dickinson Street.

All bidders shall include a cashier’s or certified check or a satisfactory bid bond furnished by a solvent surety company authorized to do business in the state of West Virginia in an amount equal to five percent (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total amount of the bid. A West Virginia Contractor’s License Number must be included in the bid submission.

The successful bidder will be required to furnish Performance and Payment Bonds each equal to one-hundred percent (100{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the contract amount; the fee for all bonds shall be included in the bid proposal.

No bid may be withdrawn after the scheduled closing time for the receipt of bids for at least thirty (30) days.(605661)
Class: 983 DailyMail Legal Ads Last appeared: 08-05-2015

2.NOTICE OF
TRUSTEE’S SALE
NOTICE OF TRUSTEE’S SALE and Notice of the Beneficiary/Servicer’s election to sell property, is hereby given pursuant to and by virtue of the authority vested in the Trustee(s) by that certain Credit Line Deed of Trust dated March 29, 2004, executed by Mark E. Davis and Tammy L. Davis to Barry Dobson and George M. Cipriani, Trustees, of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3117, at Page 467. Hereford & Riccardi, PLLC was appointed as Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated June 3, 2015, of record in the Clerk’s Office in Book 4104, at Page 522. The borrowers defaulted under the Note and Deed of Trust and the Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on:MONDAY,
AUGUST 10, 2015,
AT 1:30 O’CLOCK P.M.
All that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, being the remainder of Lot 2, part of Lot 3, and abandoned road right of way in the subdivision of the George W. Scott Estate, situate in Charleston North Tax District, City of Charleston, Kanawha County, West Virginia, and being more particularly described as follows:

Beginning at a ¾ ” iron pipe found in the northerly right of way line of Woodbridge Drive, said pipe marking a common corner to the aforesaid Lot 2 and Lot 7-Section Two of Woodbridge Subdivision; thence with said right of way, S. 65 deg. 32′ 48″ W. 68.93 feet to a point in the traveled way known as Scott Road; thence leaving the aforesaid Woodbridge right of way and with line of Lot 2 along the easterly side of a 20 foot wide right of way the following courses and distances; N. 08 deg. 50′ 00″ W. 107.58 feet to a point, N. 38 deg. 11′ 00″ E. 68.44 feet to a point, N. 06 deg. 05′ 00″ W. 30.13 feet to a #5 rebar set; thence leaving said right of way and through Lot 3, N. 79 deg. 12′ 06″ E. 113.51 feet to a #5 rebar set, N. 89 deg. 00′ 00″ E. 33.00 feet to a #5 rebar set marking the southeast corner of said lot; thence crossing the aforesaid abandoned right of way, S. 46 deg. 34′ 54″ W. 44.03 feet to a #5 rebar set in the northerly or rear line of Lot 7 of Woodbridge Subdivision; thence with said rear line, S. 88 deg. 36′ 39″ W. 40.00 feet to a ¾” iron pipe found, thence through Lot 2, S. 12 deg. 00′ 39″ W. passing a ¾” iron pipe found at 50.04 feet, in all 155.54 feet to the point of beginning.

This is the same property conveyed unto Mark E. Davis and Tammy L. Davis by Deed dated July 10, 2003, of record in the Clerk’s Office in Book 2580, at Page 571. Thereafter, on April 14, 2008, the property was conveyed by VERA MCCORMICK, CLERK OF THE COUNTY COMMISSION OF KANAWHA COUNTY, WEST VIRGINIA, Grantor, and REBUILD AMERICA, INC., a Florida Corporation, (Assignee U.S. Bank Cust. Sass Muni V DTR) Grantee (“Rebuild”). The Deed and conveyance was declared null and void by that ORDER GRANTING HUNTINGTON NATIONAL BANK’S SUMMARY JUDGMENT entered in the Circuit Court of Kanawha County, West Virginia on March 20, 2014, which Order is of record in the Clerk’s Office in Book 2912, at Page 179. This Order was affirmed by Order entered in the Supreme Court of Appeals of West Virginia dated April 9, 2015, which Order is of record in the Clerk’s Office in Book 2912, at Page 188. TERMS OF SALE:
1)The property will be conveyed in an “AS IS” physical condition by Deed containing no warranty, express or implied, subject to the Internal Revenue Service right of redemption, all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights-of-ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-2.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

5)The Trustee shall be under no duty to cause any existing tenant or person occupying the property to vacate the property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

6)The total purchase price is payable to the Trustee by cashier’s check, cash or the equivalent within thirty (30) days of the date of sale, with ten (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total purchase price payable to the Trustee at sale by cashier’s check, cash or the equivalent.

Given under my hand this 20th day of July, 2015.HEREFORD & RICCARDI,
PLLC-TRUSTEE

By: Philip B. Hereford,
Member
405 Capitol Street,
Suite 306
Charleston,
West Virginia 25301
Phone: (304) 346 1800
WVSB #1687
(605308)
Class: 983 DailyMail Legal Ads Last appeared: 08-07-2015

3.NOTICE OF LOST
CERTIFICATE

To whom it may concern:
Take notice that the undersigned, being the owner of Stock Certificate No. C-2762 of Kenna Homes Cooperative Corporation having mislaid, lost or misplaced the same, has made application to Kenna Homes Cooperative Corporation for a duplicate stock certificate to replace the one lost.
Dated this 14th day of July, 2015.
Brian Slaman(604787)
Class: 983 DailyMail Legal Ads Last appeared: 08-07-2015

4.Request for Bid
The purpose of this bid is to establish a price basis upon which purchases, blanket-purchase agreement, blanket-service agreements or public works contracts can be issued for the listed items. The Fayette County Board of Education reserves the right to reject any/or all bids presented.

TITLE: Fayette County Student Drug Testing
A.Random drug testing

B.Athletes, extra-curricular activities, simulated workplace and student drivers

C.Opt-in student participants

D.Voluntary urine specimen testing

DUE DATE: August 10, 2015 by 4:00 PM

SEND TO:
Fayette County
Board of Education
111 Fayette Avenue
Fayetteville, WV 25840

CONTACT
INFORMATION

Bid packets regarding the drug testing bid specifications may be directed to:

Aimee Shumate
[email protected]
304.574.1176, ext. 2141

Questions regarding bid procedure and bid proposals may be directed to:

Serena Starcher
[email protected]
304-574-1176, ext. 2141(605662)
Class: 983 DailyMail Legal Ads Last appeared: 08-06-2015

5.TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE
The undersigned Trustee, by virtue of the authority vested in him by that certain Deed of Trust dated August 27, 2004, and duly recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed of Trust Book 3170, at Page 51, Christopher A. Kidd did convey unto Richard A. Pill, Trustee, certain real property described in said Deed of Trust; and default having been made under the aforementioned Deed of Trust, and the undersigned Trustee having been instructed by the secured party to foreclose thereunder, will offer for sale at public auction at the front door of the Kanawha County Courthouse, in Charleston, West Virginia, on Wednesday,
August 12, 2015,
at 5:30 PM
The following described real estate, with its improvements, easements and appurtenances thereunto belonging, situate in the Charleston District, Kanawha County, West Virginia, and more particularly described as follows:

Parcel One: All that certain lot or parcel of land situate on the waters of Two Mile Creek, in Charleston District, Kanawha County, West Virginia, beginning at an iron pin by a post in the right of way 119 feet from a Honey Locust tree in the right of way or road going up Scraggs Hollow, the dividing line tree between Oscar W. Rowley and Ernestine RCowley and Edward Amos and the two right of ways running south from said Scraggs Hollow Road; thence up the hill in an easterly direction 60 feet to a peach tree and iron pin; thence up the hill the same direction 97 feet to a post and iron pin; thence in a north easterly direction 40 feet to a post and iron pin; thence in a southerly direction 63 feet to a post and iron pin; thence back down the hill in a westerly direction 184 feet to an iron pin in said right of way; thence 37 feet in a northerly direction with said right of way to said post and iron pin place of beginning.

Parcel Two: That certain parcel of land situate on the waters of Kanawha Two Mile Creek, Charleston District, Kanawha County, West Virginia, and being more particularly described as follows:

BEGINNING at an iron pin along Friendly Drive and which iron pin is located at the corner of the property owned by the parties of the second part; thence with one line by of the property owned by the parties of the second part 60 feet to a stake; thence continuing with another line of said property by the said parties of the second part 97 feet to a stake and rear corner of the property of the parties of the second part; thence with the boundary line between the parties of the second part’s property and M.B. Kidd 56 feet to a stake; thence leaving said boundary line and running in a southwesterly direction 124 feet to the place of beginning.

This conveyance is made subject to such rights of way, easements, restrictions, covenants, conditions and reservations as may be found in prior deeds of record in the chain of title.

At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 2404 Friendly Drive, Charleston, WV 25312.

AND BEING the same real estate which was conveyed to Christopher A. Kidd, by Deed dated August 18, 2004, from Dorothy Miller, and recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 2611, at Page 421.

The above described property will be sold subject to any covenants, restrictions, easements, leases and conditions of record, and subject to any unpaid real estate taxes.

The subject property will be sold in “AS IS” condition. The Trustee shall be under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

TERMS: Ten percent (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the purchase price as a cash deposit with the balance due and payable within 30 days of the day of sale.Richard A. Pill, Trustee

P. O. Box 440,
85 Aikens Center,
Martinsburg, WV 25404
Phone (304) 263-4971,
Fax (304) 267-5840,
E-mail:
[email protected]
(605196)
Class: 983 DailyMail Legal Ads Last appeared: 08-11-2015

6.ADVERTISEMENT
FOR PROPOSALS
FOR THE
REDEVELOPMENT
OF PROPERTY
The Charleston Urban Renewal Authority (the Authority) hereby solicits sealed proposals for the redevelopment of property located at 1601-1609 Washington Street, East and containing approximately 8,000 square feet of building area (plus basement) on approximately 5,900 square feet of land.

The property is owned by the Authority and is identified as the Charleston East Tax District, Map 25, Tax Parcels 7 & 8, City of Charleston, Kanawha County, West Virginia.

All proposals must include a plan for the development of the entire building, although phasing will be considered. The project will respond to the requirements of the Corridor Village District (CVD) which allows for a wide variety of commercial and residential uses, including the mixture of uses within the same building. The developer will be responsible for all costs associated with purchasing (or leasing) and developing the property and locating tenants for long term occupancy. The property’s current value is approximately $25.00 per square foot of building.

The criteria upon which the developer is selected include, but are not limited to, factors such as project design, qualifications and experience of the developer, feasibility of financing and benefits to the community.

All proposals for development must be delivered to the Charleston Urban Renewal Authority, Suite 244, Morrison Building, 815 Quarrier Street, Charleston, West Virginia 25301 on or before 4:00 p.m. on Friday, September 25, 2015.

Persons or firms interested in submitting proposals may obtain further information as is available from the Authority’s office by calling (304) 348-6890 between the hours of 8:30 a.m. and 4:30 p.m., Monday through Friday, excluding holidays, or by writing the Authority at the above-stated address, or by email at [email protected].

The Authority reserves the right to reject any and all proposals received. EQUAL OPPORTUNITY
EMPLOYER

CHARLESTON URBAN
RENEWAL AUTHORITY
James H. Edwards
Executive Director
(605910)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

7.ADVERTISEMENT
Notice is hereby given that an application for Operator Assignment has been submitted to the Department of Environmental Protection (DEP) located at 254 Industrial Drive, Oak Hill, WV, 25901 for permit number S300405 held by Tyler Morgan, LLC, PO Box 3301, Charleston, WV 25333. This application will assign Administrative Services Inc., 1719 Pleasant Valley Rd, Given, WV 25245 as an operator on the permit above.

Comments on the application shall be in writing and shall identify the applicant and application number and should be sent to the DEP at the address above. Comments received by 9/11/2015, or thirty (30) days from date of publication, will be considered

A copy of the notification will be available until 9/11/2015, or thirty (30) days from date of publication in the DEP Regional Office located at the address above AND in the Kanawha County Clerk’s Office during normal business hours.

DEP Telephone Number
304-465-1911

NOTE: Location map not required. (606954)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

8.ADVERTISEMENT FOR BIDS

NITRO REGIONAL WASTEWATER UTILITY
WASTEWATER
SYSTEM
IMPROVEMENTS PROJECT

CONTRACT NO. 2015-01 BLAKES CREEK &
EASTWOOD SEWER EXTENSION

CONTRACT NO. 2015-02 BELT FILTER PRESS &
BUILDING
REPLACEMENT
Separate sealed Bids for the following installation work and/or furnishing of materials will be received by the Nitro Regional Wastewater Utility, City of Nitro, Kanawha County, West Virginia, until 1:30 P.M., L.P.T., on September 8, 2015.
Immediately following the scheduled closing time for the reception of Bids, all Bids which have been submitted in accordance with all Contract Documents will be publicly opened and read aloud.
A mandatory Pre-Bid Conference will be held at the City of Nitro, City Hall located at 20th Street & 2nd Avenue, Nitro, West Virginia, and will be held at 1:30 P.M., L.P.T., on August 25, 2015.

The Contract Documents may be examined at the following locations:

NRWU – City of Nitro F.W. Dodge Corporation
20th Street & 2nd Ave Plan Room
Nitro, WV 25143 3315 Central Avenue
Hot Springs, AR 71913

S & S Engineers, Inc Contractoirs Association of
501 Eagle Mountain Road West Virginia
Charleston, WV 25311 2114 Kanawha Blvd. E
Charleston, WV 25311

Copies of the Contract Documents may be obtained from the office of S & S Engineers, Inc., 501 Eagle Mountain Road, Charleston, West Virginia 25311, upon a non-refundable payment of $200.00 for Contract No. 2015-01 – Blakes Creek & Eastwood Acres Sewer Extension or $175.00 for Contract No. 2015-02 – Belt Filter Press & Building Replacement. Bidders wishing to have plans mailed will be charged an additional $25.00 per contract. All Bidders must have a current and valid West Virginia Contractor’s License per Section 21-11-11 of the West Virginia Code. A copy of the Bidder’s Contractor’s License must be submitted in the first envelope and all subcontractors must supply a current and valid contractor’s license number to the primary Bidder prior to award.
A five percent (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) Bid Bond or certified cashier’s check must accompany all Bids. After Bid opening, a Bidder may not withdraw his Bid for a period of ninety (90) days.
The Bid opening procedures shall be a two envelope system. The system shall consist of two separate and distinct envelopes each with proper identification. The envelopes shall be identified as “Bid Opening Requirements” (first envelope) and the other as “Bid Proposal” (second envelope). The first envelope must be submitted in a sealed envelope containing Bid Bond, Certificate of Compliance, Power of Attorney and all other necessary documents as specified in the Bidder’s Checklist. The second envelope must be a separate sealed envelope containing the Form of Proposal for the contract that is being bid.
Both the first envelope and second envelope must have the following information in the lower left hand corner:

Name and Address of Bidder, Bid for Contract No. 2015-01 – Blakes Creek & Eastwood Sewer Extension, Wastewater System Improvements Project or Contract No. 2015-02 – Belt Filter Press & Building Replacement, Wastewater System Improvements Project, Opening Time 1:30 P.M., L.P.T., on September 8, 2015.

The first envelope will be opened first and Bid Bond, Power of Attorney and Certificate of Compliance and other required documents as listed on the Bidder’s Checklist will be checked to make sure that all the documents are in order. If the documents are found to be in order, the second envelope containing the Bid will be opened and publicly read aloud. If the documents are not in order, then the second envelope shall be returned to the Bidder unopened. At that time, the Engineer will declare the bidder non-responsive.

The work to be bid upon is generally described as follows:

Contract No. 2015-01: Blakes Creek & Eastwood Sewer Extension
Installation of approximately 8,650 LF of 8″ PVC, 9,400 LF of 6″ PVC, 150 LF of 8″ DIP, 1,000 LF of 6″ DIP gravity sewer lines, 3,500 LF of 4″ PVC sewer lateral, 160 manholes, 3 pump stations, 3 grinder pump stations, 1,700 LF of 4″ PVC, 3,400 LF of 3″ PVC, 200 LF of 1¼” HDPE force mains to discharge into the existing sewer system, 580 LF of 30″ HDPE stormsewer, 720 LF of 24″ HDPE stormsewer, relining of 2,300 LF of 42″ brick sewer line, replacement of an existing pump station No. 6 and other appurtenances necessary to complete this project. Additive Alternate A includes the installation of approximately 685 LF of 6″ PVC, 115 LF of 6″ DIP gravity sewer lines, 90 LF of 4″ PVC sewer lateral, 7 manholes and other appurtenances necessary to complete this project.

Contract No. 2015-02: Belt Filter Press & Building Replacement
Replacement of existing belt filter press with a new 2.2 meter belt filter press system, complete with air compressor, wash water booster pump, control panel, polymer system, sludge pump, sludge cake conveyor, lime system, etc., construction of a new 48’x56′ belt filter press building, modification to existing effluent parshall flume structure and other appurtenances necessary to complete this project.

Prospective Bidders are advised that the contract awarded under this Advertisement for Bids is to be funded in whole or in part by the West Virginia Department of Environmental Protection Clean Water State Revolving Fund Program and Nitro Regional Wastewater
Utility. Neither the United States nor any of its departments, agencies, or employees is or will be a party to this Advertisement for Bids or any resulting contract.
Bidders must comply with the President’s Executive Order Nos. 11246 and 11375, which prohibit discrimination in employment regarding race, creed, color, sex or national origin. Bidders must comply with Title VI of the Civil Rights Act of 1964, the Anti-Kickback Act, Section 3 Segregated Facilities, Section 109, Davis Bacon Act and Wage Rates, West Virginia Division of Labor Wage Rates and the Contract Work Hours Standard Act.NOTICE OF FEDERAL WAGE REQUIREMENTS
Contractors are required to comply with all laws pertaining to prevailing federal wage rates issued in accordance with the Davis Bacon Act. The contractor will be required to pay the federal wage rates appropriate for each worker classification.SUSPENSION AND DEBARMENT
Recipient shall not entertain the use of businesses that are listed on the “Excluded Parties List System” at www.epls.gov in accordance with 2 CFR Part 1532 and Subpart B and C of 2 CFR Part 180.NONDISCRIMINATION IN EMPLOYMENT
Bidders on this work will be required to comply with the President’s Executive Order No. 11246. The requirements for bidders and contractors under this order are explained in the specifications.AMERICAN IRON AND STEEL REQUIREMENT
P.L. 113-76, SECTION 436
P.L. 113-76, Consolidated Appropriations Act, 2014 (Act), includes an “American Iron and Steel (AIS)” requirement in section 436 that requires Clean Water State Revolving Loan Fund (CWSRF) and Drinking Water State Revolving Loan Fund (DWSRF) assistance recipients to use iron and steel products that are produced in the United States for projects for the construction, alteration, maintenance, or repair of a public water system or treatment works.
The City of Nitro will consider informal any bid not prepared and submitted in accordance with the provisions hereof, and reserves the right to reject any and/or all Bids.NITRO REGIONAL WASTEWATER UTILITY
CITY OF NITRO
David Casebolt, Chairman & Mayor
(606238)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

9.ADVERTISEMENT
FOR BIDS
Kanawha County Parks and Recreation Commission

The Kanawha County Parks and Recreation Commission is accepting bids for the purchase of 6,000 pounds of Grass Seed. Bids will be received by Kanawha County Parks and Recreation Commission at the Administration Office, 2000 Coonskin Drive Charleston, WV 25311 until 2:00 p.m. Thursday August 27, 2015. At which time bids shall be opened and read aloud.

Copies of BID SPECIFICATIONS may be obtained at the Administration Office of Kanawha County Parks and Recreation Commission at 2000 Coonskin Drive, Charleston, WV 25311.

The Kanawha County Parks and Recreation Commission reserves the right to reject any and all bids.Jeffrey K. Hutchinson,
PGA Pro
Executive Director
(606810)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

10.ADVERTISEMENT
FOR BIDS
CITY OF
RONCEVERTE
STREETSCAPE PROJECT –
PHASES 3 and 4
Separate sealed bids for each Ronceverte Streetscape Project – Phases 3 and 4 will be received by the City of Ronceverte, until 2 p.m., local time on August 31, 2015, and then at said office publicly opened and read aloud.

These project phases involve the demolition of existing concrete pavements, construction of new concrete curbing and sidewalk, installation of truncated dome panels, streetlight installation and other electrical appurtenances, storm inlets and piping, and other miscellaneous site elements.

A mandatory pre-bid will be held August 20, 2015 at 10:00 am at City Hall.

Contract Documents for both phases 3 and 4 may be examined at the following locations:

Ronceverte City Hall
200 Main Street
Ronceverte, WV 24970
Office: 304-647-5455

Contractors Association
of West Virginia
2114 Kanawha Boulevard,
East
Charleston, WV 25311
304-342-1166

E. L. Robinson
Engineering
5088 Washington Street,
West
Charleston, WV 25313
304-776-7473

Copies of the contract documents may be obtained by contacting E. L. Robinson Engineering, 5088 Washington Street, West, Charleston, WV 25313 at 304-776-7473. A non-refundable $100 deposit is required for the combination of both phase 3 & 4 sets. There will be an additional charge for priority overnight delivery based on actual cost.

Bids shall be submitted to the attention of Mayor David Smith, City of Ronceverte, 200 Main Street, Ronceverte, WV 24970.  Bids may not be modified or withdrawn for a period of 60 days after receipt of Bids without forfeiture of Bid security, not as a penalty but as liquidated damages. A five percent (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) Bid Bond or certified cashier’s check must accompany all bids.

This project is partially funded by the Federal Highway Administration through the WVDOH Transportation Enhancement Program.

The successful bidder shall be required to pay the highest of the 2015 State/Federal local (prevailing) wage rates as determined by the Davis-Bacon Act.

Bidders on this work shall be required to comply with the President’s Executive Order No. 11246 which prohibits discrimination in employment regarding race, creed, color, sex, national origin, or physical disability, and bidders shall also comply with Title VI of the Civil Rights Act of 1964, the Davis-Bacon Act, the Anti-Kickback Act, and the Contract Work Hours Standards Act.

Any Contractor submitting a bid on this project hereby certifies, indicates, and acknowledges that he/she holds a current WV Contractor’s License on the date of the bid opening, and meets all the qualifications required by the statutes of the State and subdivision in which the work is to be performed and acknowledges the guidelines of the Enhancement Grant Program and all applicable State and Federal Regulations

The City of Ronceverte reserves the right to reject any or all bids and to waive any informality therein.(606809)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

11.ADVERTISEMENT
FOR BIDS

TAYLOR COUNTY
COURTHOUSE
TAYLOR COUNTY,
WEST VIRGINIA
PROPOSED
HVAC SYSTEMS
RENOVATIONS
THRASHER PROJECT
# 101-060-0304
Sealed Bids for The Taylor County Courthouse HVAC Systems Renovations will be received by the The Thrasher Group, Inc., 600 White Oaks Blvd., Bridgeport Harrison County, West Virginia, until 2:00 p.m., L.P.T., on Tuesday, September 8, 2015, for furnishing labor and materials and performing all Work set forth in the Contract Documents prepared by The Thrasher Group, Inc. Immediately following the scheduled closing time for the reception of Bids, all proposals which have been submitted in accordance with the conditions of the Contract Documents will be publicly opened and read aloud.

