INVITATION FOR BIDS CHARLESTON- KANAWHA HOUSING HVAC RENOVATIONS ORCHARD MANOR Contract 24-01 CHARLESTON-KANAWHA HOUSING, Charleston, West Virginia will receive sealed bids for its ORCHARD MANOR HVAC RENOVATION PROJECT until 2:00 PM EST on the 28th day of March, 2024, at which time and place all bids will be publicly opened and read aloud. The work consists of but is not limited to installation of new Air Conditioning Systems, including outdoor condensing unit, line sets, interior A-Coil, thermostats, duct cleaning and an alternate to replace the existing gas furnace with a new electric furnace, etc. and all associated work for a complete project. Contractors shall have 5 years minimum experience in the work to be performed. Bids can be hand delivered to: Charleston – Kanawha Housing 1525 Washington St. West Charleston, West Virginia 25387 Attn: Mr. Robert Shamblin Director of Facilities Maintenance or mailed to: Charleston-Kanawha Housing Post Office Box 86 Charleston, West Virginia 25321-0086 Attn: Mr. Robert Shamblin Director of Facilities Maintenance Copies of the Bid Documents may be obtained at the office of the Architect, ADKINS DESIGN, Inc. 1522 Clearview Heights, Charleston, WV 25312 (304) 984-2415, upon payment of a non-refundable $50.00. Each bidder is required to purchase one set of project documents to insure that they possess and