The approximate quantities of Work to be Bid upon is as described as follows:

Contractors are to provide all labor, bonds, taxes, fees, permits, materials, tools & equipment necessary to complete a full demolition of existing HVAC heating and cooling systems at the Taylor County Courthouse and Judicial Annex. Demolition is to include, but not limited to, all boilers, existing units, PTAC wall units, ductwork, wiring, and controls as shown per construction drawings. As well contractors are to complete a turnkey installation of a new “VRF” HVAC heating and cooling systems in both the courthouse and judicial annex. Also included in the scope of work will be patching and painting of all floors and walls associated with the demolition of the existing PTAC units, all patch and painting will match existing facility finishes. Along with patching will be the full replacement of all corridor lay in ceilings for both the annex and the courthouse. Contractors will also be asked to supply add alternate pricing for a two year maintenance contract with the Taylor County Commission to serve the newly installed system.

The Work will be substantially completed within 120 days after the date when the Contract Times commence to run, and completed and ready for final payment within 150 days after the date when the Contract Times commence to run. Liquidated damages shall be $500.00 per day.

Contract Documents may be examined at the following places:

The Taylor County
Commission
214 West Main Street
Grafton, WV 26354

The Thrasher Group, Inc.
600 White Oaks Boulevard
Bridgeport, WV 26330

Dodge Reports
www.mcgraw-hill.com
Contractor’s
Association of WV
2114 Kanawha Boulevard
East
Charleston, WV 25311

Complete sets of Bidding Documents may be obtained from the office of The Thrasher Group, Inc., 600 White Oaks Boulevard, P. O. Box 940, Bridgeport, WV 26330, for the following costs:

-Bidding Documents issued as hard copy drawings and hard copy specifications are available for $50.00 per set.

-Bidding Documents issued as digital drawings and digital specifications on a C.D., are available for $25.00 per set.

Amounts paid are not subject to refund.

A two envelope system will be used.

Envelope No. 1 must have the following information presented on the front:

Name and address of Bidder

Bid on: Taylor County Courthouse HVAC System Renovations

Received by the Taylor County Commission

Envelope No. 2 labeled “Bid Proposal” shall also be placed inside of Envelope #1.

Envelope No. 1 will be opened first and the Bid Opening Requirement items checked for compliance as outlined on the Bid Opening Checklist on page BOR – 1 of these contract documents. If such documents are found to be in order, Envelope No. 2 “Bid Proposal”, will then be opened and will be publicly read aloud. If the documents required to be contained in Envelope No. 1 are not in order, Envelope No. 2 “Bid Proposal” will not be opened and the Bid will be considered non-responsive and will be returned to the Bidder.

A Bidder may not withdraw his Bid for a period of ninety (90) days after the date set for the opening of Bids.

Bids shall be accompanied by a certified check or Bid Bond payable to the Taylor County Commission, an amount equal to five percent (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the base Bid.

Bidders must hold a current West Virginia contractor’s license on the date of Bid Opening.

Bids received after the scheduled closing time for the reception of Bids will be returned unopened to the Bidders.

The Taylor County Commission reserves the right to reject any and all Bids.

A MANDATORY pre-bid conference will be held at the Taylor County Courthouse located at 214 W. Main Street, Grafton, Taylor County, West Virginia, on Wednesday, August 19, 2015, at 10:00 a.m., L.P.T.
The Thrasher Group, Inc.
600White Oaks Blvd
Bridgeport, WV 26330
Rusty David Efaw,
President
Taylor County Commission
(606944)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

12.ADVERTISEMENT
FOR PROPOSALS
Sealed proposals will be received by the West Virginia Parkways Authority for:BRIDGE RETROFIT
CONTRACT
BR-1-15
MILEPOST 95
KANAWHA COUNTY
This project is located along the West Virginia Turnpike at I-77 Milepost 95. It consists of retrofit strengthening of SB Yeager Approach Span Unit A, Approach Span Unit B, West Truss, and East Truss.

A MANDATORY PRE-BID meeting will be held on August 18, 2015 at 2:00 pm at the office of the West Virginia Parkways Authority, Administration Building, Charleston, West Virginia. Attendees must be full time employees of the contractor.

All work under this contract shall be completed by June 30, 2016.

Proposals will be received at the office of the West Virginia Parkways Authority, Administration Building, Charleston, West Virginia until 3:00 PM September 1, 2015, at which time and place said proposals will be publicly opened and read. If proposals are to be mailed via the U.S. Postal Service regular mail, they must be addressed to the West Virginia Parkways Authority, P.O. Box 1469, Charleston, WV 25325. This mail is picked up by the Authority once a day between 7:00 AM and 8:00 AM. However, Express Mail One Day Service, Federal Express, United Parcel Service (UPS), etc., must be sent to the West Virginia Parkways Authority, 3310 Piedmont Road, Charleston, WV 25306. It shall be the bidder’s responsibility to determine his transmittal method such that his bid will arrive in the Authority’s office prior to the scheduled bid opening. Bids received in the Authority’s office after the scheduled opening will be returned to the bidder unopened.

Prospective bidders must be prequalified in accordance with SECTION 102.1 of the WVDOH Standard Specifications. Contract Documents without Standard Specifications or other referenced standards can be obtained from HNTB Corporation, 41 Mission Way, Scott Depot, WV 25560, Phone (304) 760-1806, or email [email protected].

Proposals must be made upon the forms furnished by the Authority in the manner designated in the specifications, and must be enclosed in sealed envelopes bearing the name and address of the bidder and the number of the contract on the outside, and must be accompanied by a CASHIER’S or CERTIFIED CHECK or BID BOND in favor of the West Virginia Parkways Authority, FOR AN AMOUNT EQUAL TO FIVE PERCENT (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) OF THE AMOUNT OF THE PROPOSAL OR $2,000 WHICHEVER IS THE GREATER, and must be delivered at the place designated above on or before the day and hour named.

Pursuant to Bureau of Employment Programs (BEP) Rule 96 C.S.R.1 Implementation Rule dated June 30, 2000, Contractors requesting plans must furnish their FEIN Number, company name and any name they are doing business as. Firms listed in the BEP Default Directory will not be issued Bidding Documents.

The Authority reserves the right to reject any and all Proposals submitted, and to waive any or all formalities in bidding, as it may deem in its best interest.

The Authority strongly encourages Minority Owned and Women Owned businesses to submit proposals for this contract.

The WVPA is an Equal Opportunity Employer. All firms submitting proposals must certify that they practice Equal Employment Opportunities.(606953)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

13.Braxton County
Development Authority
SUTTON,
WEST VIRGINIA

INVITATION TO BID
For the
Braxton County RETI Conference Center

Sealed bids for proposed Braxton County RETI Conference Center, will be received by the Owner (hereafter known as the Owner), attention Terrell Ellis, c/o The Braxton County Development Authority, Braxton County Tech. Center, 89 Richard D. Minnich Drive, Room 101, Sutton, West Virginia, 26601, until 11:00 am L.P.T., on Thursday, September 10, 2015, for performing all Work set forth in the Contract Documents prepared by Omni Associates – Architects, Inc. which will be available as of Wednesday August 12, 2015. A Mandatory Pre-bid Conference will be held at the Braxton County Tech. Center, 89 Richard D. Minnich Drive, Room 101, Sutton, West Virginia, 26601 on Friday, August 20, 2015 at 10:00 am L.P.T. Directions can be obtained from the office of the Omni Associates. It is required that any Prime Bidder, or his representative, planning to submit a Bid on this Project be in attendance at this meeting.

The project will be constructed under a Single Prime Contract as follows: Braxton County RETI Conference Center.

Immediately following the scheduled closing time for the reception of Bids, all proposals that have been submitted in accordance with the conditions of the Contract Documents will be publicly opened and read aloud.

Contract Documents and a full copy of the Invitation to Bid may be examined at the following locations:

Omni Associates – Architects
1543 Fairmont Avenue, Suite 201
Fairmont, WV 26554

Electronic copy (pdf) of Drawings and Specifications will be available from the office of the Omni Associates, 1543 Fairmont Avenue, Suite 201, Fairmont, WV 26554, 304-367-1417, [email protected].(606502)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

14.CITY OF CHARLESTON
ADVERTISEMENT
FOR BIDS
STORM SEWER
REHABILITATION
PROJECT
CURED IN PLACE
PIPE (CIPP) LINING,
VARIOUS LOCATIONS
PROJECT NUMBER
E3 08/15-094
The City of Charleston, West Virginia will receive sealed bids for the installation of CIPP within storm sewer pipes at various locations until 10:00 a.m., Thursday, August 13, 2015 in the City Manager’s Office on the first floor of City Hall. Immediately following the scheduled closing time for the receipt of bids, all proposals which have been submitted in accordance with the project requirements will be publicly opened and read aloud. The City reserves the right to reject any or all bids, to waive any informalities in bidding, and to accept the bid considered to be in its best interest from the lowest responsible bidder. All interested parties are invited to attend the bid opening.

Plans and specifications may be obtained from the City Manager’s Office. Plans and specifications may be examined at the following locations:

Contractor’s Association
of West Virginia
2114 Kanawha Blvd.,
East
Charleston, WV 25311
City of Charleston
City Manager’s Office
501 Virginia St., East;
Room 101
Charleston, WV 25301

The Contractor will be required to comply with all applicable Federal requirements pertaining to Affirmative Action, Employment Opportunity, Federal Labor Standards, Copeland Anti-Kickback Act, and DBE/WBE goals as described in the Specifications.

A mandatory pre-bid conference for the purpose of discussing and clarifying the project plans and specifications will be held at 10:00 a.m. on Thursday, August 6, 2015, in the City Engineer’s Office located at 114 Dickinson Street.

All bidders shall include a cashier’s or certified check or a satisfactory bid bond furnished by a solvent surety company authorized to do business in the state of West Virginia in an amount equal to five percent (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total amount of the bid. A West Virginia Contractor’s License Number must be included in the bid submission.

The successful bidder will be required to furnish Performance and Payment Bonds each equal to one-hundred percent (100{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the contract amount; the fee for all bonds shall be included in the bid proposal.

No bid may be withdrawn after the scheduled closing time for the receipt of bids for at least thirty (30) days.(605661)
Class: 983 Gazette Legal Ads Last appeared: 08-05-2015

15.CLASS II LEGAL NOTICE
REQUEST FOR
BID NUMBER
WVSOM-16-B-008
WVSOM TUCK
POINT PROJECT
(MAIN BUILDING “B”)
The West Virginia School of Osteopathic Medicine (WVSOM) Board of Governors on behalf of WVSOM located at 400 North Lee Street, Lewisburg, WV 24901 is soliciting Request for Bids (RFB) for competitive firm fixed priced bids (FFP) from qualified, responsive and responsible vendors to complete the WVSOM Tuck Pointing Contract (Main Building (B).

MANDATORY PRE-BID MEETING: All potential Bidders must attend a Mandatory Pre-Bid Meeting which will be held at the date, time and location identified below:

Date:17 August 2015

Time: 10:00 a.m.

Location:
WVSOM Campus,
Main Building (Quad)
2nd Floor Conference Room

Any questions pertaining to this RFB shall be submitted IN WRITING ONLY, no later than 4:30 p.m. on 20 August 2015, to the address below.

Sealed bids will be received in the WVSOM Contracts Department, Room A220/221, located at 400 North Lee Street, Lewisburg, WV 24901 until 3:30 p.m. (EST) on 25 August 2015, at which time all sealed bids will be publically opened and read aloud. Bids received after that date and time will not be opened or considered for award.

All bids must be submitted in accordance with the RFB, as issued by the WVSOM Contracts Department. The RFB will be issued on or about 10 August 2015. ALL REQUESTS FOR THE RFB AND QUESTIONS MUST BE SUBMITTED IN WRITING ONLY TO:
West Virginia School of
Osteopathic Medicine
400 North Lee Street,
Lewisburg, WV 24901
WVSOM Point of
Contact: Debbie Pope,
Contracts Dept.
Room A220/221 or
via email
[email protected]

Additional information and requirements will be provided in the WVSOM RFB Documents.Debbie Pope,
Purchasing Assistant II WVSOM Contracts Dept.
(606812)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

16.Henry-Theodore: Elden-Jr. secured rights, property & defenses in publicly recorded documents at Kanawha Co. Courthouse. View at www.abodia.com/docs Learn your rights – see Ted in court 344-2335
[email protected](606245)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

17.IN THE CIRCUIT COURT OF KANAWHA COUNTY,
WEST VIRGINIA
ERIE INSURANCE COMPANY
Plaintiff,

v.
Civil Action No 15-C-1355

JAMIE KUBBE,
Defendants.ORDER OF
PUBLICATION

The object of the above titled action is to collect a debt. And it appearing by and affidavit filed in this action that the Plaintiff has exercised due diligence to locate the Defendant and failed to locate them.
It is ordered that Jamie Kubbe do serve upon Clinton W. Smith, Plaintiff’s Attorney, whose address is Mezzanine Suite 4, 405 Capitol Street, Charleston, West Virginia 25301, an answer, including an related counterclaim you may to the complaint filed against you in the above styled civil action, a true copy of said complaint can be obtained from the undersigned Clerk at their office. You are required to serve your answer with in 20 days after service of this Summons upon you, exclusive of the day of service. If you fail to do so, judgment by default will be taken against you for the relief demanded in the Complaint and you will be thereafter barred for asserting another action any claim you may have which must be asserted by counterclaim in the above styled civil action.
Entered by the Clerk of said Court July 22, 2015.Cathy S. Gatson
Clerk
Clerk of Court
(605949)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

18.IN THE CIRCUIT COURT OF
KANAWHA COUNTY, WEST VIRGINIA
IN RE: CHANGE OF NAME FROM : Deloris A. Fredrick TO: Deloris A. Dawson

CIVIL ACTION
NO.: 15-P-316LEGAL NOTICE OF PUBLICATION
CHANGE OF NAME PROCEEDING
Notice is hereby given that on the 1st day of Deptember, 2015 at 1:00 p.m. on said day, or as soon thereafter as the matter may be heard, Deloris A. Fredrick will apply by Petition to the Circuit Court of Kanawha County, West Virginia for the entry of an order by said Court changing his/her name from Deloris A. Fredrick to Deloris A. Dawson, at which time and place any interested party may appear and be heard, if they so desire.
You are hereby notified that this matter may be rescheduled without further notice or publication.
A copy of said Petition can be obtained from the undersigned Clerk’s Office at: 111 Court Street, Charleston, West Virginia, 25301.
Entered by the Clerk of said Court this 3rd day of August, 2015.Cathy S. Gatson
Kanawha County Circuit Clerk
(606539)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

19.IN THE CIRCUIT COURT OF
KANAWHA COUNTY, WEST VIRGINIA
IN RE: CHANGE OF NAME FROM : Kevin Gatling TO : Kevin Williams

CIVIL ACTION
NO.: 15-P-313LEGAL NOTICE OF PUBLICATION
CHANGE OF NAME PROCEEDING

Notice is hereby given that on the 31st day of August, 2015 at 10:00 a.m. on said day, or as soon thereafter as the matter may be heard, Kevin Gatling will apply by Petition to the Circuit Court of Kanawha County, West Virginia for the entry of an order by said Court changing his/her name from Kevin Gatling to Kevin Williams, at which time and place any interested party may appear and be heard, if they so desire.
You are hereby notified that this matter may be rescheduled without further notice or publication.
A copy of said Petition can be obtained from the undersigned Clerk’s Office at: 111 Court Street, Charleston, West Virginia, 25301.
Entered by the Clerk of said Court this 31stth day of July, 2015.Cathy S. Gatson
Kanawha County Circuit Clerk
(606386)
Class: 983 Gazette Legal Ads Last appeared: 08-05-2015

20.IN THE CIRCUIT COURT OF
KANAWHA COUNTY, WEST VIRGINIA
IN RE: CHANGE OF NAME FROM: Alyssa Joy Dolson TO: Alyssa Joy Padgett

CIVIL ACTION
NO.: 15-P-325LEGAL NOTICE OF PUBLICATION
CHANGE OF NAME PROCEEDING
Notice is hereby given that on the 28th day of August, 2015 at 10:30 a.m. on said day, or as soon thereafter as the matter may be heard, Bruce Padgett will apply by Petition to the Circuit Court of Kanawha County, West Virginia for the entry of an order by said Court changing the name of his/her child from Alyssa Joy Dolson to Alyssa Joy Padgett, at which time and place any interested party may appear and be heard, if they so desire.
You are hereby notified that this matter may be rescheduled without further notice or publication.
A copy of said Petition can be obtained from the undersigned Clerk’s Office at: 111 Court Street, Charleston, West Virginia, 25301.
Entered by the Clerk of said Court this 6th day of August, 2015.Cathy S. Gatson
Kanawha County Circuit Clerk
(606885)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

21.IN THE CIRCUIT COURT OF
KANAWHA COUNTY, WEST VIRGINIA
IN RE: CHANGE OF NAME FROM: Dustin Troy Lee Rubin TO: Dustin Troy Lee BurkerCIVIL ACTION
NO.: 15-D-320

LEGAL NOTICE OF PUBLICATION
CHANGE OF NAME PROCEEDING
Notice is hereby given that on the 11th day of September, 2015 at 1:30 p.m. on said day, or as soon thereafter as the matter may be heard, Dustin Troy Lee Rubin will apply by Petition to the Circuit Court of Kanawha County, West Virginia for the entry of an order by said Court changing his/her name from Dustin Troy Lee Rubin to Dustin Troy Lee Burker, at which time and place any interested party may appear and be heard, if they so desire.
You are hereby notified that this matter may be rescheduled without further notice or publication.
A copy of said Petition can be obtained from the undersigned Clerk’s Office at: 111 Court Street, Charleston, West Virginia, 25301.
Entered by the Clerk of said Court this 5th day of August, 2015.Cathy S. Gatson
Kanawha County Circuit Clerk
(606735)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

22.IN THE CIRCUIT COURT OF
KANAWHA COUNTY, WEST VIRGINIA
IN RE: CHANGE OF NAME FROM: Stephanie Ashley-Anne Rubin TO: Stephanie Ashley-Anne BurkerCIVIL ACTION
NO.: 15-D-321

LEGAL NOTICE OF PUBLICATION
CHANGE OF NAME PROCEEDING
Notice is hereby given that on the 11th day of September, 2015 at 1:30 p.m. on said day, or as soon thereafter as the matter may be heard, Stephanie Ashley-Anne Rubin will apply by Petition to the Circuit Court of Kanawha County, West Virginia for the entry of an order by said Court changing his/her name from Stephanie Ashley-Anne Rubin to Stephanie Ashley-Anne Burker, at which time and place any interested party may appear and be heard, if they so desire.
You are hereby notified that this matter may be rescheduled without further notice or publication.
A copy of said Petition can be obtained from the undersigned Clerk’s Office at: 111 Court Street, Charleston, West Virginia, 25301.
Entered by the Clerk of said Court this 7th day of August, 2015.Cathy S. Gatson
Kanawha County Circuit Clerk
(606989)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

23.IN THE CIRCUIT COURT OF
KANAWHA COUNTY, WEST VIRGINIA
IN RE: CHANGE OF NAME FROM: Tiara Nicholle Jones-Fields
TO:Tiara Nicholle Jones

CIVIL ACTION
NO.: 15-P-278
Judge KaufmanLEGAL NOTICE OF PUBLICATION
CHANGE OF NAME PROCEEDING
Notice is hereby given that on the 1st day of September, 2015 at 8:45 a.m. on said day, or as soon thereafter as the matter may be heard, Tiara Nicholle Jones-Fields will apply by Petition to the Circuit Court of Kanawha County, West Virginia for the entry of an order by said Court changing his/her name from Tiara Nicholle Jones-Fields to Tiara Nicholle Jones, at which time and place any interested party may appear and be heard, if they so desire.
You are hereby notified that this matter may be rescheduled without further notice or publication.
A copy of said Petition can be obtained from the undersigned Clerk’s Office at: 111 Court Street, Charleston, West Virginia, 25301.
Entered by the Clerk of said Court this 13th day of July, 2015.Cathy S. Gatson
Kanawha County Circuit Clerk
(606509)
Class: 983 Gazette Legal Ads Last appeared: 08-05-2015

24.IN THE CIRCUIT COURT OF KANAWHA COUNTY,
WEST VIRGINIA
Richard Jeffrey,
Plaintiff

Civil Action No 15-C-292

David A. Schoolcraft
and Alan W. Schoolcraft,
DefendantsORDER OF
PUBLICATION
The object of the above entitled action is a domestic lawsuit against Respondent, David Alan Schoolcraft.
And it appearing by an affidavit filed in this action that the Petitioner, Richard Jeffrey, by and through his Attorney, Katherine L. Dooley, has been unable, despite reasonable efforts, to secure service by the Court of the Petition, filed on
February 7, 2015, upon Respondent, David Alan Schoolcraft.
Having found that due diligence was undertaken to have the Respondent served without effect it is Ordered that David Alan Schoolcraft do serve upon Petitioner’s attorney, whose address is P.O. Box 11270, Charleston, WV 25339-1270 an answer or other defense to the Petition filed in this action on or before August 22, 2015, otherwise judgment by default will be taken against David Alan Schoolcraft at any time thereafter. A copy of said Complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court July 24, 2015
Cathy S. Gatson
Clerk
(
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

25.IN THE CIRCUIT
COURT OF
KANAWHA COUNTY,
WEST VIRGINIA
STATE OF WEST VIRGINIA
Petitioner

v. CASE NO. 15-C-1411

2004 JAGUAR XJ8
VIN: SAJEA71C74SG09072
(Timothy A. Johnson
aka Zan)
Respondent

On April 23, 2015, Officers of the Metropolitan Drug Enforcement Network Team seized a 2004 Jaguar XJ8, VIN: SAJEA71C74SG09072, located at or near 1562 Franklin Avenue, Charleston, Kanawha County, West Virginia. The 2004 Jaguar XJ8, VIN: SAJEA71C74SG09072 constitutes a conveyance which was used, had been used or was intended for use, to transport, or in any manner facilitate the transportation, sale, receipt, possession or concealment of a controlled substance, in violation of West Virginia Code, Chapter 60A, and/or the laws of the State of West Virginia. The 2004 Jaguar XJ8, VIN: SAJEA71C74SG09072, was found in the possession and /or control of Timothy Johnson and at the time of the seizure, he claimed ownership. The State of West Virginia has filed a Forfeiture Petition wherein it has asked the Circuit Court of Kanawha County, West Virginia to forfeit the above-described 2004 Jaguar XJ8, VIN: SAJEA71C74SG09072, to the State and to vest title to ownership of the in the State of West Virginia. A copy of said Forfeiture can be obtained from the Kanawha County Clerk’s Office. Any person having a claim upon the above-described 2004 Jaguar XJ8, VIN: SAJEA71C74SG09072, shall make a claim on said property on or before the passing of 30 days from the first publication of this legal publication. Any claim must clearly identify the claimant and the address at which legal process can be served upon the claimant. All claims shall be delivered to Reagan E. Whitmyer, Assistant Prosecuting Attorney, 301 Virginia Street East, Charleston, WV, 25301.

STATE OF WEST VIRGINIA
and METROPOLITAN
DRUG ENFORCEMENT
NETWORK TEAM
CHARLES MILLER
Prosecuting Attorney
By: Reagan Whitmyer,
Assistant Prosecuting
Attorney
for Kanawha County,
West Virginia
(605595)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

26.IN THE CIRCUIT
COURT OF
KANAWHA COUNTY,
WEST VIRGINIA
STATE OF WEST VIRGINIA
Petitioner

v. CASE NO. 15-C-1410

2015 CHEVROLET IMPALA, VIN: 2G1WB55K369392359, 2001 GMC SIERRA, VIN: 2GTEK69U711370764, And $490.00 (FOUR HUNDRED AND NINETY DOLLARS), In United States Currency,
(Lemoine K. Richmond
aka Snoop)
Respondent

On April 30, 2015, Officers of the Metropolitan Drug Enforcement Network Team seized a 2015 Chevrolet Impala, VIN: 2G1WB55K369392359, 2001 GMC Sierra, VIN: 2GTEK69U711370764, and $490 (Four Hundred and Ninety Dollars) at or near 5639 MacCorkle Avenue, South Charleston, Kanawha County, West Virginia. The 2015 Chevrolet Impala, VIN: 2G1WB55K369392359, 2001 GMC Sierra, VIN: 2GTEK69U711370764, and $490 (Four Hundred and Ninety Dollars) constitutes a conveyance which was used, had been used or was intended for use, to transport, or in any manner facilitate the transportation, sale, receipt, possession or concealment of a controlled substance, in violation of West Virginia Code, Chapter 60A, and moneys furnished or intended to be furnished, in violation of West Virginia State Code, Chapter 60A, by any person in exchange for a controlled substance, and/or proceeds traceable to such an exchange, and/or moneys used, or which have been used, or which are intended to be used to facilitate any violation of the West Virginia Sate Code, Chapter 60A and/or the laws of the State of West Virginia. 2015 Chevrolet Impala, VIN: 2G1WB55K369392359, 2001 GMC Sierra, VIN: 2GTEK69U711370764, and $490 (Four Hundred and Ninety Dollars) were found in the possession and /or control of Lemoine Richmond and at the time of the seizure, he claimed ownership of the same. The State of West Virginia has filed a Forfeiture Petition wherein it has asked the Circuit Court of Kanawha County, West Virginia to forfeit the above-described 2015 Chevrolet Impala, VIN: 2G1WB55K369392359, 2001 GMC Sierra, VIN: 2GTEK69U711370764, and $490 (Four Hundred and Ninety Dollars), to the State and to vest title to ownership of the in the State of West Virginia. A copy of said Forfeiture can be obtained from the Kanawha County Clerk’s Office. Any person having a claim upon the above-described 2015 Chevrolet Impala, VIN: 2G1WB55K369392359, 2001 GMC Sierra, VIN: 2GTEK69U711370764, and $490 (Four Hundred and Ninety Dollars), shall make a claim on said property on or before the passing of 30 days from the first publication of this legal publication. Any claim must clearly identify the claimant and the address at which legal process can be served upon the claimant. All claims shall be delivered to Reagan E. Whitmyer, Assistant Prosecuting Attorney, 301 Virginia Street East, Charleston, WV, 25301.

STATE OF WEST VIRGINIA
and METROPOLITAN
DRUG ENFORCEMENT
NETWORK TEAM
CHARLES MILLER
Prosecuting Attorney
By: Reagan Whitmyer,
Assistant Prosecuting
Attorney
for Kanawha County,
West Virginia
(606591)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

27.IN THE
FAMILY COURT OF
KANAWHA COUNTY,
WEST VIRGINIA

LEGAL NOTICE
IN THE MATTER OF:

Amoret McClung

Civil Action #:
10-D-2173

Camie Shirkey
James Miller
RESPONDENT(S)

The object of the above-entitled action is: Obtain Modification of Guardianship

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the Petitioners used due diligence to ascertain the whereabouts of Camie Shirkey and James Miller without effect is here by ordered that Camie Shirkey and James Miller serve upon Amoret McClung, whose address is PO Box 56, Smithville, WV 26178, an answer, including any related counter claim or defense you may have to the petition filed in this action on or before September 1, 2015. If you fail to do so, thereafter, upon proper hearing, Petitioners will be granted relief demanded in their Petition being appointed Guardians of said infant.

A copy of said Petition can be obtained from the undersigned Clerk at her office.

Entered by the Clerk of said Court this the 3rd day of Aug, 2015.Cathy S. Gatson
Clerk of Court
(606529)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

28.IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA
To: Aaron Barefield
Respondent’s Name
1049 Circle Drive
Dunbar, WV 25064
Address
05/21/85
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1153

Family Court Civil
Action: 15-DV-1102ORDER OF
PUBLICATION
PROTECTION ORDER
1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order from the Circuit Clerk of the county listed above.

TO THE ABOVE-NAMED RESPONDENT:
If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 11/02/2015.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 7, 2015Cathy S. Gatson
Circuit Clerk
(606985)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

29.IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA
To: Barry Lee Pace
Respondent’s Name
103 Ohio Avenue
Charleston, WV 25302
Address

Magistrate Court
Case No: 15-D-1042

Family Court Civil
Action: 15-DV-996ORDER OF
PUBLICATION
PROTECTION ORDER
1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order from the Circuit Clerk of the county listed above.

TO THE ABOVE-NAMED RESPONDENT:
If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 01/11/2016.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 6, 2015Cathy S. Gatson
Circuit Clerk
(606992)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

30.IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA
To: Charles D. Williams
Respondent’s Name
305 Glenwood Avenue
Charleston, WV 25302
Address
09/30/83
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1070

Family Court Civil
Action: 15-DV-1022ORDER OF
PUBLICATION
PROTECTION ORDER
1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order from the Circuit Clerk of the county listed above.

TO THE ABOVE-NAMED RESPONDENT:
If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 01/20/2016.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 6, 2015Cathy S. Gatson
Circuit Clerk
(606991)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

31.IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA
To: Christian Tabias Lilly
Respondent’s Name
4404 Brounland Road
Charleston, WV 25314
Respondent’s Address
02/12/71
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1152

Family Court Civil
Action: 15-DV-1101ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE
1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order and Petition from the Circuit Clerk of the county listed above.
TO THE ABOVE-NAMED RESPONDENT:
If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 08/18/2015.
A final hearing is scheduled for the 18th day of August, 2015., at 9:15 am before the Kanawha County Family Court.
Issued this August 6, 2015Cathy S. Gatson
Circuit Clerk
(606984)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

32.IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA
To: James Michael Bastic
Respondent’s Name
198 Delaware St.
Charleston, WV 25311
Respondent’s Address
05/27
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1137

Family Court Civil
Action: 15-DV-1087ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE
1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order and Petition from the Circuit Clerk of the county listed above.
TO THE ABOVE-NAMED RESPONDENT:
If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/08/2015.
A final hearing is scheduled for the 8th day of September, 2015., at 9:30 am before the Kanawha County Family Court.
Issued this August 6, 2015Cathy S. Gatson
Circuit Clerk
(606981)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

33.IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA
To: Mark Edward Mike
Respondent’s Name
4564 Victoria Road
Charleston, WV 25313
Address
11/03/92
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1100

Family Court Civil
Action: 15-DV-1052ORDER OF
PUBLICATION
PROTECTION ORDER
1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order from the Circuit Clerk of the county listed above.

TO THE ABOVE-NAMED RESPONDENT:
If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 01/21/2016.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 6, 2015Cathy S. Gatson
Circuit Clerk
(606990)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

34.IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA
To: Samuel Jordan Fleet
Respondent’s Name
1922 Grant Avenue
St. Albans, WV 25177
Address
02/12/93
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-185

Family Court Civil
Action: 15-DV-178ORDER OF
PUBLICATION
PROTECTION ORDER
1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order from the Circuit Clerk of the county listed above.

TO THE ABOVE-NAMED RESPONDENT:
If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 11/10/2015.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 6, 2015Cathy S. Gatson
Circuit Clerk
(606987)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

35.IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA
To: Samuel Jordan Fleet
Respondent’s Name
1922 Grant Avenue
St. Albans, WV 25177
Address
02/12/93
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-186

Family Court Civil
Action: 15-DV-179ORDER OF
PUBLICATION
PROTECTION ORDER
1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order from the Circuit Clerk of the county listed above.

TO THE ABOVE-NAMED RESPONDENT:
If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 11/10/2015.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 6, 2015Cathy S. Gatson
Circuit Clerk
(606986)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

36.INVITATION FOR
AUDIT PROPOSALS
DUNBAR HOUSING
AUTHORITY
The Dunbar Housing Authority is inviting Certified Public Accountants or licensed public accountants to submit proposals by September 8, 2015 for auditing the financial operations of the Authority for the one-year period ending September 30, 2015 with the option of auditing its financial statements for each of the three subsequent fiscal years – 2016 through 2018. After the first year, the Authority reserves the right to extend the agreement and to negotiate rates, terms and conditions, based on changes of circumstances or re-RFP the audit, as maybe in the Authority’s best interest.

The audits shall be performed in accordance with federal regulations and OMB Circular A-133 and generally accepted auditing standards as established by the AICPA (and must be completed by March 31, 2016). For further information concerning the procedures for submitting an audit proposal, interested accountants should call the Dunbar Housing Authority at telephone number 304-768-8006 or write to the Authority at 900 Dutch Hollow Road, Dunbar, West Virginia 25064.Kathryn Hyer
Executive Director
Dunbar Housing
Authority
EOH EOE
(606803)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

37.LEGAL NOTICE

July 30, 2015
James L. Pitrolo, Jr., Chairman of the West Virginia Health Care Authority, today announced that the Authority has received a request for an exemption from Certificate of Need review, pursuant to W.Va. C.S.R. § 65-27, from Charleston Hospital, Inc. d/b/a Saint Francis Hospital and Herbert J. Thomas Memorial Association, South Charleston, Kanawha County, CON File #15-3-10564-X, for the development of a hospital ambulatory health care facility in Kanawha County. The facility is located at 4610 Kanawha Avenue, S.W., Suite 401, South Charleston, Kanawha County. The office will be staffed by five (5) or less urology physicians.

The capital expenditure associated with the project is $90,000.

Any affected person may oppose this proposal by submitting a letter stating the reason for the opposition, within thirty days of the first date of publication of the public notice to:
Marianne Kapinos
General Counsel
West Virginia
Health Care Authority
Certificate of Need Program
100 Dee Drive
Charleston W.Va. 25311

The last date upon which an affected party may file a letter of opposition to this proposal is September 8, 2015.(606589)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

38.Legal Notice of State
Purchasing Division
The State of West Virginia Purchasing Division will accept sealed bids for:

Buyer
GN-44

CRFQ No.
DNR1600000001

Spending Unit
Division of
Natural
Resources

Commodity
Expression of Interest for Design and Engineering Services for Model Cabin renovation project in Watoga and Cass State Parks.

Bids/proposals must be submitted to the Purchasing Division located at 2019 Washington Street, East, Post Office Box 50130, Charleston, WV 25305-0130 as instructed in the specifications prior to the bid opening date and time scheduled for 08/27/2015 at 1:30 PM. Telephone inquiries may be made to Buyer designated in the specifications or 304-558-2596.(605755)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

39.NOTICE OF
PUBLIC REVIEW
Public Hearing Notice:  Availability of a federal grant plan for public review for the proposed use and distribution of funds.

The purpose is to receive comment on the proposed use of funds during Federal Fiscal Years 2016 and 2017. The grant being reviewed will be the Community Services Block Grant (CSBG). A public hearing will be held on Wednesday, August 19, 2015, at 3:00 p.m., 700 Washington Street East, Second Floor, Charleston, WV 25301. All written comments must be received before 5:00 p.m. on August 20, 2015. A copy of the plan will be available beginning on August 5, 2015 online at www.goeo.wv.gov. The public comment period will begin on August 5, 2015 and conclude on August 19, 2015 by close of business. Anyone may submit written comments regarding the proposed use of these funds. Written comments should be sent to, Director, WV Office of Economic Opportunity, 700 Washington Street East – 4th Floor, Charleston, WV 25301.(606421)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

40.NOTICE OF
SUCCESSOR
TRUSTEE’S SALE
Notice is hereby given, by virtue of the authority vested in the undersigned Successor Trustees, James W. Lane, Jr. and Bradford P. Bury, by that certain Deed of Trust made by Bronson Kennedy, dated May 4, 2007 and recorded May 8, 2007 in the office of the Clerk of the County Commission of Kanawha County, West Virginia in Trust Deed Book 3462 at page 419, the said Successor Trustees acting by virtue of that certain Appointment of Successor Trustee dated July 22, 2015 and recorded July 28, 2015 in the aforesaid Clerk’s office in Trust Deed Book 4114, at page 918, and default having been made in the payment of the Note secured by the aforesaid Deed of Trust, and having been requested in writing by the owner and holder of the Note, will offer for sale, at public auction, to the highest bidder at the front door of the Courthouse of Kanawha County, West Virginia, on September 8, 2015 at 9:15 a.m.,

All that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Elk District, Kanawha County, West Virginia, as shown upon a map entitled “Map Showing Property of Elizabeth M. And L. Hunter Coen, Elk District, Kanawha County, West Virginia, surveyed for F. J. And Mary L. Songer, September 1958”, by C. B. Holsclaw, Engineer, said map being of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 1258, at page 473, said parcel of land being more particularly bounded and described as follows:

BEGINNING at an iron pin the line between the property of Elizabeth M. and L. Hunter Coen and the Kanawha County Airport property, which pin is located S. 45° 40′ E., a distance of 310.0 feet from an iron pin said line, which iron pin is the northwestern corner of the remaining Coen property and the southwestern corner of the property heretofore conveyed to Robert W. Stroupe and Letha L. Stroupe, his wife, by deed dated August 9, 1957, of record in the aforesaid Clerk’s Office, by said Coens; thence running N. 50° 00′ E., a distance of 138.55 feet to an iron pin located in the western line of a private drive designated “Foster Drive”; thence running with said line S. 11° 59′ E., a distance of 149.73 feet to an iron pin; thence running S. 44° 20′ W., a distance of 54.82 feet to an iron pin located in said line between the property of Elizabeth M. and L. Hunter Coen and the Kanawha County Airport property; thence running with said line N. 45° 40′ W., a distance of 138.10 feet to the place of beginning, containing 0.30 acres.

Being the same property conveyed unto Bronson Kennedy by Asadollah Davari and Mozhgan D. Arjomand, his wife, by deed dated May 4, 2007 and recorded in the office of the Clerk of the County Commission of Kanawha County in deed book 2689 at page 483.

At the time of execution of the deed of trust, the grantor represented that the address of the property was 1511 Hunter Drive, Charleston, WV 25311.

TERMS OF SALE: The Premises will be sold “AS IS, WHERE IS,” in its present condition and with all faults and defects, if any. The Premises will be conveyed by deed with no covenants of warranty of title. The Premises shall be sold subject to all liens not discharged by the sale, including, without limitation, liens for real estate taxes, incinerator, sanitary and sewer charges and liens with priority to the Deed of Trust pursuant to which this sale is being conducted. The Premises shall be sold subject to all covenants, restrictions, easements, rights of way and reservations which may be a matter of record in the aforesaid Clerk’s office or visible upon the ground. The Premises will be sold for cash in hand on the date of sale to the highest bidder. The purchasers at the sale shall be responsible for paying the recording costs and also the tax on the privilege of transferring real property (the cost of the tax stamps to be affixed to the deed). The Successor Trustees and City National Bank of West Virginia shall not be responsible for the removal of any person or personal property from the Premises.

Pursuant to the Deed of Trust, the Successor Trustees may postpone the sale by public announcement at the time and place designated and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the Premises at such sale.

Dated: 7/30/2015.James W. Lane, Jr., Esq.
Bradford P. Bury, Esq.,
M.B.A.
Successor Trustees
200 Capitol Street,
Charleston, WV 25301
(304) 205-6373
(606331)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

41.NOTICE OF
TRUSTEE’S SALE
NOTICE IS HEREBY GIVEN that by virtue of a certain Deed of Trust (the “Deed of Trust”) dated January 13, 2003, made by McLain Surgical Supply, Inc., to Gregory Wm. Adkins and Matthew D. Smith, Trustees, of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book No. 2930, at page 651, to secure WesBanco Bank in the payment of the sum of $200,000.00, evidenced by a negotiable promissory note bearing even date therewith, and WesBanco Bank, Inc. being authorized and empowered to designate and appoint one or more substitute trustees in the place and stead of the trustee named in the Deed of Trust and the undersigned, Christopher R. Arthur and/or James H. Adkins, were so appointed by the terms of a Designation of Substitute Trustee of record in said Clerk’s office, and default having been made in the payment of said indebtedness and said Substitute Trustees having been requested in writing so to do by WesBanco Bank, Inc. owner and holder of said note, said Substitute Trustees, onTUESDAY,
AUGUST 25, 2015
AT 11:00 A.M.
EASTERN TIME
offer for sale and sell at public auction at the Kanawha County Courthouse, Charleston, West Virginia to the highest bidder therefore, which is comprised of all of ITS right, title and interest, in and to being all that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the City of Charleston, Kanawha County, West Virginia and being more particularly bounded and described as follows:

BEGINNING at a point in the northwesterly right of way of Broad Street, common corner between the herein described and conveyed parcel and a fifteen (15) foot wide alley; thence with said northwesterly right of way line of Broad Street, S. 47° 30′ W. 32.04 feet to a point; thence leaving Broad Street running through a parcel of land formerly owned by Harold E. Runyan et. al. N. 42° 30′ W. 98.59 feet to a point; thence N. 47° 30′ E. 32.09 feet to a point in the southerly right of way line of said fifteen (15) foot wide alley; thence with said southerly right of way line of said fifteen (15) foot wide alley, S. 42° 28′ 30″ E. 98.59 feet to the point at the place of beginning, said beginning of the aforesaid parcel being located N. 47° 30′ E. 131.29 feet from a point located at the juncture of the northwesterly right of way line of Broad Street with the northeasterly right of way line of Quarrier Street, all as shown on a map thereof entitled, “Plat showing a 0.073 Acre Tract Being Owned by Alfred L. Atkinson, Vernon L. Hess and Harold E. Runyan Situate at 205 Broad Street in the City of Charleston Kanawha County, West Virginia,” dated April 8, 1983, prepared by E.L. Robinson Engineering, which map is attached to that certain agreement dated April 22, 1983, between Alfred L. Atkinson and Stella R. Atkinson, his wife, Vernon H. Hess and Naomi R. Hess, his wife, and Harold E. Runyan and Erma G. Runyan, his wife, parties of the first part, and McLain Surgical Supply, Inc., a West Virginia corporation, party of the second part, filed and of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 2030, at page 700.

The sale of said property will be made subject to all exceptions, encumbrances, reservations, rights of way, easements, conditions, covenants, restrictions, leases and other servitudes of record, if any, pertaining to said real estate, and any and all unpaid taxes assessed against said property.

Joe R. Pyle Auction Service will assist with the sale. Any sale hereunder may be adjourned from time to time without notice other than oral proclamation at the time and place appointed for the sale. The Substitute Trustees reserve the right to reject any or all bids. Conveyance shall be by special warranty deed, and purchaser shall pay for all transfer stamps, recording fees, and other closing costs.

TERMS OF SALE: Ten percent (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the sales price shall be paid by cash, cashier’s check, or check guaranteed by bank letter of credit in acceptable form, in hand on the day of sale (the “Good Faith Deposit”), with the balance to be paid in cash at closing within 30 days after the date of sale. Additional terms and conditions shall be announced at the sale.

At public sale any person or entity may bid and may purchase any real estate sold if they be the highest bidder. If the real estate is sold for an amount in excess of the outstanding balance of the mortgage, together with all interest, unpaid real estate taxes and costs, said excess must be used to satisfy any other encumbrances on said property and after all said encumbrances are satisfied together with all interest and costs, any excess then remaining must be paid to the Grantor. If the Grantor or any person holding an encumbrance cannot be found after a diligent search, the money shall be paid into the Circuit Court of the county for the benefit of the Grantor or the holder of any such encumbrance.

Dated: July 21, 2015.
James H. Adkins,
as Substitute Trustee
Steptoe & Johnson PLLC
P. O. Box 1588
Charleston, WV 25326
(605418)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

42.NOTICE OF
TRUSTEE’S SALE
NOTICE OF TRUSTEE’S SALE and Notice of the Beneficiary/Servicer’s election to sell property, is hereby given pursuant to and by virtue of the authority vested in the Trustee(s) by that certain Credit Line Deed of Trust dated March 29, 2004, executed by Mark E. Davis and Tammy L. Davis to Barry Dobson and George M. Cipriani, Trustees, of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3117, at Page 467. Hereford & Riccardi, PLLC was appointed as Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated June 3, 2015, of record in the Clerk’s Office in Book 4104, at Page 522. The borrowers defaulted under the Note and Deed of Trust and the Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on:MONDAY,
AUGUST 10, 2015,
AT 1:30 O’CLOCK P.M.
All that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, being the remainder of Lot 2, part of Lot 3, and abandoned road right of way in the subdivision of the George W. Scott Estate, situate in Charleston North Tax District, City of Charleston, Kanawha County, West Virginia, and being more particularly described as follows:

Beginning at a ¾ ” iron pipe found in the northerly right of way line of Woodbridge Drive, said pipe marking a common corner to the aforesaid Lot 2 and Lot 7-Section Two of Woodbridge Subdivision; thence with said right of way, S. 65 deg. 32′ 48″ W. 68.93 feet to a point in the traveled way known as Scott Road; thence leaving the aforesaid Woodbridge right of way and with line of Lot 2 along the easterly side of a 20 foot wide right of way the following courses and distances; N. 08 deg. 50′ 00″ W. 107.58 feet to a point, N. 38 deg. 11′ 00″ E. 68.44 feet to a point, N. 06 deg. 05′ 00″ W. 30.13 feet to a #5 rebar set; thence leaving said right of way and through Lot 3, N. 79 deg. 12′ 06″ E. 113.51 feet to a #5 rebar set, N. 89 deg. 00′ 00″ E. 33.00 feet to a #5 rebar set marking the southeast corner of said lot; thence crossing the aforesaid abandoned right of way, S. 46 deg. 34′ 54″ W. 44.03 feet to a #5 rebar set in the northerly or rear line of Lot 7 of Woodbridge Subdivision; thence with said rear line, S. 88 deg. 36′ 39″ W. 40.00 feet to a ¾” iron pipe found, thence through Lot 2, S. 12 deg. 00′ 39″ W. passing a ¾” iron pipe found at 50.04 feet, in all 155.54 feet to the point of beginning.

This is the same property conveyed unto Mark E. Davis and Tammy L. Davis by Deed dated July 10, 2003, of record in the Clerk’s Office in Book 2580, at Page 571. Thereafter, on April 14, 2008, the property was conveyed by VERA MCCORMICK, CLERK OF THE COUNTY COMMISSION OF KANAWHA COUNTY, WEST VIRGINIA, Grantor, and REBUILD AMERICA, INC., a Florida Corporation, (Assignee U.S. Bank Cust. Sass Muni V DTR) Grantee (“Rebuild”). The Deed and conveyance was declared null and void by that ORDER GRANTING HUNTINGTON NATIONAL BANK’S SUMMARY JUDGMENT entered in the Circuit Court of Kanawha County, West Virginia on March 20, 2014, which Order is of record in the Clerk’s Office in Book 2912, at Page 179. This Order was affirmed by Order entered in the Supreme Court of Appeals of West Virginia dated April 9, 2015, which Order is of record in the Clerk’s Office in Book 2912, at Page 188. TERMS OF SALE:
1)The property will be conveyed in an “AS IS” physical condition by Deed containing no warranty, express or implied, subject to the Internal Revenue Service right of redemption, all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights-of-ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-2.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

5)The Trustee shall be under no duty to cause any existing tenant or person occupying the property to vacate the property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

6)The total purchase price is payable to the Trustee by cashier’s check, cash or the equivalent within thirty (30) days of the date of sale, with ten (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total purchase price payable to the Trustee at sale by cashier’s check, cash or the equivalent.

Given under my hand this 20th day of July, 2015.HEREFORD & RICCARDI,
PLLC-TRUSTEE

By: Philip B. Hereford,
Member
405 Capitol Street,
Suite 306
Charleston,
West Virginia 25301
Phone: (304) 346 1800
WVSB #1687
(605308)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

43.NOTICE OF
TRUSTEE’S SALE
NOTICE OF TRUSTEE’S SALE is hereby given pursuant to and by virtue of the authority vested in the Substitute Trustee, Pill & Pill, PLLC, by that certain Deed of Trust dated March 15, 2005, executed by Borrowers Cynthia S. Dotson and Fredrick Gregory Dotson, to Tommy J. Dixon , the Trustee of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3225, at Page 982. At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 5814 Church Drive, Charleston, WV 25306. Pill & Pill, PLLC was appointed as Substitute Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated February 3, 2015, of record in the Clerk’s Office in Book 4083, Page 226. The borrowers defaulted under the Note and Deed of Trust and the Substitute Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Substitute Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on the following date:August 26, 2015
at 5:32 p.m.
The property is described as of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Malden District, Kanawha County, West Virginia, and being more particularly described as follows:

ALL THAT CERTAIN PROPERTY SITUATED IN THE DISTRICT OF MALDEN, COUNTY OF KANAWHA AND STATE OF WEST VIRGINIA, LOT #18, IN BLOCK. J, MAP OF CONNELL, BEING MORE FULLY DESCRIBED IN A DEED VOLUME 2614 AND PAGE 647, MAP# 29B, PARCEL# 117 AND ACCOUNT# 6920371. TAX MAP OR PARCEL ID NO.: 29B-117

Being the same property conveyed to Cynthia S. Dotson and Frederick Gregory Dotson by the Deed dated October 7, 2004 and recorded in Deed Book 2614, at Page 647 in the Office of the Clerk of the County Commission of Kanawha County, West Virginia.TERMS OF SALE:
1)The property will be conveyed in an “AS IS” physical condition by Deed containing no warranty, express or implied, subject to the Internal Revenue Service right of redemption, all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights-of-ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-1.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

5)The Trustee shall be under no duty to cause any existing tenant or person occupying the property to vacate said property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

6)The total purchase price is payable to the Trustee by certified or cashier’s check within thirty (30) days of the date of sale, with ten (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total purchase price payable to the Trustee.Pill & Pill, PLLC,
Substitute Trustee

BY:Pill & Pill, PLLC
85 Aikens Center
Edwin Miller Boulevard
P.O. Box 440
Martinsburg, WV 25402
(304) 263-4971
pillforeclosures@
earthlink.net
(606184)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

44.Notice of Consulting Services
Notice is hereby given by the West Virginia Department of Transportation, Division of Highways, that engineering consulting services will be utilized for the following projects:

State Project S310-6-0.12 00, Earl M. Vickers Memorial Bridge Rehab +4, located in Fayette County, West Virginia. This project shall consist of a Renovation Study and development of Contract Plans for the renovation of structures carrying West Virginia Route 6 over the Kanawha River, CSX Railroad tracks, United States Route 60, West Virginia Route 61, and 4th and 5th Avenues. The project shall include the main river span, approach spans, and ramp bridges. The existing main river span is 1,665 feet long by 28 feet wide and connects United States Route 60 with West Virginia Route 61 in the City of Montgomery.

State Project S318-77-137.74 00, Mill Creek Bridge, located in Jackson County, West Virginia. This project shall consist of a Renovation Study and the development of Contract Plans for the renovation of the northbound and southbound bridges carrying Interstate 77 over Mill Creek and Jackson County Route 5/9. The existing bridges are 261 feet long by 41 feet wide and are located 0.15 miles south of the United States Route 33 interchange.

Method of payment shall be Lump Sum.

A single assignment will be made for each project.

Firms interested in being considered for either of these projects must submit a “Letter of Qualification” for each project and one unpriced prospectus to Mr. Michael D. Lilly, P. E., Section Head, Technical Section, Engineering Division, Division of Highways, 1334 Smith Street, Charleston, West Virginia 25301 or preferably by email to [email protected] to 4:00 p.m. on August 24, 2015.

As a minimum, the prospectus shall include the following evaluation information factors:

1.Professional qualifications necessary for consideration and satisfactory performance of the required work and as a minimum shall have a professional engineer licensed by the State of West Virginia. That person shall be located within the office where the work is to be performed, and shall demonstrate sufficient past experience performed for the State of West Virginia, Department of Highways related to design and plan development to be provided. This individual shall be the person-in-charge overseeing the work and must be readily accessible to the Department, preferably located in-state.

2.Consideration shall be given to specialized experience and technical competence. Specialized experience shall focus on the qualifications of the staff working on the project with emphasis placed on individual specialized expertise required for the project. As a minimum, the firm shall provide a Résumé of those individuals who will be committed to the needs of the project. Strong considerations will be based on the professional and non-professional staff specialized experience and technical competence stationed within the office where the work is to be performed.

3. Capacity consideration shall be made on the firm’s ability to accomplish the work within the Department’s required schedule time frame; personnel dedicated to perform such work.

4.Past performance on contracts with Government agencies and private industry in terms of cost control, quality of work, and compliance with performance schedules.

5.Location shall be based on the geographic location of the Consultant’s office relative to the project site along with past experience and knowledge of the area where the project site is located with the significant importance being given to accessibility of the office location relative to the Department.

In addition to the above evaluation factors, the prospectus shall include, as a minimum, the following items:

1.A completed copy of the Division’s Consultant Confidential Qualification Questionnaire dated January 1, 2015 or later, if not already on file. It must specifically indicate the staff levels by classification located in-state vs. out-of-state. It must also indentify the person in-charge overseeing the work that holds a valid professional license issued by the West Virginia Board of Professional Engineers.

2.Location of office or office(s) in which the work, or part of the work, will be performed.

3.Identification of subconsultants by name as to the type of work anticipated to be subcontracted or performed, if proposed as part of the design team.

4.Indication of whether a cost accounting system has been maintained and is in effect such that it is capable of segregating and identifying accumulating costs for each job that is performed under cost type projects.

5.Completed copies of the Division’s “Consultant Short List Selection Criteria Technical Evaluation” form limited to a single page of data. One loose leaf copy of form per project is to accompany the bound unpriced prospectus. Cross referencing on this form to other parts of the prospectus is not acceptable.

6.A copy of a valid “Certificate of Authorization” to offer Engineering, Surveying, or other related services within the state, issued by the appropriate West Virginia Board.

A single “Letter of Qualification” for each project and one unpriced prospectus are required and must contain all of the above information required to be considered. Failure to provide the required information and/or insufficient information will cause disqualification and the prospectus will be returned. All evaluation factors as noted herein before will be given equal consideration in the selection process, unless a project specific weighting of the evaluation factors is shown in the Notice for Consulting Services.

Prior to entering into any contract negotiations, the selected firm and any subconsultants shall submit a current audited overhead rate computation performed by a State or Federal government agency or independent CPA firm. The submitted overhead audit shall contain a detailed exhibit of the computations with all applicable eliminations and references. The audit shall be done in accordance with Government Auditing Standards issued by the Comptroller General of the United States and all eliminations required by the Federal Acquisition Regulations will be made. The submitted certified audited overhead (Indirect Cost Rate) report shall include the certification, certifying that the allowability of costs used to establish the final indirect cost rate are in accordance with the FAR cost principles, or a verification indicating this certification was previously submitted and accepted by the cognizant agency. This requirement will be waived for the selected firm or any subconsultant when its portion of the fee for the project is less than One Hundred Thousand Dollars ($100,000.00). In such instances, a company computed overhead rate may be utilized.

It is the policy of the West Virginia Department of Transportation, Division of Highways, that Disadvantaged and Women-owned Business Enterprises shall have the maximum opportunity to participate in the performance of contracts financed in whole or in part with Federal funds.(605893)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

45.NOTICE OF HEARING

Unknown Father
You have been named as the father of T.Mohamed, born to Maria Munos. A petition has been filed in the Circuit Court of Kanawha, West Virginia, and this petition requests the Court to grant permanent custody of this child to the West Virginia Department of Health and Human Resources.

This case is set for a hearing on August 13th, 2015, at 10:00 o’clock a.m. This hearing may result in the termination of all of your rights as the parent of above listed children. This hearing will be held before the Honorable Louis H. Bloom Circuit Judge, at the Kanawha County Judicial Annex, 111 Court Street, 5th Floor, Courtroom C, Charleston, West Virginia.

If you want to keep your rights as a parent of the children listed above you should attend this hearing. An attorney has been appointed by the Court to represent you if you attend the hearing. IF YOU DO NOT SHOW UP FOR THE HEARING, you may lose all rights to see, visit or claim kinship to this child.

August 6, 2015Amy Paxton
Assistant Prosecuting
Attorney
(606952)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

46.NOTICE OF LOST
CERTIFICATE

To whom it may concern:
Take notice that the undersigned, being the owner of Stock Certificate No. C-2762 of Kenna Homes Cooperative Corporation having mislaid, lost or misplaced the same, has made application to Kenna Homes Cooperative Corporation for a duplicate stock certificate to replace the one lost.
Dated this 14th day of July, 2015.
Brian Slaman(604787)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

47.NOTICE OF
OPEN MEETING –
CHARLESTON AREA
MEDICAL CENTER, INC.
BOARD OF TRUSTEES
QUALITY COMMITTEE
Notice is hereby given that the Quality Committee of the Board of Trustees of Charleston Area Medical Center Inc. (“CAMC”) will hold a regular meeting at 7:30 a.m. on Thursday, August 13, 2015, in the corporate boardroom of CAMC General Hospital, 501 Morris St., Charleston, West Virginia. Members of the public wishing to address the committee must sign up no later than 7:15 a.m. the day of the meeting.(605422)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

48.NOTICE OF
OPEN MEETING –
CHARLESTON AREA
MEDICAL CENTER, INC.
MEDICAL STAFF
EXECUTIVE COMMITTEE
Notice is hereby given that the Medical Staff Executive Committee of Charleston Area Medical Center Inc. (“CAMC”) will hold a regular meeting at 5:30 p.m. on Thursday, August 13, 2015, in the corporate boardroom of CAMC General Hospital, 501 Morris St., Charleston, West Virginia. (605424)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

49.NOTICE OF
SUCCESSOR
TRUSTEE’S SALE
Notice is hereby given, by virtue of the authority vested in the undersigned Successor Trustees, James W. Lane, Jr. and Bradford P. Bury, by that certain Deed of Trust made by Jerry O. Akers and Valerie Akers, dated August 10, 1999 and recorded August 19, 1999 in the office of the Clerk of the County Commission of Kanawha County, West Virginia in Trust Deed Book 2568 at page 1, the said Successor Trustees acting by virtue of that certain Appointment of Successor Trustee dated July 22, 2015 and recorded July 28, 2015 in the aforesaid Clerk’s office in Trust Deed Book 4114, at page 916, and default having been made in the payment of the Note secured by the aforesaid Deed of Trust, and having been requested in writing by the owner and holder of the Note, will offer for sale, at public auction, to the highest bidder at the front door of the Courthouse of Kanawha County, West Virginia, on Tuesday, September 8, 2015 at 9:30 a.m.,

All of that certain piece or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the Town of Chesapeake, Chesapeake Tax District (formerly Loudon District), Kanawha County, West Virginia, and being more particularly designated and described as all of Parcel “B” of the Resubdivision of Lots 4 and 5, Block “J” in the Town of Chesapeake, as shown upon a map thereof entitled, “Resubdivision Lots 4 & 5 Block J, Town of Chesapeake, Loudon District, Kanawha Co., W.Va.”, dated March, 1949, of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 935, at page 374.

And being the same property that was conveyed unto Jerry O. Akers and Valerie S. Akers, his wife, by deed dated October 31, 1996, from Robin L. Nelson, formerly known as Robin L. Lloyd, of record in the aforesaid Clerk’s Office in Deed Book 2398, at page 582.

At the time of execution of the deed of trust, the grantor represented that the address of the property was 115 126th Street, Chesapeake, WV 25315.

TERMS OF SALE: The Premises will be sold “AS IS, WHERE IS,” in its present condition and with all faults and defects, if any. The Premises will be conveyed by deed with no covenants of warranty of title. The Premises shall be sold subject to all liens not discharged by the sale, including, without limitation, liens for real estate taxes, incinerator, sanitary and sewer charges and liens with priority to the Deed of Trust pursuant to which this sale is being conducted. The Premises shall be sold subject to all covenants, restrictions, easements, rights of way and reservations which may be a matter of record in the aforesaid Clerk’s office or visible upon the ground. The Premises will be sold for cash in hand on the date of sale to the highest bidder. The purchasers at the sale shall be responsible for paying the recording costs and also the tax on the privilege of transferring real property (the cost of the tax stamps to be affixed to the deed). The Successor Trustees and City National Bank of West Virginia shall not be responsible for the removal of any person or personal property from the Premises.

Pursuant to the Deed of Trust, the Successor Trustees may postpone the sale by public announcement at the time and place designated and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the Premises at such sale.

Dated: __________________James W. Lane, Jr., Esq.
Bradford P. Bury, Esq.,
M.B.A.
Successor Trustees
200 Capitol Street
P.O. Box 3843
Charleston, WV 25338
(304) 205-6373
(606949)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

50.NOTICE OF TRUSTEE
SALE OF VALUABLE
REAL ESTATE
Pursuant to the authority vested in the undersigned by deed of trust dated the 11th day of January 2002, signed by James Jones and Joyce Jones, to Mitchell Lee Klein, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 2797, at page 80, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor and present holder of the note, said Trustee will sell at public auction at 10:45 o’clock A.M. on the 18th day of
AUGUST 2015
at the front doors of the Courthouse in Kanawha County in Charleston, West Virginia the following described real estate in Malden District, on the waters of Campbell Creek, Kanawha County, State of West Virginia, to wit:

All that certain parcel of land together with the improvements thereon and the appurtenances belonging to, beginning at a corner of Jess Wills’ lot, Station 24, located on the south side of Station Avenue, Coal Ford and 30 feet from the center line of the Cambells Creek Railroad; thence with the line of Jess Wills and leaving Station Avenue S. 32 degrees 30 minutes east 127.20 feet to a stale at Station 28, Corner to Jess Wills; thence leaving Jess Wills’ lot S 55 degree, 10 minutes west 80.0 feet to a stake at Station 39A corner common with Charles Frazier; thence with a common line with Frazier N. 32 degrees 3 minutes west 127.32 feet to an iron pin, Station 39 on the South side of Station Avenue; common corner with Frazier; thence leaving Frazier and running with Station Avenue N. 59 degrees 10 minutes East 80.0 feet to the beginning, containing 0.238 acres, as shown, laid down and designated upon a map by P.O. Hamer, dated March 7, 1950, attached and made part of deed recorded in aforesaid Clerk’s Office in Deed Book 2283, at Page 65.

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:
480 Staton Drive,
Charleston,
West Virginia 25306
TERMS OF SALE: Cash in hand on day of sale or within 30 days of date of sale upon terms to be agreed upon between Trustee and successful bidder, time being of the essence; payment for unpaid real estate taxes to be assumed by the purchaser. The Trustee does not warrant title or fitness to this property; it is being purchased as is; this is a buyer beware sale and any buyer is advised to retain counsel before the sale. If there is any part of the process of sale which is found to be objectionable, the Trustee reserves the right to cancel the sale. No purchaser should take possession or make improvements in the premises until the Trustee deed is delivered or recorded. A third party purchaser at sale will be required to pay the purchase price plus all recording and transfer fees.

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

FEDERAL TAX LIEN: In the event that there are Federal Tax Liens against the property, the United States would have the right to redeem the property within a period of 120 days from the date of such sale or the period allowable for redemption under local law, whichever is longer.

The party(ies) secured by the Deed of Trust reserve the right to purchase the property at such sale. If the purchaser at sale is unable to complete the terms of purchase within 30 days, the Trustee reserves the right to transfer the property to the next highest bidder.

Any sale hereunder may be adjourned from time to time without any notice other than oral proclamation at the time and place appointed for this sale or by posting of a notice of same. Should the Trustee not appear at the time appointed for the sale and there is no notice posted of a continuance please contact the office of the Trustee to make further inquiry. Any sale may be conducted or adjourned by the designated agent or attorney of the Trustee. The undersigned is fully vested with the authority to sell said property as Trustee by instrument of record.

Should any party have any inquires, objections to the sale or protests regarding the sale, or requests regarding the sale, please notify the trustee below by one of the means of communications set forth below.GOLDEN & AMOS, PLLC,
TRUSTEE
543 Fifth Street,
P.O. Box 81
Parkersburg, WV 26102
Telephone (304) 485 3851
Fax (304) 485-0261
E-mail:
[email protected]

Lender: Green Tree
Processor: Victor / Ext. 12
JonesJoyce NTS / cclem
/ foreclosure notices – 2015

(606071)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

51.NOTICE OF TRUSTEE SALE
OF VALUABLE REAL ESTATE
Pursuant to the authority vested in the undersigned by deed of trust dated the 12th day of January, 2010, signed by Jon C. Keeney and Stacey A. Keeney, husband and wife, to Advantage Title Company, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 3701, at page 814, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor and present holder of the note, said Trustee will sell at public auction at 10:45 o’clock, a.m. on the 18TH DAY OF AUGUST 2015
at the front doors of the Courthouse in Kanawha County in Charleston West Virginia the following described real estate:

All that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate on the waters of the right hand fork of Kanawha Two-Mile Creek in Union District, Kanawha County, West Virginia, and being more particularly bounded and described as follows:

BEGINNING at a one inch diameter steel pin found, said pin being Oral Taylor, see deed in Deed Book 2399 Page 516, 22.6 acres southwesterly corner and said pin being in County Route 27-Edens Fork Road northerly right of way; thence leaving County Route 27-Edens Fork Road northerly right of way and running with Oral Taylor westerly line for the next ten calls N 09 degrees 43′ E 82.16 feet to a 5/8 inch diameter steel reinforcing bar (#5 rebar) set, N 09 degrees 43′ E 76.15 feet to a #5 rebar set, N 09 degrees 43′ E 64.75 feet to a 30 inch poplar, N 07 degrees 26′ W 206.23 feet to a #5 rebar set, N 07 degrees 26′ W 137.02 feet to 31 inch maple, N 07 degrees 26′ W 211.11 feet to a #5 rebar set, N 07 degrees 26′ W 300.04 feet to a 48 inch red oak, N 41 degrees 00′ E 337.00 feet to a #5 rebar set, N 40 degrees 45′ E 298.22 feet to a #5 rebar set and N 40 degrees 45′ E 215.78 feet to a #5 rebar set, said #5 being in a high pressure natural gas line right of way, and said #5 rebar being Oral Taylor northwesterly corner and in Jessie Guthrie, see Deed Book 1937, page 478, 52.5 acres southerly line; thence leaving Oral Taylor and running with Jessie Guthrie southerly line for the next two calls S 88 degrees 00′ W 124.00 feet to a #5 rebar set and S 78 degrees 08′ W approximately 242 feet (by scale) to a point, said point being Jessie Guthrie southwesterly corner and Jerry Vorholt see deed in Deed Book 2588, page 395, 33.14 acres southeasterly corner; thence leaving Jessie Guthrie and running with Jerry Vorholt southerly line for the next three calls S 78 degrees 08′ W 440.06 feet to a #5 rebar set, S 78 degrees 08′ W 452.50 feet to a #5 rebar set and S 78 degrees 08′ W 88.24 feet to a #5 rebar set, said #5 rebar being in J.F. Casdorph, see deed in Deed Book 1278, page 486, 86.5 acres northeasterly corner; thence leaving Jerry Vorholt and running with J.F. Casdorph for the next two calls S 17 degrees 30′ E 157.10 feet to a #5 rebar set and S 17 degrees 30′ E 277.90 feet to a ¾ inch diameter pipe found, said ¾ inch diameter pipe found being Joseph P. Fleck, see deed in Deed Book 2046, page 447, 4.53 acres northwesterly corner; thence leaving J.F. Casdorph and running with Joseph P. Fleck northerly and easterly lines for the next five calls N 55 degrees 52′ E 164.06 feet to a ¾ inch diameter pipe found S 20 degrees 00′ E 266.00 feet to a roof bolt found, S 20 degrees 00′ E 534.30 feet to a roof bolt found and S 20 degrees 00′ E 229.57 feet to a #4 rebar found, S 20 degrees 38′ E 181.35 feet to a roof bolt found, said roof bolt being Joseph P. Fleck southeasterly corner and being in County Route 27-Edens Fork Road northerly right of way; thence leaving Joseph P. Fleck and running with County Route 27-Edens Fork Road northerly right of way N 88 degrees 00′ E 154.08 feet to the place of beginning, being all of 19.57 acres and designated as parcel equaling 19.57 acres on that certain plat attached hereto entitled “Plat Showing Survey of a Parcel having 19.57 acres, fronting on County Route 27-Edens Fork Road, situate in Union District, Kanawha County, West Virginia” prepared by Michael E. Mayes, LLS, dated April 8, 2006, Scale 1″=100′.

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:
3123 Edens Fork Road,
Charleston, West Virginia 25312
TERMS OF SALE: Cash in hand on day of sale or within 30 days of date of sale upon terms to be agreed upon between Trustee and successful bidder, time being of the essence; payment for unpaid real estate taxes to be assumed by the purchaser. The Trustee does not warrant title or fitness to this property; it is being purchased as is; this is a buyer beware sale and any buyer is advised to retain counsel before the sale. If there is any part of the process of sale which is found to be objectionable, the Trustee reserves the right to cancel the sale. No purchaser should take possession or make improvements in the premises until the Trustee deed is delivered or recorded. A third party purchaser at sale will be required to pay the purchase price plus all recording and transfer fees.

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

FEDERAL TAX LIEN: In the event that there are Federal Tax Liens against the property, the United States would have the right to redeem the property within a period of 120 days from the date of such sale or the period allowable for redemption under local law, whichever is longer.

The party(ies) secured by the Deed of Trust reserve the right to purchase the property at such sale. If the purchaser at sale is unable to complete the terms of purchase within 30 days, the Trustee reserves the right to transfer the property to the next highest bidder.

Any sale hereunder may be adjourned from time to time without any notice other than oral proclamation at the time and place appointed for this sale or by posting of a notice of same. Should the Trustee not appear at the time appointed for the sale and there is no notice posted of a continuance please contact the office of the Trustee to make further inquiry. Any sale may be conducted or adjourned by the designated agent or attorney of the Trustee. The undersigned is fully vested with the authority to sell said property as Trustee by instrument of record.

Should any party have any inquires, objections to the sale or protests regarding the sale, or requests regarding the sale, please notify the trustee below by one of the means of communications set forth below.
GOLDEN & AMOS, PLLC, TRUSTEE
543 Fifth Street, P.O. Box 81
Parkersburg, WV 26102
Telephone (304) 485 3851
Fax (304) 485-0261
E-mail: [email protected]

Lender: Bank of America
Processor: Kristi/Ext. 27
(KeeneyJon.nts/mbaker/finishedforeclosure2015)

(605900)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

52.NOTICE OF TRUSTEE SALE
OF VALUABLE REAL ESTATE
Pursuant to the authority vested in the undersigned by deed of trust dated the 26th day of May 1998, signed by Katherine J. Workman, single, to Otis L. O’Conner, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 2544, at page 563, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor and present holder of the note, said Trustee will sell at public auction at 10:45 a.m. on the 18th day of AUGUST 2015
at the front doors of the Courthouse in Kanawha County in Charleston, West Virginia the following described real estate:

All that certain tract or parcel of land, together with improvements thereon and the appurtenances thereunto belonging, situate in the City of South Charleston, in Loudon District, Kanawha County, West Virginia, fronting fifty five (55) feet on the southerly side of Rosemont Avenue and extending back to and abutting on Forest Avenue, being all of Lot No. 158 of the L.C. Massey Subdivision of Montrose, South Charleston, Kanawha County, West Virginia, as laid down and shown on the map of same of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Map Book 2 at page 72, and more particularly bounded and described as follows: BEGINNING at a stake in the southerly line of Rosemont Avenue, common corner between Lots No. 156 and Lot No. 158 of the L.C. Massey Subdivision of Montrose, as shown upon the map aforesaid; thence leaving said Rosemont Avenue and with the common lines between said Lot No. 156 and Lot No. 158, S. 2 degrees 00′ W. 159.4 feet to an old iron pin in the northerly line of Forest Avenue; thence with the northerly line of Forest Avenue, N. 81 degrees 30′ W. 39.4 feet to a point in the easterly line of a ten foot alley; thence with said line of said alley, N. 4 degrees 30′ W. 149 feet to a point at the intersection of the easterly line of said alley with the southerly line of Rosemont Avenue; thence with the southerly line of Rosemont Avenue, N. 85 degrees 30′ E. 55 feet to the beginning.

This conveyance is subject to the exception and reservation from the above described property of a strip of land approximately three (3) feet wide off of the westerly side of the property hereby conveyed, which said strip of land is more particularly bounded and described as follows: BEGINNING at the intersection of the southerly line of Rosemont Avenue with the easterly line of a ten foot alley, also being the northwest corner of said Lot 158, and running thence with the southerly line of Rosemont Avenue, N. 85 degrees 30′ E. 3.0 feet to a stake in said line; thence running through said Lot 158, S. 4 degrees 30′ E. 149.69 feet, more or less, to a stake in the northerly line of Forest Avenue; thence with the northerly line of Forest Avenue, N. 81 degrees 30′ W. 3.08 feet to a point where the northerly line of Forest Avenue intersects the easterly line of said ten foot alley; thence with the easterly line of said ten foot alley N. 4 degrees 30′ W. 149 feet to the place of beginning.

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:
122 Rosemont Avenue,
South Charleston, West Virginia 25303
TERMS OF SALE: Cash in hand on day of sale or within 30 days of date of sale upon terms to be agreed upon between Trustee and successful bidder, time being of the essence; payment for unpaid real estate taxes to be assumed by the purchaser. The Trustee does not warrant title or fitness to this property; it is being purchased as is; this is a buyer beware sale and any buyer is advised to retain counsel before the sale. If there is any part of the process of sale which is found to be objectionable, the Trustee reserves the right to cancel the sale. No purchaser should take possession or make improvements in the premises until the Trustee deed is delivered or recorded. A third party purchaser at sale will be required to pay the purchase price plus all recording and transfer fees.

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

FEDERAL TAX LIEN: In the event that there are Federal Tax Liens against the property, the United States would have the right to redeem the property within a period of 120 days from the date of such sale or the period allowable for redemption under local law, whichever is longer.

The party(ies) secured by the Deed of Trust reserve the right to purchase the property at such sale. If the purchaser at sale is unable to complete the terms of purchase within 30 days, the Trustee reserves the right to transfer the property to the next highest bidder.

Any sale hereunder may be adjourned from time to time without any notice other than oral proclamation at the time and place appointed for this sale or by posting of a notice of same. Should the Trustee not appear at the time appointed for the sale and there is no notice posted of a continuance please contact the office of the Trustee to make further inquiry. Any sale may be conducted or adjourned by the designated agent or attorney of the Trustee. The undersigned is fully vested with the authority to sell said property as Trustee by instrument of record.

Should any party have any inquires, objections to the sale or protests regarding the sale, or requests regarding the sale, please notify the trustee below by one of the means of communications set forth below.GOLDEN & AMOS, PLLC, TRUSTEE
543 Fifth Street, P.O. Box 81
Parkersburg, WV 26102
Telephone (304) 485 3851
Fax (304) 485-0261
E-mail: [email protected]

Lender: Green Tree
Processor: Victor / Ext. 12
WorkmanKatherine NTS / cclem / foreclosure notices – 2015

(606070)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

53.NOTICE OF TRUSTEE’S SALE
NOTICE IS HEREBY GIVEN that by virtue of a certain Deed of Trust (the “Deed of Trust”) dated April 19, 2011, made by Robert Siwo, to R. Bruce White, Trustee, of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book No. 3791, at page 628, to secure WesBanco Bank, Inc. in the payment of the sum of $78,400.00, evidenced by a negotiable promissory note bearing even date therewith, and WesBanco Bank, Inc. being authorized and empowered to designate and appoint one or more substitute trustees in the place and stead of the trustee named in the Deed of Trust and the undersigned, Christopher R. Arthur and/or James H. Adkins, were so appointed by the terms of a Designation of Substitute Trustee of record in said Clerk’s office, and default having been made in the payment of said indebtedness and said Substitute Trustees having been requested in writing so to do by WesBanco Bank, Inc. owner and holder of said note, said Substitute Trustees, onTUESDAY, SEPTEMBER 1, 2015
AT 10:45 A.M. EASTERN TIME
will offer for sale and sell at public auction at the Kanawha County Courthouse, Charleston, West Virginia to the highest bidder therefore, which is comprised of all of his right, title and interest, in and to being all those certain lots and parcels of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the City of Charleston, Kanawha County, West Virginia, more particularly described as follows:

PARCEL NO. 1:

Being all that certain lot or parcel of real estate, together with the improvements thereon and the appurtenances thereunto belonging, situate and being in the City of Charleston, Charleston West District, Kanawha County, West Virginia, being described as follows: with the tax account number 06596524, and being more fully described in a deed dated 6/25/74, and recorded 5/16/78, among the land records of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 1866, at page 544.

The surface only of all of that certain lot or parcel of real estate, together with the improvements thereon and the appurtenances thereunto belonging, situate and being in the City of Charleston, Kanawha County, West Virginia and being known, numbered and designated on a map or plat entitled “Beechwood Addition To The City of Charleston, W.Va.,” made by Cavendish and Given, Engineers, dated May 1906 and of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia in Deed Book 104, at page 198.

And being the same property conveyed to Robert Siwo from C. Douglas Stewart and Patricia C. Stewart, by deed dated April 19, 2014, of record in the Office of the Clerk of the County Commission, Kanawha County, West Virginia in Deed Book 2815, at page 588.

PARCEL NO. 2:

Being all that certain lot, tract or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the City of Charleston, Kanawha County, West Virginia, more particularly bounded and described as follows: Beginning at an iron pin corner in the northerly line of Delaware Avenue, located a distance of 1.4 feet south of the front common corner of Lots Nos. 6 and 7 of Block 43 of Glenwood Addition of West Charleston; thence running with the line of Delaware Avenue, N. 31û 30′ E. 40 feet to an iron pin in the front line of Lot No. 8 of Block 43; thence leaving Delaware Avenue and running across said Lot No. 8 of Block 43, S. 58û 30′ W. 126 feet to an iron pin in the rear line of said Lot No. 8 of Block 43; thence with the rear lines of Lots Nos. 8,7 and 6 of Block 43, S. 31û 30′ W. 40 feet to an iron pin in the rear line of Lot No. 6 of Block 43, which iron pin is located a distance of 1.4 feet sound of the common rear corner of said Lots Nos. 6 and 7 of Block 43; thence running across said Lot No. 6 of Block 43, N. 58û 30′ W. 126 feet to the point of beginning; and being all of Lot No. 7 and parts of Lots 6 and 8 of Block 43 of Glenwood Addition to West Charleston, as shown upon a map showing a recent survey of the lot hereby conveyed, made by J. Lewis Hark, R.P.E., dated December 24, 1949, of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia in Deed Book 1264, at page 446; and being the same property conveyed to Robert Siwo from Fannie Mae (aka Federal National Mortgage Association, a corporation organized and existing under the laws of the United States, by deed dated March 30, 2009, and of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia in Deed Book 2744, at page 470.

The sale of said property will be made subject to all exceptions, encumbrances, reservations, rights of way, easements, conditions, covenants, restrictions, leases and other servitudes of record, if any, pertaining to said real estate, and any and all unpaid taxes assessed against said property.

Joe R. Pyle Auction Service will assist with the sale. Any sale hereunder may be adjourned from time to time without notice other than oral proclamation at the time and place appointed for the sale. The Trustees reserve the right to reject any or all bids. Conveyance shall be by special warranty deed, and purchaser shall pay for all transfer stamps, recording fees, and other closing costs.

TERMS OF SALE: Ten percent (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the sales price shall be paid by cash, cashier’s check, or check guaranteed by bank letter of credit in acceptable form, in hand on the day of sale (the “Good Faith Deposit”), with the balance to be paid in cash at closing within 30 days after the date of sale. Additional terms and conditions shall be announced at the sale.

At public sale any person or entity may bid and may purchase any real estate sold if they be the highest bidder. If the real estate is sold for an amount in excess of the outstanding balance of the mortgage, together with all interest, unpaid real estate taxes and costs, said excess must be used to satisfy any other encumbrances on said property and after all said encumbrances are satisfied together with all interest and costs, any excess then remaining must be paid to the Grantor. If the Grantor or any person holding an encumbrance cannot be found after a diligent search, the money shall be paid into the Circuit Court of the county for the benefit of the Grantor or the holder of any such encumbrance.

Dated: July 28, 2015.
James H. Adkins, as Substitute Trustee
Steptoe & Johnson PLLC
P. O. Box 1588
Charleston, WV 25326
(606067)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

54.NOTICE OF
TRUSTEE’S SALE
NOTICE IS HEREBY GIVEN that by virtue of a certain deed of trust (the “Deed of Trust”) dated July 24, 2012 made by London Mart, LLC to John Dorsey, Trustee, of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book No. 3887, at page 925 to secure WesBanco Bank, Inc., (“WesBanco”) in the payment of the sum of $21,600.00, evidenced by a promissory note bearing even date therewith, and WesBanco being authorized and empowered to designate and appoint one or more substitute trustees in the place and stead of the trustee named in the Deed of Trust and the undersigned, Christopher R. Arthur and/or James H. Adkins (the “Substitute Trustees”), were so appointed by the terms of a Designation of Substitute Trustee of record in said Clerk’s office, and default having been made in the payment of said indebtedness and said Substitute Trustees having been requested in writing so to do by WesBanco, owner and holder of said note, said Substitute Trustees, onTUESDAY,
SEPTEMBER 1, 2015
AT 10:30 A .M.
EASTERN TIME
will offer for sale and sell at public auction at the front door of the Kanawha County Courthouse, 409 Virginia Street East, Charleston, West Virginia, to the highest bidder therefore, which is comprised of all of their right, title and interest, in and to all of that certain lot, tract or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Cabin Creek District, Kanawha County, West Virginia, and more particularly designated and described as:

All of the residual of Lots Nos. 2 and 3, Saunders Addition, London, West Virginia, after that certain out-conveyance to West Virginia Road Commission of West Virginia, a corporation, under date of the 19th day of July, 1940, as same are set out on that certain map of lots laid off for R.G. Saunders under date of the 25th day of October, 1983, and re-issued by map of C. B. Holsclaw, Engineer, under date of the 15th day of November, 1934, and further shown on a map of “Parts of Lots 2 and 3, R.G. Saunders, Hughes Creek, London, West Virginia” by Ralph Adkins, Land Surveyor, November 29, 1985;

Map No. 35A
Parcel No.: 134;

and being the same property conveyed to London Mart, LLC, a West Virginia limited liability company, from Community Trust Bank, Inc., a Kentucky banking corporation, by deed dated July 2, 2012 and recorded in the Office of the Clerk of the County Commission of Kanawha County in Deed Book 2828, at page 442.

The sale of said property will be made subject to all exceptions, encumbrances, reservations, rights of way, easements, conditions, covenants, restrictions, leases and other servitudes of record, if any, pertaining to said real estate, and any and all unpaid taxes assessed against said property.

Any sale hereunder may be adjourned from time to time without notice other than oral proclamation at the time and place appointed for the sale. The Substitute Trustees reserve the right to reject any or all bids. Conveyance shall be by special warranty deed, and purchaser shall pay for all transfer stamps, recording fees, and other closing costs.

TERMS OF SALE: Ten percent (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the sales price shall be paid by cash, cashier’s check, or check guaranteed by bank letter of credit in acceptable form, in hand on the day of sale (the “Good Faith Deposit”), with the balance to be paid in cash at closing within 30 days after the date of sale. Additional terms and conditions shall be announced at the sale.

At public sale any person or entity may bid and may purchase any real estate sold if they be the highest bidder. If the real estate is sold for an amount in excess of the outstanding balance of the mortgage, together with all interest, unpaid real estate taxes and costs, said excess must be used to satisfy any other encumbrances on said property and after all said encumbrances are satisfied together with all interest and costs, any excess then remaining must be paid to the Grantor. If the Grantor or any person holding an encumbrance cannot be found after a diligent search, the money shall be paid into the Circuit Court of the county for the benefit of the Grantor or the holder of any such encumbrance.

Dated: July 28, 2015.
James H. Adkins,
as Substitute Trustee
Steptoe & Johnson PLLC
P. O. Box 1588
Charleston, WV 25326
(606068)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

55.NOTICE OF
TRUSTEE’S SALE
Notice is hereby given that by virtue of the authority under that certain deed of trust executed by Thomas R. Lloyd, Jr., to M. Glenn Turley and Susan L. Petrella, Trustee(s) dated October 5, 2007, and recorded in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 3509, at page 350, by which was conveyed to said Trustee(s) the hereinafter described real estate to secure the payment of a certain promissory note set out and described therein, and default having been made in the payment of said note, the undersigned Substitute Trustee(s) having been appointed Substitute Trustee by an Appointment of Substitute Trustee dated July 10, 2015, and having been requested in writing by the holder of said note, will sell to the highest and best bidder on August 26, 2015 at 5:30 p.m., at the front door of the courthouse of Kanawha County, West Virginia, the real estate conveyed by said deed of trust and situate in the City of South Charleston, Kanawha County, West Virginia, together with easements, improvements and appurtenances thereunto belonging, and at the time of the signing of the Deed of Trust it was reported that the address was: 1224 Ridge Drive, South Charleston, West Virginia, and being more particularly bounded and described therein as follows:

All of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the City of South Charleston, Kanawha County, West Virginia and being all of Lot Eighteen (18) as shown on the “Revised Map Showing Ridgewood Section, Rock Lake Village, South Charleston, Kanawha County, West Virginia,” dated June, 1955, and of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia in Map Book 17, at pages 116 and 117.

Being the same property conveyed to United Bank, Inc., from J. Nicholas Barth, Successor Trustee, by deed dated July 25, 2007 of record in the aforesaid Clerk’s office in Deed Book 2696, at page 595. Also being the same property conveyed to Thomas R. Lloyd, Jr. from United Bank, Inc. by deed dated October 2, 2007, recorded in the afore said Clerk’s office in Deed Book 2700, at page 439, to which map and deed reference is here made for a more particular description of the property herein conveyed and conveyed to Thomas R. Lloyd Jr. and Ashley L. Stephenson by deed dated October 16, 2007, from Thomas R. Lloyd Jr, recorded in the aforesaid Clerk’s office in Deed Book 2701, at page 63.

This conveyance is made subject to such rights of way, easements, restrictions, covenants, conditions and reservations as may be found in prior deeds of record in the chain of title.

This sale is made subject to any special assessments, unpaid taxes, easements, conditions, reservations and restrictions affecting the aforesaid real estate.

The property will be conveyed in an “AS IS” condition by Deed containing no warranty, express or implied, subject to all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights of ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

Pursuant to the terms of said deed of trust, the Substitute Trustee(s) may postpone the sale by public announcement at the time and place designated for the sale. The West Virginia Housing Development Fund or its designee may purchase the property at any sale.

The Substitute Trustees shall be under no duty to cause any existing tenant or person occupying the property to vacate said property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

TERMS OF SALE: Cash in hand on day of sale.

DATED this 5th day of August, 2015.
Pill & Pill, PLLC,
Substitute Trustee

BY:Richard A. Pill,
Member
304-263-4971
[email protected]
(606802)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

56.NOTICE OF
TRUSTEE’S SALE
NOTICE OF TRUSTEE’S SALE is hereby given pursuant to and by virtue of the authority vested in the Substitute Trustee, Pill & Pill, PLLC, by that certain Deed of Trust dated December 17, 2009, executed by Borrowers Ben D. Griffith, Sr. and Wilda L. Griffith, to Vance Golden, the Trustee of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3696, at Page 74. At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 617A Vorpe Road, Saint Albans, WV 25177. Pill & Pill, PLLC was appointed as Substitute Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated April 10, 2015, of record in the Clerk’s Office in Book 4107, Page 79. The borrowers defaulted under the Note and Deed of Trust and the Substitute Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Substitute Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on the following date:August 26, 2015
at 5:36 p.m.
The property is described as of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Jefferson District, Kanawha County, West Virginia, and being more particularly described as follows:

All that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Jefferson District, Kanawha County, West Virginia, being part of Lot “C” of the partition of the Elizabeth Griffith Estate, more particularly bounded and described as follows:

BEGINNING at a 1/2″ rebar set corner to the Griffith tract recorded in Deed Book 2291, page 505 and the Griffith tract recorded in Deed Book 1399, at page 579, and in easterly line of Vorpe Road (WV Route 3/4); thence with said Vorpe Road for two (2) calls 1) N. 00° 04′ E. 45.52 feet to a point; 2) N. 07° 52′ E. 176.60 feet to a 3/8 rebar set; thence leaving said Vorpe Road and running through the Griffith tract recorded in Deed Book 1399, at page 579, and from which this tract is a part of four (4) calls; 1) S. 72° 39′ E. 99.37 feet to a 6 inch gate post; 2) N. 23° 57′ E. 19.87 feet to a 10 inch walnut at head of drain; 3) S. 64° 48′ E. 58.23 feet to a point in said drain; 4) S. 07° 52′ W. 233.11 feet to a point in the line of the two said Griffith tracts; thence with said Griffith tract N. 73° 32′ W. 154.23 feet to the place of beginning, containing 0.83 acre, more or less.

And being a part of the same property conveyed unto Ben D. Griffith by Lorimer D. Griffith, et als., by deed dated December 11, 1963, of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 1399, at page 579. Reference is also made to that certain deed to said Ben D. Griffith and Wilda Lee Griffith, his wife, by Delafield Griffith and Mary D. Griffith, his wife, by deed dated April 3, 1954, of record in the aforesaid Clerk’s Office in Deed Book 1114, at page 81, for all pertinent and relevant purposes; and being also the same property conveyed unto Ben D. Griffith and Wilda Lee Griffith by Ben D. Griffith by deed dated June 30, 2009, of record in the aforesaid Clerk’s Office in Deed Book 2749, at page 365.

There is reserved from the above described tract a 30.00 foot right of way for ingress and egress and for utilities for the remaining acreage on the Griffith tract recorded in Deed Book 1399, at page 579, along the existing road leading from Vorpe Road and being located along and near the northerly line of the above described tract.

This conveyance is made subject to any and all covenants, restrictions, and easements as the same may appear in instruments of record in the aforesaid Clerk’s Office.TERMS OF SALE:
1)The property will be conveyed in an “AS IS” physical condition by Deed containing no warranty, express or implied, subject to the Internal Revenue Service right of redemption, all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights-of-ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-1.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

5)The Trustee shall be under no duty to cause any existing tenant or person occupying the property to vacate said property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

6)The total purchase price is payable to the Trustee within thirty (30) days of the date of sale, with ten (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total purchase price payable to the Trustee at sale.Pill & Pill, PLLC,
Substitute Trustee

BY:______________________
Pill & Pill, PLLC
85 Aikens Center
Edwin Miller Boulevard
P.O. Box 440
Martinsburg, WV 25402
(304) 263-4971
foreclosures@
pillwvlaw.com
(606696)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

57.NOTICE OF
TRUSTEE’S SALE
NOTICE OF TRUSTEE’S SALE is hereby given pursuant to and by virtue of the authority vested in the Substitute Trustee, Pill & Pill, PLLC, by that certain Deed of Trust dated January 27, 2005, executed by Borrowers Matthew S. Shamblin and Tara R. Shamblin, to Turley Law Office, the Trustee of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3213, at Page 6. At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 1106 Wilkie Dr, Charleston, WV 25314. Pill & Pill, PLLC was appointed as Substitute Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated June 5, 2015, of record in the Clerk’s Office in Book 4108, Page 602. The borrowers defaulted under the Note and Deed of Trust and the Substitute Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Substitute Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on the following date:August 26, 2015
at 5:38 p.m.
The property is described as of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Loudon District, Kanawha County, West Virginia, and being more particularly described as follows:

All that certain lot, piece or parcel of land, situate in Loudon District, Kanawha County, West Virginia, being known and designated as all that certain part of Lot One Hundred Seventy-two (172), of Forest Hills, Section Five Addition to the City of Charleston, as laid down and shown upon the map hereof, made by E. H. Venable, E. 6., dated August, 1947, of record in the office of the Cleric of the County Commission of Kanawha County, West Virginia, in Photostatic Map Book 14, at page 37, and more particularly bounded and described as follows:

BEGINNING at an iron pin on the south side of Wilkie Drive, a common corner of Lots Nos. 171 and 172; thence running with the south side, of said Drive with a curve having a radius of 321.6 feet and a chord bearing N. 82° 54′ E. 52.0 feet to an iron pin, corner to Lot No. 173; thence running with the common dividing line between Lots Nos. 172 and 173, S., 11° 28′ E. 120.0 feet to an iron pin; thence running across the rear of Lot No. 172 N. 88° 56′ W. 70.2 feet to an iron pin in the common dividing line between Lots Nos. 171 and 172; thence with said common dividing line N. 2° 44′ W. 110.0 feet to the place of beginning.

And being the same property conveyed to Thomas Gregory Wegmann from Ella Mae Coleman and Charles F. Coleman, her husband and George W. Nichols and Wanda L. Nichols, his, wife, by deed dated December 2, 1992 of record in the aforesaid Clerk’s office in Deed Book 2306, at page 654. And also being the same property conveyed to Mathew S. Shamblin and Tara R. Shamblin, husband and wife, from Thomas Gregory Wegmann by deed dated January 7, 2005, to be recorded concurrently, to which map and deed reference is here made for a more particular description of the property herein conveyed.

This conveyance is made subject to such rights of way, easements, restrictions, covenants, conditions and reservations as may be found in prior deeds of record in the chain of title.

Being the same property conveyed to Matthew S. Shamblin by the Deed dated June 6, 2012 and recorded in Deed Book 2837, at Page 315 in the Office of the Clerk of the County Commission of Kanawha County, West Virginia.TERMS OF SALE:
1)The property will be conveyed in an “AS IS” physical condition by Deed containing no warranty, express or implied, subject to the Internal Revenue Service right of redemption, all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights-of-ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-1.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

5)The Trustee shall be under no duty to cause any existing tenant or person occupying the property to vacate said property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

6)The total purchase price is payable to the Trustee within thirty (30) days of the date of sale, with ten (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total purchase price payable to the Trustee at sale.Pill & Pill, PLLC,
Substitute Trustee

BY:_
Pill & Pill, PLLC
85 Aikens Center
Edwin Miller Boulevard
P.O. Box 440
Martinsburg, WV 25402
(304) 263-4971
[email protected]
(606792)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

58.NOTICE OF
TRUSTEE’S SALE
NOTICE OF TRUSTEE’S SALE is hereby given pursuant to and by virtue of the authority vested in the Substitute Trustee, Pill & Pill, PLLC, by that certain Deed of Trust dated March 19, 2008, executed by Borrower Jack E. Smith, to Philip Hereford, the Trustee of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3550, at Page 940. At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 2317 Jefferson Ave, St Albans, WV 25177. Pill & Pill, PLLC was appointed as Substitute Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated June 18, 2015, of record in the Clerk’s Office in Book 4112, Page 406. The borrower defaulted under the Note and Deed of Trust and the Substitute Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Substitute Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on the following date:August 26, 2015
at 5:40 p.m.
The property is described as of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in St. Albans District, Kanawha County, West Virginia, and being more particularly described as follows:

Situate in the City of St. Albans Tax District, (formerly Jefferson Tax District), Kanawha County, West Virginia, and being the easterly 32 feet of Lot No. Nine (9) and the adjoining westerly 20 feet of Lot No. Ten (10), Block U, Highlawn Addition to St. Albans, Section One (1), shown on a map duly of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Map Book 2 at page 95, and more particularly described as follows:

BEGINNING at a stake in the southerly line of Jefferson Avenue, located in the northerly line of Lot 10, Block U of the Highlawn Addition to St. Albans, Section 1, said beginning point being located N. 73° W. 220 feet from the intersection of the southerly line of Jefferson Avenue with the westerly line of Walnut Street, and 20 feet from the common front comer to Lots Nos. Ten (10) and Eleven (11) of said Block U and running with a line through Lot No. Ten (10) S. 16° 26′ W. 105 feet to a stake in the northerly line of an alley located 20 feet in a northwesterly direction from the common rear corner to Lots Nos. Ten (10) and Eleven (11); thence running with the northerly line of said alley N. 73° 34′ W. 52 feet to a stake in the southerly or rear line of Lot No. Nine (9), said point being located 8 feet in a southeasterly direction from the common rear corner to Lots Nos. Eight (8) and Nine (9); thence running with a line through Lot No. Nine (9) parallel to and 8 feet from the dividing line between Lots Nos. Eight (8) and Nine (9) N. 16° 26′ E, 105 feet to an iron pin in the southerly line of Jefferson Avenue; thence running with the southerly line of said Jefferson Avenue S. 73° 34′ E. 52 feet to the place of beginning.

Being the same property conveyed to Jack Edward Smith by the Deed dated February 12, 2008 and recorded in Deed Book 2716, at Page 11 in the Office of the Clerk of the County Commission of Kanawha County, West Virginia.

TERMS OF SALE:

1)The property will be conveyed in an “AS IS” physical condition by Deed containing no warranty, express or implied, subject to the Internal Revenue Service right of redemption, all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights-of-ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-1.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

5)The Trustee shall be under no duty to cause any existing tenant or person occupying the property to vacate said property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

6)The total purchase price is payable to the Trustee within thirty (30) days of the date of sale, with ten (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total purchase price payable to the Trustee at sale.Pill & Pill, PLLC,
Substitute Trustee

BY:_Pill & Pill, PLLC
85 Aikens Center
Edwin Miller Boulevard
P.O. Box 440
Martinsburg, WV 25402
(304) 263-4971
foreclosures@
pillwvlaw.com
(606697)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

59.NOTICE OF
TRUSTEE’S SALE
NOTICE OF TRUSTEE’S SALE is hereby given pursuant to and by virtue of the authority vested in the Substitute Trustee, Pill & Pill, PLLC, by that certain Deed of Trust dated October 27, 2003, executed by Borrowers Lillian A. Spurlock and Shawn E. Spurlock, to Bart Demeter , the Trustee of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3067, at Page 684. At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 785 Jordan Creek Rd, Elkview, WV 25071. Pill & Pill, PLLC was appointed as Substitute Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated June 22, 2015, of record in the Clerk’s Office in Book 4111, Page 502. The borrowers defaulted under the Note and Deed of Trust and the Substitute Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Substitute Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on the following date:August 26, 2015
at 5:42 p.m.
The property is described as of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Big Sandy District, Kanawha County, West Virginia, and being more particularly described as follows:

ALL THAT PARCEL OF LAND IN BIG SANDY DISTRICT, KANAWHA COUNTY, STATE OF WEST VIRGINIA, AS MORE FULLY DESCRIBED IN DEED BOOK 2538, PAGE 669, ID# 6035168 AND ID#7097866, BEING KNOWN AND DESIGNTED AS PARCEL 1, CONTANING 3 ACRES MORE OR LESS AND PARCEL 2, METES AND BOUNDS PROPERTY, BY FEE SIMPLE DEED FROM JAMES E. RUCKER AS SET FORTH IN BOOK 2538 PAGE 669 DATED 11/16/2001 AND RECORDED 11/19/2001, KANAWHA COUNTY RECORDS, STATE OF WEST VIRGINIA.

Being the same property conveyed to Lillian A. Spurlock by a Deed dated October 23, 2012 in Deed Book 2833, at Page 679 in the Office of the Clerk of the County Commission of Kanawha County, West Virginia; and further being the same property conveyed to Shawn E. Spurlock and Lillian A. Spurlock by a Deed dated November 16, 2001 in Deed Book 2538, at Page 669.

TERMS OF SALE:

1)The property will be conveyed in an “AS IS” physical condition by Deed containing no warranty, express or implied, subject to the Internal Revenue Service right of redemption, all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights-of-ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-1.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

5)The Trustee shall be under no duty to cause any existing tenant or person occupying the property to vacate said property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

6)The total purchase price is payable to the Trustee within thirty (30) days of the date of sale, with ten (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total purchase price payable to the Trustee at sale.Pill & Pill, PLLC,
Substitute Trustee

BY:_Pill & Pill, PLLC
85 Aikens Center
Edwin Miller Boulevard
P.O. Box 440
Martinsburg, WV 25402
(304) 263-4971
foreclosures@
pillwvlaw.com
(606698)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

60.NOTICE OF
TRUSTEE=S SALE
Notice is hereby given, by virtue of the authority vested in the undersigned, J. Nicholas Barth, Successor Trustee, by that certain Deed of Trust made by Joseph J. Lentz and Mary Catherine Lentz to P. M. Pleska and F. T. Graff, Jr., Trustees, bearing date August 24, 1999, and of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 2569 at page 85; the said J. Nicholas Barth acting as Successor Trustee by virtue of that certain Appointment of Successor Trustee dated July 25, 2007, of record in the aforesaid Clerk=s Office in Trust Deed Book 3487 at page 451; and default having been made in the payment of the Note secured by the aforesaid Deed of Trust, and having been requested in writing by the owner and holder of the Note, the undersigned Successor Trustee will offer for sale, at public auction, to the highest bidder at the North Front Door of the Courthouse of Kanawha County, West Virginia, in the City of Charleston, West Virginia, on the 2nd day of September, 2015, at 9:30 o=clock a.m., all that certain lot or parcel of land, together with improvements thereon and appurtenances thereunto belonging, situate in Loudon District, Kanawha County, West Virginia, known and designated as Lot No. Twenty-Eight (28) in Block D-9, in the property of the Kanawha Land Company, known as South Charleston, in Kanawha County, West Virginia, as laid out in lots, streets and alleys, on map of same by M. W. Venable, C. E., filed and recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia;

And being the same property conveyed unto Joseph J. Lentz and Mary Catherine Lentz, as joint tenants, by deed bearing date the 16th day of August, 1999, from James H. Martin, Jr., and L. Christina Martin, his wife, of record in the aforesaid Clerk=s Office in Deed Book 2478 at page 736.
Said property having address of 201 9th Avenue, South Charleston, West Virginia.

The referenced property will be conveyed with covenants of special warranty subject to all further covenants, restrictions, easements, rights of way and reservations which may be a matter of record in the aforesaid Clerk=s Office or visible upon the ground.

TERMS OF SALE: Cash in hand at time of sale, subject to all prior liens and encumbrances, including, without limitation, liens for real estate taxes, incinerator, sanitary and sewer charges.

Pursuant to the terms of the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.

Dated this 4th day of August, 2015.J. NICHOLAS BARTH
Successor Trustee
(606699)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

61.OHIO COUNTY SCHOOLS
RITCHIE ELEMENTARY
SCHOOL RENOVATIONS
ADVERTISEMENT
FOR BIDS 1
ADVERTISEMENT
FOR BIDS
OHIO COUNTY SCHOOLS
RITCHIE ELEMENTARY
SCHOOL RENOVATIONS
GENERAL
CONSTRUCTION
CONTRACT
WHEELING,
WEST VIRGINIA
Sealed proposals for the construction of the Ritchie Elementary School Renovations will be received andlogged by the West Virginia School Building Authority and Ohio County Schools, 2203 National Road, Wheeling, WV 26003 on Monday, August 31, 2015 at the office of Dr. Dianna Vargo, Superintendent until 1:00 p.m. local time. All Bids will be publicly opened and read aloud shortly thereafter at the Ohio County Board of Education Meeting Room, 2203 National Road, Wheeling, WV 26003.

Copies of the Bidding Documents will be available on or after Friday, July 31, 2015 at the office of the Architect, M&G Architects & Engineers, at the address noted below, upon payment of a deposit of $400.00 per set. The deposit will be refunded if the bidding documents are returned in good condition within ten days following receipt of bids. Electronic Portable Document (.pdf) format documents will be available upon payment of $100.00 per set, which is non-refundable. All bids must be submitted in accordance with the requirements listed in the bidding documents to be considered valid.

A mandatory Prebid Meeting will be held on Tuesday, August 11, 2015 at 1:00 p.m. local time at the Ritchie Elementary School, 3700 Wood St, Wheeling, WV 26003, with check-in at the school’s Main Office, for the purpose of familiarizing Bidders with bidding requirements and to answer questions regarding the Bidding Documents. All Bidders must attend the Prebid meeting in order to familiarize themselves with the existing conditions at the project site.

Bidders may review the bidding documents at the following locations:

M&G Architects
& Engineers
1027 Mount de Chantal Road
Wheeling, WV 26003
Phone: 304/242-8248
Fax: 304/242-8249

Ohio Valley Construction
Employers Council
21 Armory Drive
Wheeling, WV 26003
Phone: 304/242-0520
Fax: 304/242-7261

Ohio Valley Construction
Employers Council
626 N. 4th Street
Steubenville, OH 43952
Phone: 740/282-3616

Parkersburg-Marietta
Contractor’s Association
2905 Emerson Avenue
Parkersburg, WV 26104
Phone: 304/485-6485
Fax: 304/428-7622

Pittsburgh Builders
Exchange
1813 North Franklin Street
Pittsburgh, PA 15233-2221
Phone: 412/922-4200
Fax: 412/928-9406

A satisfactory Bid Bond executed by the Bidder or an acceptable surety in an amount equal to 5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c} of the bid shall be submitted with each bid. The successful Bidder will be required to furnish and pay for a satisfactory 100{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c} Performance Bond and Labor and Material Payment Bond in the amount of the contract price.

The bidder(s) submitting the lowest qualified bid(s) as determined by the results of the bid opening shall submit a listing of all subcontractors and all major equipment and material suppliers proposed for each major branch of work itemized and described in the contract documents for the project.

Bidders shall reference the Project Manual for all required Bidding Documents to be submitted as a part of a complete bid.

Each Bidder must insure that no employees and applicants for employment are discriminated against because of race, creed, color, sex, or national origin.

Bids may not be withdrawn for a period of 30 days without the consent of the Owner.

Contractors shall comply with all applicable National, State, and Local codes.

Pursuant to Chapter 21, Article 11 of the “West Virginia Contractor Licensing Act” of 1991, all Contractors doing business in West Virginia must be licensed to perform work in the State; the Contractor’s WV License number must be affixed to all submitted construction bids and fully executed and binding construction contracts or agreements.

Ohio County Schools reserves the right to reject any and all bids, to waive all formalities, and to make selections from the bids that are solely in the best interest of the school system.

Ohio County Schools will suffer loss if the project is not completed within the Contract Time. Therefore, as liquidated damages, and not as a penalty, the Contractor shall be liable for such damages at the rate of $2,000.00 per calendar day for unexcused delays beyond the date of Substantial Completion.(605906)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

62.ORDER OF
PUBLICATION
IN THE CIRCUIT COURT OF KANAWHA COUNTY,
WEST VIRGINIA
State of West Virginia ex
rel.
Offices of the West
Virginia Insurance
Commissioner,
Plaintiff,

v

Civil Action: 15-C-622

Rissa Black, dba
Elite Masonry,
Defendant.

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that Rissa Black, is a resident of the State of West Virginia, it is hereby Ordered that serve upon David Ansell, Plaintiff’s attorney, whose address is Office of the West Virginia Insurance Commissioner, PO Box 50540, Charleston, West Virginia, 25305-0540, an Answer, including any related counter claim or defense you may have to the Complaint filed in this action on or before thirty (30) days from the first date of publication hereof. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the said Complaint.
This also serves as notice that a hearing in regard to the above action will take place on Wednesday, the 2nd day of September, 2015, at 1:00 pm, in the Court of Judge Carrie Webster, of the Judicial Annex Building on 111 Court Street, Charleston, West Virginia.
A copy of said Complaint can be obtained from the undersigned Clerk at this office.
Entered by the Clerk of said Court 7/28/15.Cathy S. Gatson,
Clerk
(606104)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

63.ORDER OF PUBLICATION

IN THE CIRCUIT
COURT OF
LINCOLN COUNTY,
WEST VIRGINIA

IN RE:
CASE NO.:
15-A-21

THE OBJECT OF THIS SUIT IS TO SEEK ADOPTION OF A MINOR CHILD:

TO: MARK FONZO McCLANAHAN

You are hereby notified that a Petition for the Adoption of I.S.M., born on April 29, 2013, will be brought on for hearing before the Honorable Judge for the Circuit Court of Lincoln County, West Virginia, at the Lincoln County Courthouse, 8000 Court Avenue, Hamlin, West Virginia, on the 2nd day of September, 2015, at the hour of 10:30 o’clock a.m., at which time and place you may appear to offer any objection or defense to the Petition for Adoption, otherwise, your parental rights, if any, may be terminated.

You are further notified that this matter may be rescheduled without further notice or publication.

Entered by the Clerk of said Court this 29th day of July, 2015.Charles Brumfield,
Clerk
Lincoln County
Circuit Court
(606074)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

64.ORDER OF
PUBLICATION
FAMILY COURT OF
KANAWHA COUNTY
Brittany Shanahan
Plaintiff

Civil Action No.
13-D-501

Antonio J. Daniels
Defendant

The object of this suit is to obtain a divorce from the bonds of matrimony.

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the plaintiff has used due diligence to ascertain the whereabouts of Antonio J. Daniels without effect it is hereby ordered that Antonio J. Daniels, serve upon Brittany Shanahan, plaintiff, whose address is 1311 Renissance Circle, Apt 301, Charleston, WV 25311, an answer, including any related counter claim or defense you may have to the complaint filed in this action on or before September 16, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the complaint.
A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court July 13, 2015.Cathy S. Gatson
Clerk of Court
(606617)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

65.ORDER OF
PUBLICATION
FAMILY COURT OF
KANAWHA COUNTY
Emily Kathryn Legg
Plaintiff

Civil Action No.
14-D- 1548

Christopher David Legg
Defendant

The object of this suit is to obtain a divorce from the bonds of matrimony.

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the plaintiff has used due diligence to ascertain the whereabouts of Christopher David Legg without effect it is hereby ordered that Christopher David Legg, serve upon Emily Kathryn Legg, plaintiff, whose address is 409 Elk Ave, Clendenin, WV 25045, an answer, including any related counter claim or defense you may have to the complaint filed in this action on or before September 12, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the complaint.
A copy of said complaint can be obtained from the undersigned Clerk at her office.

Entered by the Clerk of said Court July 31, 2015.Cathy S. Gatson
Clerk of Court
(606534)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

66.ORDER OF
PUBLICATION
FAMILY COURT OF
KANAWHA COUNTY
Paula F. Fluharty
Plaintiff

Civil Action No.
15-D- 1146

Ward C. Eister, III,
Defendant

The object of this suit is to obtain a divorce from the bonds of matrimony.

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the plaintiff has used due diligence to ascertain the whereabouts of Ward C. Eister, III without effect it is hereby ordered that Ward C. Eister, III, serve upon Paula F. Fluharty, plaintiff, whose address is 802 Mathews Ave., Charleston, WV 25302, an answer, including any related counter claim or defense you may have to the complaint filed in this action on or before September 17, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the complaint.
A copy of said complaint can be obtained from the undersigned Clerk at her office.

Entered by the Clerk of said Court August 4, 2015.Cathy S. Gatson
Clerk of Court
(606754)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

67.ORDER OF
PUBLICATION
FAMILY COURT OF
KANAWHA COUNTY
Rachel Thomas
Plaintiff

Civil Action No.
15-D- 1077

Robert Thomas
Defendant

The object of this suit is to obtain a divorce from the bonds of matrimony.

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the plaintiff has used due diligence to ascertain the whereabouts of Robert Thomas without effect it is hereby ordered that Robert Thomas, serve upon Rachel Thomas, plaintiff, whose address is 3228 Kanawha Terrace Apt 1, St. Albans, WV 25177, an answer, including any related counter claim or defense you may have to the complaint filed in this action on or before September 12, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the complaint.
A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court August 3, 2015.Cathy S. Gatson
Clerk of Court
(606615)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

68.ORDER OF
PUBLICATION
IN THE MAGISTRATE COURT OF KANAWHA COUNTY, WEST VIRGINIA
Charlotte Pritt
PO Box 13100
Charleston, WV 25360
Plaintiff

Civil Action 15-C-1962

v

The Estate of Ralph Lanham
2026 Walker Dr
Charleston, WV 25312
Defendant

The object of the above entitled action is to obtain a judgment against The Estate of Ralph Lanham and possession of property located at 2026 Walker Dr., Charleston, 25312.
And it appearing by an affidavit filed in this action that the plaintiff has used due diligence to ascertain the residence and whereabouts of said defendant without effect.
It is ordered that The Estate of Ralph Lanham, do serve upon Kanawha County Magistrate Court, magistrate, whose address is 111 Court St., Charleston, WV 25301, an answer or other defense to the complaint filed in this action on or before 30 days, otherwise judgment by default will be taken against The Estate of Ralph Lanham at any time thereafter. A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court January 28, 2015.
Angel Cincinnati
Magistrate Court Clerk
()
Class: 983 Gazette Legal Ads Last appeared: 08-05-2015

69.ORDER OF
PUBLICATION

IN THE MAGISTRATE COURT OF PUTNAM COUNTY,
WEST VIRGINIA
William Shortridge
109 Beechwood Ave
Winfield, WV 25213
PLAINTIFF
V.
Burt George
100 Hudson Ave Apt C
St. Albans, WV 25177
DEFENDANT

Civil Action No. 15C-191

The object of the above entitled action is to obtain judgment in the amount of $4650.00 plus court costs.
And it appearing by an affidavit filed in this action that The Plaintiff has used due diligence to locate the Defendant.
it is ordered that HE do serve upon PPUTNAM CO. MAGISTRATE COURT, magistrate, whose address is 12093 Winfield Road Suite 15, Winfield, WV 25213, an answer or other defense to the complaint filed in this action on or before 30 DAYS, otherwise judgment by default will be taken against HE at any time thereafter. A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court July 7, 2015Darry Casto
Magistrate Court Clerk
(606723)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

70.PI Telecom Infrastructure V, LLC proposes to construct a 110-foot monopole tower. The proposed lighting on the tower is medium intensity dual red and white lights. The tower will be located at 0.04 miles southeast of the intersection of Cardinal Drive and Athens Avenue in Charlestown, Kanawha County, West Virginia. Interested persons may review the application online at www.fcc.gov/asr/applications by entering the Form 854 File Number A0974462. Interested persons may raise environmental concerns about the proposed structure by filing a Request for Environmental Review with the Federal Communications Commission (FCC):

-The FCC strongly encourages interested parties to file Requests for Environmental Review Online. Instructions for making such filing can be found online at www.fcc.gov/asr/environmentalrequest.

-The mailing address for interested parties that would prefer to file a Request for Environmental Review by paper copy is FCC Request for Environmental Review, Attn: Ramon Williams, 445 12th Street SW, Washington, DC 20554.

We also invite your comments pertaining to the effect of the proposed tower on historic properties. Please submit comments regarding effects on historic properties within 30 days to Lisa Heise c/o Martin Environmental Solutions Inc at 8823 San Jose Blvd., Suite 103, Jacksonville, FL 32217, [email protected], or call (904) 737-1034.(606702)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

71.Public Hearing Notice
The West Virginia Bureau for Public Health, Office of Nutrition Services, Women, Infants and Children’s (WIC) Program is seeking public comment on its 2016 State Plan, in accordance with Federal Regulations 246.4 (23) (b). The plan outlines the program’s goals, priorities and objectives for the upcoming fiscal year.

A hearing will be held to receive public comment on the plan from 1:00 pm to 3:00 pm on Tuesday, August 11, 2015, in Room 507 at 350 Capitol Street in Charleston.

A copy of the State Plan may be viewed at the State WIC office at the above address or on the Office of Nutrition Services website at http://ons.wvdhhr.org . Written comments about the plan may be sent to: WV WIC Program, Room 519, 350 Capitol Street, Charleston, WV 25301-3717, Attention: Public Comment. The deadline for submitting written comments is August 18, 2015. Those comments will be made available for public review at the above address beginning Wednesday, August 19, through Wednesday, August 26, 2015 on regular business days between the hours of 8:30 a.m. to 4:30 p.m.(606418)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

72.PUBLIC NOTICE
INTENT TO
ENTER PROPERTY
TO CONDUCT
RECLAMATION
ACTIVITIES

MORRISVALE
(HOLESTIN) DRAINAGE
TO ALL HEIRS KNOWN AND UNKNOWN AND ALL THOSE HAVING AN INTEREST IN THE HEREINAFTER DESCRIBED PROPERTY IN THE NAME OF BARRY CLARK AND CHANDRA CLARK. THE STATE OF WEST VIRGINIA, ACTING BY AND THROUGH THE DEPARTMENT OF ENVIRONMENTAL PROTECTION, OFFICE OF ABANDONED MINE LANDS AND RECLAMATION, HEREBY GIVES NOTICE IT SHALL ENTER UPON THE HEREINAFTER DESCRIBED PROPERTY NEAR THE COMMUNITY OF MORRISVALE, SCOTT DISTRICT, BOONE COUNTY, WEST VIRGINIA.

A parcel of land described as 5 acres located at the intersection of WV near the community of Morrisvale, Scott District, Boone County, West Virginia, being Parcel 15.1 of Tax Map 10.

WHEREAS, the Official Code of West Virginia, Chapter 22, Article 2, covering the Abandoned Mine Reclamation Act stipulates that the State of West Virginia, acting by and through the Department of Environmental Protection, Office of Abandoned Mine Lands and Reclamation, is authorized to do all things necessary or expedient to protect the public health, safety and general welfare from the adverse effects of past coal mining practices in West Virginia, and

WHEREAS, upon investigation the Department of Environmental Protection has determined that there presently exists a situation of adverse effects in the area of the aforesaid property as a result of past coal mining practices, and

WHEREAS, there is no statutory obligation on the part of any landowner or former mine owner to perform reclamation and there is no other person or agency which will act expeditiously or otherwise to control and abate the adverse effects of these past coal mining practices, and

WHEREAS, all the owners, heirs, or other persons having an interest in said property cannot be located and/or there may be some unknown owners, heirs or persons having an interest in said property.

NOW, THEREFORE, having made a reasonable effort to locate and obtain consent from any and all property owners, the State of West Virginia, acting by and through the Department of Environmental Protection, Office of Abandoned Mine Lands and Reclamation, its agents, assignees, employees and contractors hereby gives notice that on or after September 1, 2015 , it will enter the aforesaid property for the purpose of doing the necessary abatement work as the situation and the safety of the public requires, all in accordance with Chapter 22, Article 2, Section 6 of the Official Code of West Virginia, which provides for entry upon lands as an exercise of the police power of the State of West Virginia for the protection of public health, safety and general welfare.

Submitted this 30th day of July, 2015.Robert Rice, Chief
Office of Abandoned
Mine Lands & Reclamation
(606693)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

73.PUBLIC NOTICE
THE KANAWHA COUNTY PLANNING COMMISSION WILL HOLD A PUBLIC HEARING IN THE KANAWHA COUNTY COMMISSION COURTROOM, LOCATED AT 409 VIRGINIA STREET, EAST, FIRST FLOOR, CHARLESTON, WEST VIRGINIA, on WEDNESDAY, SEPTEMBER 9, 2015 AT 6 P.M. TO CONSIDER THE FOLLOWING FOR APPROVAL. (Note: The first Public Hearing (Cell Tower) was originally scheduled for Wed. Aug. 12, 2015, but has been postponed until September 9, 2015 at the request of PI Telecom Infrastructure V, LLC for Verizon Wireless.)

1. Cell Tower Application by PI Telecom Infrastructure V, LLC d/b/a Verizon Wireless for a 105′ Cell Tower with an additional 4′ long lightning rod on top to be located off Cardinal Drive in Rand, WV, at Malden District Tax Map 19A, Parcels 173 &174, Kanawha County, WV.

2.Subdivision Application by Terry Shafer for Preliminary Approval and Final Approval for 3 new Lots in the Pinell Point Subdivision, located at Elk District, Tax Map 24, Parcel 6.4. Subdivision is located in Elkview near Blue Creek.(606415)
Class: 983 Gazette Legal Ads Last appeared: 08-05-2015

74.PUBLIC NOTICE
The next meeting of the Medical Executive Committee of West Virginia University Hospitals, Inc. will convene at 4:30 p.m., Wednesday, August 19, 2015 in POC Conference Room 4, WVU Hospital, Morgantown, WV. Open to the public.(606613)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

75.REQUEST FOR
QUOTATIONS
The West Virginia Parkways Authority will accept sealed proposals for the following: Contract TB-1-16
REPLACEMENT OF
TAMARACK BOILERS
Bid proposals will be received at the office of the WV Parkways Authority, Administration Building, 3310 Piedmont Road, Charleston, WV until 3PM on Tuesday, August 18th, 2015.

Specifications are available by at www.wvturnpike.com.

The WVPA is an Equal Opportunity Employer(606590)
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

76.REQUEST FOR
ARCHITECTS
EXPRESSIONS OF
INTEREST
Pursuant to West Virginia Code 5G-1-3, the City of Hinton is seeking Expression of Interest from Architectural and Engineering firms to provide all professional services including but not limited to master planning, conceptual design, contract documents and construction administration for all projects to be determined in the master plan whether constructed by city employees or competitively bid.
Qualified firms are invited to submit three (3) copies of an Expression of Interest and Statement of Qualifications based upon the above Scope for the past 10 years to, Cris Meadows, City Manager, no later than Thursday, August 13, 2015 by 4:00 p.m. LPT, at the office of the City Manager, 322 Summers Street, Hinton, WV 25951.
The City of Hinton reserves the right to reject any and/or all statements from interested firms and to make the award in any manner cdeemed to be in the best interest of the City of Hinton and in accordance with WV Code 5G-1-3.THE CITY OF HINTON
Cris Meadow
City Manager
(605862)
Class: 983 Gazette Legal Ads Last appeared: 08-10-2015

77.Request for Bid
The purpose of this bid is to establish a price basis upon which purchases, blanket-purchase agreement, blanket-service agreements or public works contracts can be issued for the listed items. The Fayette County Board of Education reserves the right to reject any/or all bids presented.

TITLE: Fayette County Student Drug Testing
A.Random drug testing

B.Athletes, extra-curricular activities, simulated workplace and student drivers

C.Opt-in student participants

D.Voluntary urine specimen testing

DUE DATE: August 10, 2015 by 4:00 PM

SEND TO:
Fayette County
Board of Education
111 Fayette Avenue
Fayetteville, WV 25840

CONTACT
INFORMATION

Bid packets regarding the drug testing bid specifications may be directed to:

Aimee Shumate
[email protected]
304.574.1176, ext. 2141

Questions regarding bid procedure and bid proposals may be directed to:

Serena Starcher
[email protected]
304-574-1176, ext. 2141(605662)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

78.REQUEST FOR
QUOTATIONS
The West Virginia Parkways Authority will accept sealed proposals for the following:
SCB-1600 Shot Blaster with BH-16 Head
Attachment or Equal – Rebid
Bid proposals will be received at the office of the WV Parkways Authority, Administration Building, 3310 Piedmont Road, Charleston, WV until 2PM on Tuesday, August 25th , 2015.

Specifications are available by at www.wvturnpike.com(606950)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

79.REQUEST FOR
QUOTATIONS
The West Virginia Parkways Authority will accept sealed proposals for the following:

SLOPE MOWERS (2)

Bid proposals will be received at the office of the WV Parkways Authority, Administration Building, 3310 Piedmont Road, Charleston, WV until 2PM on Tuesday, August 25th, 2015.

Specifications are available by at www.wvturnpike.com.(606951)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

80.Tariff Form No. 8-C
(Tariff Rule No. 30-C)

PUBLIC NOTICE OF CHANGE
IN RATES UPON APPLICATION
NOTICE is hereby given that MOUNTAINEER GAS COMPANY, a public utility, has filed with the PUBLIC SERVICE COMMISSION OF WEST VIRGINIA, an application containing decreased rates, tolls and charges for furnishing natural gas service to approximately 220,000 customers at various locations in the Counties of Barbour, Berkeley, Boone, Braxton, Brooke, Cabell, Calhoun, Clay, Doddridge, Fayette, Gilmer, Grant, Greenbrier, Hancock, Hardy, Harrison, Jackson, Jefferson, Kanawha, Lewis, Lincoln, Logan, Marion, Marshall, Mason, McDowell, Mercer, Mineral, Mingo, Monongalia, Monroe, Nicholas, Ohio, Pendleton, Preston, Putnam, Raleigh, Randolph, Ritchie, Roane, Summers, Tucker, Tyler, Upshur, Wayne, Wetzel, Wirt, Wood, and Wyoming.

The proposed rates and charges will become effective for services rendered on and after November 1, 2015, unless otherwise ordered by the Public Service Commission, and reduce annual revenue by approximately $28,573,933, a decrease of approximately 20{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}.

The average monthly bill for the various classes of customers of MOUNTAINEER GAS COMPANY will be changed as follows:DECREASE DECREASE
Residential $7.55 11.79{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}
Commercial $36.64 13.40{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}
Industrial $7,566.94 22.35{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}
Resale $1,962.43 16.77{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}
Resale customers of MOUNTAINEER GAS COMPANY include Canaan Valley Gas Co., Consumers Gas Utility Co., Megan Oil and Gas, City of Philippi, and Southern Public Service.

The decreases shown are based on averages of all customers in the indicated class. Each class may receive a decrease greater or less than stated here. Individual customers may receive decreases that are greater or less than average. Furthermore, the requested rates and charges are only a proposal and are subject to change (increases or decreases) by the Public Service Commission in its review of this filing. Any change in rates and charges will not become effective until authorized and approved by the Public Service Commission. If a hearing is conducted, notice will be given of the time and place of hearing.

A complete copy of the proposed rates, as well as a representative of the Company to provide any information requested concerning the proposed rates, is available to all customers, prospective customers, or their agents at the office of the Company at 501 56th Street, SE, Charleston, West Virginia 25361.

A copy of the proposed rates is available for public inspection at the office of the Executive Secretary of the PUBLIC SERVICE COMMISSION at 201 Brooks Street, Charleston, West Virginia.

The 30-C procedure is designed to provide a procedure for changing rates charged to customers by natural gas distribution utilities based exclusively on the cost of purchased gas. Consequently, protest should be limited to the reasonableness of such costs and the method by which they are calculated. Anyone desiring to protest or intervene should file a written protest or notice of intervention within twenty-five (25) days following the date of this publication unless otherwise modified by Commission order. Failure to timely intervene can affect your rights to protest any rate change and to participate in future proceedings. Requests to intervene must comply with the Commission’s rules on intervention set forth in the Commission’s Rules of Practice and Procedure. All protests and interventions should be addressed to Executive Secretary, Public Service Commission of West Virginia, P.O. Box 812, Charleston, WV 25323.

(606948)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

81.Tariff Form No. 8-C
PUBLIC NOTICE OF CHANGE IN RATES
UPON APPLICATION
(Tariff Rule No. 30-C)
NOTICE is hereby given that Union Oil & Gas, Inc., a public utility, has filed with the PUBLIC SERVICE COMMISSION OF WEST VIRGINIA an application containing decreased rates, tolls and charges for furnishing natural gas service to 6,000 customers in the Counties of Cabell, Kanawha and Putnam, West Virginia.

The following proposed decreased rates and charges will become effective November 1, 2015, unless otherwise ordered by the Public Service Commission, and will produce an decrease of approximately $ 1,135,000 annually in revenue, an decrease of 20.7{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}. The average monthly bill for the various classes of customers will be decreased as follows:
($) DECREASE ({4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c})DECREASE
Residential(6 mcf usage) $12.40 17.3{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}
Commercial (27 mcf usage) $55.81 19.8{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}

The decreases shown are based on averages of all customers in the indicated classes. Individual customers may receive decreases that are greater or less than average. Furthermore, the requested decreased rates and charges are only a proposal and are subject to change (increases or decreases) by the Public Service Commission in its review of this filing. Any change in rates and charges will not become effective until authorized and approved by the Public Service Commission. If a hearing is scheduled, notice will be given of the time and place of hearing.

A complete copy of the tariff, as well as a representative of the Company to provide any information requested concerning it, is available to all customers, prospective customers or their agents at 85 Ferry Street, Winfield, WV 25213. A copy of the tariff is also available for public inspection at the offices of the Executive Secretary of the Public Service Commission at 201 Brooks Street, Charleston, WV 25301.

The Rule 30C procedure is designed to provide a procedure for changing rates charged to customers by natural gas distribution utilities based exclusively on the costs of purchased gas. Consequently, protest should be limited to the reasonableness of such costs and the method by which they are calculated. Anyone desiring to protest or intervene should file a written protest or notice of intervention within twenty-five (25) days following the date of this publication, unless otherwise modified by Commission order. Failure to timely intervene can affect your rights to protest any rate changes and to participate in future proceedings. Request to intervene must comply with the Commission’s rules on intervention. All protests and intervention should be addressed to Executive Secretary, Public Service Commission of West Virginia, P.O. Box 812, Charleston, WV 25323.(
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

82.The AFL-CIO Appalachian Council, Inc. Head Start Program is now accepting bids for the 2015-2016 school year for all food service products to operate the Child and Adult Care Food Program in the service areas of Boone, Doddridge, Jackson, Putnam, Roane, and Wood Counties. The opening date for bids is August 3, 2015. Closing date is August 7, 2015. Send bids to Appalachian Council Head Start, 501 Leon Sullivan Way, 2nd Floor, Charleston WV 25301. Bids must be received no later than 4:00 p.m. on Friday, August 7, 2015.

AFL-CIO Appalachian Council, Inc. Head Start is an equal opportunity provider and employer.(606175)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

83.The Sanitary Board of
the City of Charleston, WV
A Municipal Utility

INVITATION
FOR BIDS
for
TWO (2) ALUMINUM
DUMP TRUCK BEDS

July 2015
The Sanitary Board of the City of Charleston, West Virginia (CSB) will receive sealed Bids for TWO (2) ALUMINUM DUMP TRUCK BEDS at the CSB office located at 208 26th Street W, Charleston, WV 25387, until 10:00 a.m., E.S.T., on Tuesday, August 18, 2015. The Bidding will then be closed and the Bids will be publicly opened and read aloud. All Bidders are invited to attend.

The CSB will consider incomplete any Bid not prepared and submitted in accordance with the provisions herein outlined, and may reject any or all Bids. Any Bid may be withdrawn by the Bidder prior to the scheduled time for the opening of Bids or authorized postponement thereof provided the Bidder’s written request for withdrawal is delivered to the CSB before the Bids are opened. Any Bid received after the time and date specified will not be opened. No Bidder may withdraw their Bid after the actual Bid opening thereof. A Bid that has been withdrawn will be returned to the Bidder unopened at the time of the opening of the other Bids. No conditional Bids will be accepted.

Bid Documents may be obtained at the above address or by calling Jeremy Frye @ (304) 348-1084 Ext. 256.(605895)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

84.THE SHARON CHURCH OF GOD, CABIN CREEK ROAD, DRY BRANCH, WV WILL BE HAVING THEIR USDA FOOD PANTRY, SATURDAY, AUGUST 15, 2015 FROM 9:00 AM – 11:00AM
Class: 983 Gazette Legal Ads Last appeared: 08-12-2015

85.TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE
The undersigned Trustee, by virtue of the authority vested in him by that certain Deed of Trust dated August 27, 2004, and duly recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed of Trust Book 3170, at Page 51, Christopher A. Kidd did convey unto Richard A. Pill, Trustee, certain real property described in said Deed of Trust; and default having been made under the aforementioned Deed of Trust, and the undersigned Trustee having been instructed by the secured party to foreclose thereunder, will offer for sale at public auction at the front door of the Kanawha County Courthouse, in Charleston, West Virginia, on Wednesday,
August 12, 2015,
at 5:30 PM
The following described real estate, with its improvements, easements and appurtenances thereunto belonging, situate in the Charleston District, Kanawha County, West Virginia, and more particularly described as follows:

Parcel One: All that certain lot or parcel of land situate on the waters of Two Mile Creek, in Charleston District, Kanawha County, West Virginia, beginning at an iron pin by a post in the right of way 119 feet from a Honey Locust tree in the right of way or road going up Scraggs Hollow, the dividing line tree between Oscar W. Rowley and Ernestine RCowley and Edward Amos and the two right of ways running south from said Scraggs Hollow Road; thence up the hill in an easterly direction 60 feet to a peach tree and iron pin; thence up the hill the same direction 97 feet to a post and iron pin; thence in a north easterly direction 40 feet to a post and iron pin; thence in a southerly direction 63 feet to a post and iron pin; thence back down the hill in a westerly direction 184 feet to an iron pin in said right of way; thence 37 feet in a northerly direction with said right of way to said post and iron pin place of beginning.

Parcel Two: That certain parcel of land situate on the waters of Kanawha Two Mile Creek, Charleston District, Kanawha County, West Virginia, and being more particularly described as follows:

BEGINNING at an iron pin along Friendly Drive and which iron pin is located at the corner of the property owned by the parties of the second part; thence with one line by of the property owned by the parties of the second part 60 feet to a stake; thence continuing with another line of said property by the said parties of the second part 97 feet to a stake and rear corner of the property of the parties of the second part; thence with the boundary line between the parties of the second part’s property and M.B. Kidd 56 feet to a stake; thence leaving said boundary line and running in a southwesterly direction 124 feet to the place of beginning.

This conveyance is made subject to such rights of way, easements, restrictions, covenants, conditions and reservations as may be found in prior deeds of record in the chain of title.

At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 2404 Friendly Drive, Charleston, WV 25312.

AND BEING the same real estate which was conveyed to Christopher A. Kidd, by Deed dated August 18, 2004, from Dorothy Miller, and recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 2611, at Page 421.

The above described property will be sold subject to any covenants, restrictions, easements, leases and conditions of record, and subject to any unpaid real estate taxes.

The subject property will be sold in “AS IS” condition. The Trustee shall be under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

TERMS: Ten percent (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the purchase price as a cash deposit with the balance due and payable within 30 days of the day of sale.Richard A. Pill, Trustee

P. O. Box 440,
85 Aikens Center,
Martinsburg, WV 25404
Phone (304) 263-4971,
Fax (304) 267-5840,
E-mail:
[email protected]
(605196)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

86.TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE
The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated August 17, 2011, and duly recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book No. 3815, at Page 43, Jeffrey Powers did convey unto Dru A. Shope, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated June 19, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by MATRIX FINANCIAL SERVICES CORPORATION to foreclose thereunder, will offer for sale at public auction at the front door of the Kanawha County Courthouse in Charleston, West Virginia, onAugust 18, 2015
at 2:45 PM
the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Spring Hill District, Kanawha County, West Virginia, and more particularly described as follows:

All that certain lot, tract, or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, being Lot No. 51 of the Goshorn Addition to Spring Hill, as shown on a map of said addition, of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Map Book No. 12 at Page No.54, said Lot No. 51 being formerly situate in Jefferson District, and now designated Spring Hill District Map 24, Parcel 2, Kanawha County, West Virginia.

LSOT: Deed Book 2656, Page 275, dated Marche 31, 2006, Office of the Clerk of the County Commission of Kanawha County, West Virginia.

BT-54877

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 905 Wilson Street, South Charleston, WV 25309.

The referenced real estate will be conveyed with no covenants of warranty, and subject to all covenants, restrictions, easements, rights of way and reservations which may be a matter of record in the aforesaid Clerk’s Office or visible upon the ground, all prior liens and encumbrances, including, without limitation, liens for real estate taxes, incinerator, sanitary and sewer charges. The purchasers at the sale shall be responsible for paying the recording costs and also the tax on the privilege of transferring real property (the cost of the tax stamp to be affixed to the deed). The purchasers shall be responsible for payment of all real estate taxes.

The subject property will be sold in “AS IS” condition. The Substitute Trustee shall be under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

TERMS: $9,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

FEDERAL TAX LIEN: In the event that there are Federal Tax Liens against the property, the United States would have the right to redeem the property within a period of 120 days from the date of such sale or the period allowable for redemption under local law, whichever is longer.

Pursuant to the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated or by posting a notice of the same, and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.SENECA TRUSTEES, INC.
5000 Coombs Farm Drive,
Suite 104
Morgantown, WV 26508
(304) 413-0044
(304) 292-2918
Toll free: (888) 534-3132
Reference File No. 31537
(606182)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

87.TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE
The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated May 2, 2003, and duly recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book No. 2987, at Page 165, George M. Archer and Betty Jane Archer did convey unto Century Title & Escrow Services, LTD, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated June 23, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by Federal Home Loan Mortgage Corporation to foreclose thereunder, will offer for sale at public auction at the front door of the Kanawha County Courthouse in Charleston, West Virginia, onAugust 18, 2015
at 2:45 PM
the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Nitro District, Kanawha County, West Virginia, and more particularly described as follows:

All that certain lot, tract or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, known as Lot 2411 – 24th Street, situate in Nitro, Kanawha County, West Virginia, and being more particularly bounded and described as follows:

BEGINNING at a point on the north street line of Twenty-fourth Street, common corner to Lots 2411 and 2413 coordinate location North fifty plus twenty-four and thirty six hundredths and East forty plus seventy-four and ninety-three hundredths and running thence in a westerly direction along said street line for a distance of fifty feet, common corner to Lots 2411 and 2409; thence ninety degrees to the right for a distance of fifty feet, common corner to Lots 2411, 2413, 2512 and 2514; thence ninety degrees to the right for a distance of sixty-five feet, common corner to Lots 2409, 2411, 2510 and 2512; thence ninety degrees to the right for a distance of sixty-five feet to the point of beginning, embracing an area of eight hundredths of an acre, more or less, being part of Area “S”, situate in Nitro Independent District, Kanawha County, West Virginia.

Being the same property conveyed unto George M. Archer and Betty Jane Archer by Deed dated, January 12, 1987, filed for record on January 12, 1987, in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 2149, at page 73.

This conveyance is made subject to all exceptions, reservations, and conditions as contained in prior deeds of record.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 2411 24th Street, Nitro, WV 25143.

The referenced real estate will be conveyed with no covenants of warranty, and subject to all covenants, restrictions, easements, rights of way and reservations which may be a matter of record in the aforesaid Clerk’s Office or visible upon the ground, all prior liens and encumbrances, including, without limitation, liens for real estate taxes, incinerator, sanitary and sewer charges. The purchasers at the sale shall be responsible for paying the recording costs and also the tax on the privilege of transferring real property (the cost of the tax stamp to be affixed to the deed). The purchasers shall be responsible for payment of all real estate taxes.

The subject property will be sold in “AS IS” condition. The Substitute Trustee shall be under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

TERMS: 3,500.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

FEDERAL TAX LIEN: In the event that there are Federal Tax Liens against the property, the United States would have the right to redeem the property within a period of 120 days from the date of such sale or the period allowable for redemption under local law, whichever is longer.

Pursuant to the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated or by posting a notice of the same, and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.SENECA TRUSTEES, INC.
5000 Coombs Farm Drive,
Suite 104
Morgantown, WV 26508
(304) 413-0044
(304) 292-2918
Toll free: (888) 534-3132
Reference File No. 1976
(606178)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

88.TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE
The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated October 20, 2006, and duly recorded in the Office of the Clerk of the County Commission of Boone County, West Virginia, in Book No. 293, at Page 128 and modified in Book No. 316, at Page 688, Jeffery M. Pratt and Lisa G. Pratt did convey unto BB&T Collateral Service Corporation, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated July 1, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by Branch Banking and Trust Company to foreclose thereunder, will offer for sale at public auction at the front door of the Boone County Courthouse in Madison, West Virginia, onAugust 19, 2015
at 4:15 PM
the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Madison District, Boone County, West Virginia, and more particularly described as follows:

All that certain lot or parcel of real estate situate, lying and being in Madison District, Boone County, West Virginia, and being more particularly described as follows:

All of Lots Nos. 140-8 (148) and 140-9 (149) in the Danville Land Company Subdivision No. One (1) commonly known as East Danville, but now situate within the corporate limits of the City of Madison, in Scott District of Boone County, West Virginia, as said lots are shown on a map of said sub-division which is now recorded in the Office of the Clerk of the County Commission of Boone County, West Virginia, in Deed Book 144, at Page 821.

And being the same property conveyed to Jeffrey Mark Pratt and Lisa Gaye Pratt, husband and wife, by a deed dated March 15, 1995, from Enola Ruth Pratt, which deed is of record prior to or simultaneously with the recording of this document, by the undersigned attorney, in the Office of the Clerk of the County Commission of Boone County, West Virginia.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 340 3rd Street W, Madison, WV 25130.

The referenced real estate will be conveyed with no covenants of warranty, and subject to all covenants, restrictions, easements, rights of way and reservations which may be a matter of record in the aforesaid Clerk’s Office or visible upon the ground, all prior liens and encumbrances, including, without limitation, liens for real estate taxes, incinerator, sanitary and sewer charges. The purchasers at the sale shall be responsible for paying the recording costs and also the tax on the privilege of transferring real property (the cost of the tax stamp to be affixed to the deed). The purchasers shall be responsible for payment of all real estate taxes.

The subject property will be sold in “AS IS” condition. The Substitute Trustee shall be under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

TERMS: $8,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

FEDERAL TAX LIEN: In the event that there are Federal Tax Liens against the property, the United States would have the right to redeem the property within a period of 120 days from the date of such sale or the period allowable for redemption under local law, whichever is longer.

Pursuant to the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated or by posting a notice of the same, and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.SENECA TRUSTEES, INC.
5000 Coombs Farm Drive,
Suite 104
Morgantown, WV 26508
(304) 413-0044
(304) 292-2918
Toll free: (888) 534-3132
Reference File No. 28880
(606416)
Class: 983 Gazette Legal Ads Last appeared: 08-07-2015

89.WEST VIRGINIA
DEPARTMENT OF
TRANSPORTATION
DIVISION OF HIGHWAYS
NOTICE TO APPRAISERS
AND REVIEW
APPRAISERS
Sealed proposals will be received by the West Virginia Department of Transportation, Division of Highways at its central Right of Way office in Building Five, Room A-618, 1900 Kanawha Boulevard, East, Charleston, West Virginia 25305-0430 until 4:00 p.m. August 14, 2015. The next business day at 11:00 a.m. the said proposals will be publicly opened and read immediately thereafter for the appraisal or appraisal review services for the following project:

CALL 15-009 Project: X342-H-40.21 00; Federal Project NHPP-0484(317); Corridor H Kerens to RT 219, Randolph and Tucker Counties; Appraisal approx. 24 Parcels. See proposal for more detailed information.

CALL 15-010 Project: X342-H-40.21 00; Federal Project NHPP-0484(317); Corridor H Kerens to RT 219, Randolph and Tucker Counties; Appraisal Review approx. 24 Parcels. See proposal for more detailed information.

Proposals will be received from prequalified West Virginia licensed/certified appraisers currently on the WVDOT, DOH’s Approved Appraiser and/or Review Appraiser List. Registration is required with the Department of Administration, Division of Purchasing, in accordance with Chapter 5A, Article 3, Section 12 of the West Virginia Code.

Interested parties should request a bid package containing project plans and all necessary bidding documents by contacting Ms. Carolyn Gorrell via email at [[email protected]]. Information regarding qualification requirements necessary for inclusion on the WVDOT, DOH’s Approved Appraiser List is available by contacting Ms. Carolyn Gorrell via email at [[email protected]].

The West Virginia Department of Transportation, Division of Highways reserves the right to defer, delay or postpone the date for receiving and publicly opening proposals for any project designated in this advertisement, without the necessity of renewing such advertisement. All bidders obtaining valid bidding proposals as provided above will be notified of such deferment, delay or postponement and the date that proposals will be received and publicly opened.

The West Virginia Department of Transportation, Division of Highways reserves the right to reject any and all proposals.

The West Virginia Department of Transportation, Division of Highways hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, religion, sex or national origin in consideration for an award.WEST VIRGINIA
DEPARTMENT OF
TRANSPORTATION
Division of Highways
Eric B. Hudnall, J.D.
Director, Right of
Way Division
(605799)
Class: 983 Gazette Legal Ads Last appeared: 08-05-2015

90.WEST VIRGINIA
PARKWAYS AUTHORITY

ADVERTISEMENT
FOR PROPOSALS
Sealed proposals will be received by the West Virginia Parkways Authority for:CONTRACT 1C-16
CULVERT RETROFIT
MERCER, RALEIGH,
AND KANAWHA
COUNTIES
This contract is located in Mercer, Raleigh, and Kanawha Counties. It consists of dewatering and retrofit of various culverts. The locations listed below.

The existing linear feet of culvert to be retrofit are:
Milepost 13.7:
230LF 48″ CMP

Milepost 14.3:
125LF 84″ CONCRETE
PIPE

Milepost 25.5:
439LF 42″ CMP

Milepost 120.5 (I-64):
100LF 24″ CMP

Milepost 40.2:
442LF 42″ CMP

Milepost 45.9:
230LF 24″ CMP

Milepost 77.6:
15LF 36″ CMP

All work under this contract shall be completed by December 31, 2016.

Proposals will be received at the office of the West Virginia Parkways Authority, Administration Building, Charleston, West Virginia until 3:00 PM August 20, 2015, at which time and place said proposals will be publicly opened and read. If proposals are to be mailed via the U.S. Postal Service regular mail, they must be addressed to the West Virginia Parkways Authority, P.O. Box 1469, Charleston, WV 25325. This mail is picked up by the Authority once a day between 7:00 AM and 8:00 AM. However, Express Mail One Day Service, Federal Express, United Parcel Service (UPS), etc., must be sent to the West Virginia Parkways Authority, 3310 Piedmont Road, Charleston, WV 25306. It shall be the bidder’s responsibility to determine his transmittal method such that his bid will arrive in the Authority’s office prior to the scheduled bid opening. Bids received in the Authority’s office after the scheduled opening will be returned to the bidder unopened.

Prospective bidders must be prequalified in accordance with SECTION 102.1 of the WVDOH Standard Specifications. Contract Documents without Standard Specifications or other referenced standards can be obtained from HNTB, 41 Mission Way, Scott Depot, WV 25560, Phone (304) 760-1833, Email [email protected].

Proposals must be made upon the forms furnished by the Authority in the manner designated in the specifications, and must be enclosed in sealed envelopes bearing the name and address of the bidder and the number of the contract on the outside, and must be accompanied by a CASHIER’S or CERTIFIED CHECK or BID BOND in favor of the West Virginia Parkways Authority, FOR AN AMOUNT EQUAL TO FIVE PERCENT (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) OF THE AMOUNT OF THE PROPOSAL OR $2,000 WHICHEVER IS THE GREATER, and must be delivered at the place designated above on or before the day and hour named.

Pursuant to Bureau of Employment Programs (BEP) Rule 96 C.S.R.1 Implementation Rule dated June 30, 2000, Contractors requesting plans must furnish their FEIN Number, company name and any name they are doing business as. Firms listed in the BEP Default Directory will not be issued Bidding Documents.

The Authority reserves the right to reject any and all Proposals submitted, and to waive any or all formalities in bidding, as it may deem in its best interest.

The Authority strongly encourages minority owned and women owned businesses to submit proposals for this contract.

The WVPA is an Equal Opportunity Employer. All firms submitting proposals must certify that they practice Equal Employment Opportunities.(605908)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

91.WEST VIRGINIA
PARKWAYS AUTHORITY

ADVERTISEMENT
FOR PROPOSALS
Sealed proposals will be received by the West Virginia Parkways Authority for:CONTRACT BDS-1-16
PROTECTIVE BRIDGE
DECK SEALANT
RALEIGH AND
KANAWHA COUNTIES
This contract is located in Raleigh and Kanawha Counties. It consists of applying a Protective Bridge Deck Sealant to Bridges 3076N (MP 89.4), 3044N (MP 51.43), and 3034N (MP 43.5). The total estimate sealant area is as follows:

Contract BDS-1-16 64,600 square feet

All work under this contract shall be completed by October 31, 2015.

Proposals will be received at the office of the West Virginia Parkways Authority, Administration Building, Charleston, West Virginia until 3:00 PM August 20, 2015, at which time and place said proposals will be publicly opened and read. If proposals are to be mailed via the U.S. Postal Service regular mail, they must be addressed to the West Virginia Parkways Authority, P.O. Box 1469, Charleston, WV 25325. This mail is picked up by the Authority once a day between 7:00 AM and 8:00 AM. However, Express Mail One Day Service, Federal Express, United Parcel Service (UPS), etc., must be sent to the West Virginia Parkways Authority, 3310 Piedmont Road, Charleston, WV 25306. It shall be the bidder’s responsibility to determine his transmittal method such that his bid will arrive in the Authority’s office prior to the scheduled bid opening. Bids received in the Authority’s office after the scheduled opening will be returned to the bidder unopened.

Prospective bidders must be prequalified in accordance with SECTION 102.1 of the WVDOH Standard Specifications. Contract Documents without Standard Specifications or other referenced standards can be obtained from HNTB, #41 Mission Way, Scott Depot, WV 25560, Phone (304) 760-1803, Email [email protected].

Proposals must be made upon the forms furnished by the Authority in the manner designated in the specifications, and must be enclosed in sealed envelopes bearing the name and address of the bidder and the number of the contract on the outside, and must be accompanied by a CASHIER’S or CERTIFIED CHECK or BID BOND in favor of the West Virginia Parkways Authority, FOR AN AMOUNT EQUAL TO FIVE PERCENT (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) OF THE AMOUNT OF THE PROPOSAL OR $2,000 WHICHEVER IS THE GREATER, and must be delivered at the place designated above on or before the day and hour named.

Pursuant to Bureau of Employment Programs (BEP) Rule 96 C.S.R.1 Implementation Rule dated June 30, 2000, Contractors requesting plans must furnish their FEIN Number, company name and any name they are doing business as. Firms listed in the BEP Default Directory will not be issued Bidding Documents.

The Authority reserves the right to reject any and all Proposals submitted, and to waive any or all formalities in bidding, as it may deem in its best interest.

The Authority strongly encourages minority owned and women owned businesses to submit proposals for this contract.

The WVPA is an Equal Opportunity Employer. All firms submitting proposals must certify that they practice Equal Employment Opportunities.(605909)
Class: 983 Gazette Legal Ads Last appeared: 08-06-2015

92.WEST VIRGINIA
PARKWAYS AUTHORITY

ADVERTISEMENT
FOR PROPOSALS
Sealed proposals will be received by the West Virginia Parkways Authority for:CONTRACT DM-1-16
DRAINAGE
MITIGATION
MERCER COUNTY
This contract is located in Mercer County.

All work under this contract shall be completed by November 30, 2015.

Proposals will be received at the office of the West Virginia Parkways Authority, Administration Building, Charleston, West Virginia until 3:00 PM August 20, 2015, at which time and place said proposals will be publicly opened and read. If proposals are to be mailed via the U.S. Postal Service regular mail, they must be addressed to the West Virginia Parkways Authority, P.O. Box 1469, Charleston, WV 25325. This mail is picked up by the Authority once a day between 7:00 AM and 8:00 AM. However, Express Mail One Day Service, Federal Express, United Parcel Service (UPS), etc., must be sent to the West Virginia Parkways Authority, 3310 Piedmont Road, Charleston, WV 25306. It shall be the bidder’s responsibility to determine his transmittal method such that his bid will arrive in the Authority’s office prior to the scheduled bid opening. Bids received in the Authority’s office after the scheduled opening will be returned to the bidder unopened.

Prospective bidders must be prequalified in accordance with SECTION 102.1 of the WVDOH Standard Specifications. Contract Documents without Standard Specifications or other referenced standards can be obtained from HNTB, #3 Mission Way, Scott Depot, WV 25560, Phone (304) 760-1833, Email [email protected].

Proposals must be made upon the forms furnished by the Authority in the manner designated in the specifications, and must be enclosed in sealed envelopes bearing the name and address of the bidder and the number of the contract on the outside, and must be accompanied by a CASHIER’S or CERTIFIED CHECK or BID BOND in favor of the West Virginia Parkways Authority, FOR AN AMOUNT EQUAL TO FIVE PERCENT (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) OF THE AMOUNT OF THE PROPOSAL OR $2,000 WHICHEVER IS THE GREATER, and must be delivered at the place designated above on or before the day and hour named.

Pursuant to Bureau of Employment Programs (BEP) Rule 96 C.S.R.1 Implementation Rule dated June 30, 2000, Contractors requesting plans must furnish their FEIN Number, company name and any name they are doing business as. Firms listed in the BEP Default Directory will not be issued Bidding Documents.

The Authority reserves the right to reject any and all Proposals submitted, and to waive any or all formalities in bidding, as it may deem in its best interest.

The Authority strongly encourages minority owned and women owned businesses to submit proposals for this contract.

The WVPA is an Equal Opportunity Employer. All firms submitting proposals must certify that they practice Equal Employment Opportunities.(606069)
Class: 983 Gazette Legal Ads Last appeared: 08-11-2015

93.FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

ORDER OF
PUBLICATION
IN THE MATTER OF:
Avon S. Mitchell

v.

Lashonda Mitchell &
Willie (Unknown Last
Name)

Civil Action #: 15-FIG-149

The object of this suit is to obtain Guardianship of an infant

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the Petitioners used due diligence to ascertain the whereabouts of Lashonda Mitchell & Willie ( Unknown Last Name) without effect is here by ordered that Lashonda Mitchell & Willie (Unknown Last Name) serve upon Carlies & Barbara Womac whose address is 114 A Delaware Ave., Charleston, WV 25302 an answer, including any related counter claim or defense you may have to the petition filed in this action on or before September 7, 2015. If you fail to do so, thereafter, upon proper hearing, being held September 9, 2015 at 10:00 am Petitioners will be granted relief demanded in their Petition being appointed Guardians of said infant.

A copy of said Petition can be obtained from the undersigned Clerk at her office.

Entered by the Clerk of Said Court August 5, 2015.Cathy S. Gatson
Clerk of Court
(606711)
Class: 983 GazetteMail Legal Ads Last appeared: 08-08-2015

94.WEST VIRGINIA HEALTH CARE AUTHORITY
CERTIFICATE OF NEED
100 Dee Drive
Charleston, West Virginia 25311-1600

August 3, 2015

LEGAL NOTICE
James L. Pitrolo, Jr., Chairman, West Virginia Health Care Authority, announces the following Certificate of Need activities for the week ending July 31, 2015.AMENDED LETTER OF INTENT RECEIVED
July 29, 2015 – The Heritage Center at Lesage, Inc., Lesage, Cabell County, CON File #15-2-10403-X/BH, for the development of a non-medical post detox residential drug and alcohol rehabilitation and recovery treatment program for adults over the age of twenty-one to be located at 8300 Ohio River Road, Lesage, Cabell County.

The amendment is the capital expenditure from $150,000 to $465,000.REQUESTS FOR EXEMPTION RECEIVED
FOR HOSPITAL AMBULATORY
HEALTH CARE FACILITIES
July 30, 2015 – Charleston Hospital, Inc. d/b/a Saint Francis Hospital and Herbert J. Thomas Memorial Association, South Charleston, Kanawha County, CON File #15-3-10564-X, for the development of a hospital ambulatory health care facility in Kanawha County. The facility is located at 4610 Kanawha Avenue, S.W., Suite 401, South Charleston, Kanawha County. The office will be staffed by five (5) or less urology physicians.

The capital expenditure associated with the project is $90,000.

Any affected person may oppose this proposal by submitting a letter stating the reason for opposition within thirty (30) days of the first date of publication of the public notice to: Marianne Kapinos, General Counsel, West Virginia Health Care Authority, Certificate of Need Program, 100 Dee Drive, Charleston, West Virginia 25311-1600.

The last date upon which an affected party may file a letter of opposition to this proposal is September 8, 2015.

July 30, 2015 – Summers County ARH Hospital, Hinton, Summers County, CON File #15-1-10565-X, for the acquisition of a rural health clinic in Summers County. The facility is located at 197 Pleasant St., Hinton, Summers County. The office will be staffed by one family physician, one physician assistant and one nurse practitioner.

The capital expenditure associated with the project is $50,000.

Any affected person may oppose this proposal by submitting a letter stating the reason for opposition within thirty (30) days of the first date of publication of the public notice to: Marianne Kapinos, General Counsel, West Virginia Health Care Authority, Certificate of Need Program, 100 Dee Drive, Charleston, West Virginia 25311-1600.

The last date upon which an affected party may file a letter of opposition to this proposal is September 10, 2015.EXPEDITED APPLICATIONS RECEIVED
July 27, 2015 – Acuity Specialty Hospital – Ohio Valley, L.P., Steubenville, Ohio, CON File #15-101-10549-H, for the addition of sixteen (16) beds at its existing 13 bed Long Term Acute Care Hospital within Wheeling Hospital, Wheeling, Ohio County; capital expenditure: $1,000,000.

July 27, 2015 – Bio-Medical Applications of West Virginia, Inc. d/b/a Fresenius Medical Care Upshur County, Raleigh, North Carolina, CON File #15-7-10551-R, for the establishment of a new eight (8) station dialysis facility in Buckhannon, Upshur County; capital expenditure: $1,394,113.

July 28, 2015 – Appalachian Regional Healthcare, Inc., Lexington, Kentucky, CON File #15-1-10555-H, for the development of Primary Therapeutic Cardiac Catheterization Services (Primary PCI) at Beckley Appalachian Regional Hospital located in Beckley, Raleigh County; capital expenditure: $373,100.APPLICATIONS DECLARED
COMPLETE AND UNDER REVIEW
An application declared complete is one in which there is sufficient information for the Authority to make an informed decision. It does not mean that the approval of the application is warranted.EXPEDITED APPLICATIONS
July 28, 2015 – Bridgeport Health Care Center, LLC and Buckthorn Holding, LLC, Charleston, Kanawha County, CON File #15-6-10552-NH, for the acquisition of the real estate and licensed operations of Emeritus at the Heritage, a 51 bed nursing home located in Bridgeport, Harrison County; capital expenditure: $2,800,000.

July 29, 2015 – Acuity Specialty Hospital – Ohio Valley L.P., Steubenville, Ohio, CON File #15-10-10549-H, for the addition of sixteen (16) beds at its existing 13 bed Long Term Acute Care Hospital within Wheeling Hospital, Wheeling, Ohio County; capital expenditure: $1,000,000.

July 29, 2015 – Acuity Specialty Hospital – Ohio Valley L.P., Steubenville, Ohio, CON File #15-11-10550-H, for the addition of eight (8) beds at its existing 20 bed Long Term Acute Care Hospital within Weirton Medical Center, Weirton, Brooke County; capital expenditure: $1,000,000.

July 29, 2015 – Fairhaven HoldCo, LLC, Fairhaven OpCo, LLC and Fairhaven RealCo, LLC, Chicago, Illinois, CON File #15-2-10553-NH, for the acquisition of Fairhaven Rest Home, a 41 bed nursing home located in Huntington, Cabell County; capital expenditure: $2,105,075.

July 31, 2015 – Appalachian Regional Healthcare, Inc., Lexington, Kentucky, CON File #15-1-10555-H, for the development of Primary Therapeutic Cardiac Catheterization Services (Primary PCI) at Beckley Appalachian Regional Hospital located in Beckley, Raleigh County; capital expenditure: $373,100.

July 31, 2015 – Bio-Medical Applications of West Virginia, Inc. d/b/a Fresenius Medical Care Upshur County, Raleigh, North Carolina, CON File #15-7-10551-R, for the establishment of a new eight (8) station dialysis facility in Buckhannon, Upshur County; capital expenditure: $1,394,113.

The review cycle for the above-referenced projects is as follows:

August 8, 2015 – Review cycle begins;

August 18, 2015 – Last date for an affected person to present reasons why the applicant should complete a standard application to the Authority;

September 8, 2015 – Last date for an affected person to request a public hearing on the project. If a public hearing is requested, notice of time and place will be given in the Saturday editions of the Charleston Gazette and the Charleston Daily Mail, as well as the State Register;

September 9, 2015 – If no public hearing is requested, the file will close and no further information or evidence will be accepted by the Authority and no further contact with the Authority regarding the substance of the application will be permitted;

October 13, 2015 – Decision on the project will be issued by the Authority.HEARING NOTICE
The Administrative Hearing and Prehearing Conference have been CONTINUED in the following matter:

July 28, 2015 – St. Joseph’s Hospital of Buckhannon, Buckhannon, Upshur County, CON File #15-7-10388-P, for the development of an ambulatory health care facility in Elkins, Randolph County, for the provision of pre and post-obstetrical care and gynecological services in an office-based certified nurse mid-wife practice to the residents of Pocahontas, Randolph and Tucker counties.

The prehearing conference and administrative hearing in the above-referenced matter will be rescheduled at a later date. A Notice of Prehearing Conference and Administrative Hearing will be issued at that time to all interested/affected parties. The hearing will be held in the offices of the Health Care Authority, 100 Dee Drive, Charleston, West Virginia 25311-1600, unless otherwise noted.ORDER ISSUED
July 27, 2015 – St. Joseph’s Hospital of Buckhannon, Buckhannon, Upshur County, CON File #15-7-10388-P, for the development of an ambulatory health care facility in Elkins, Randolph County, for the provision of pre and post-obstetrical care and gynecological services in an office-based certified nurse mid-wife practice to the residents of Pocahontas, Randolph and Tucker counties.

It is ORDERED that the application in this matter is STAYED effective July 23, 2015.AMENDED PROJECTS
DETERMINED NOT REVIEWABLE
July 27, 2015 – Imagine Medispa, Charleston, Kanawha County, CON File #15-1-10512-X, for the complete relocation of its facility located in Beckley, Raleigh County, from 321 Dry Hill Road to 339 Rural Acres Drive; capital expenditure: $2,650.

The amendment was change in capital expenditure from $0 to $2,650.

July 27, 2015 – Imagine Medispa, Charleston, Kanawha County, CON File #15-1-10513-X, for the complete relocation of its facility located in Princeton, Mercer County, from 1033 Stafford Drive to 116 South 7th Street; capital expenditure: $13,000.

The amendment was change in capital expenditure from $0 to $13,000.

July 27, 2015 – Imagine Medispa, Charleston, Kanawha County, CON File #15-2-10514-X, for the complete relocation of its facility located in Barboursville, Cabell County, from 3018 Champion Drive to 6354 US Route 60 East, Suite 4; capital expenditure: $1,125.

The amendment was change in capital expenditure from $0 to $1,125.PROJECT DETERMINED NOT REVIEWABLE
July 29, 2015 – Potomac Highlands Guild, Inc., Petersburg, Grant County, CON File #15-8-10548-X, for the complete relocation of its Hardy County Clinic Office from 139 North Main Street to 79 Robert C. Byrd Industrial Park Road in Moorefield; no capital expenditure.CERTIFICATE OF NEED APPROVALS ISSUED
July 28, 2015 – Reynolds Memorial Hospital, Glen Dale, Marshall County, CON File #15-10-10454-X/BH, for the development of inpatient medical withdrawal management services on campus; no capital expenditure.

July 29, 2015 – Community Action Southwest (CASW), Washington, Pennsylvania, CON File #14-6-10350-PV/A, for a merger with Try-Again Homes, Inc. (TAHWV), a non-profit, tax exempt provider of children and adolescent foster care services, including behavioral health services located in Fairmont, Marion County and Parkersburg, Wood County in West Virginia. TAHWV will be dissolved, with CASW as the surviving entity; capital expenditure: $15,000.NOTICE OF SUBSTANTIAL COMPLIANCE
The following project has been implemented in substantial compliance with the decision issued in this matter and the case file is now closed:

July 29, 2015 – Oak Health and Rehabilitation Center, Inc., Oak HRC Fairmont LLC and Oak HRC 2 LLC, Bala Cynwyd, Pennsylvania, CON File #14-6-10367-A, for the acquisition of the licensed operations of the Arbors at Fairmont, a 120 bed nursing home located in Fairmont, Marion County; capital expenditure:

Further information may be obtained on any of the above-referenced projects by contacting Timothy E. Adkins, Director, Certificate of Need Division.(606596)
Class: 983 GazetteMail Legal Ads Last appeared: 08-08-2015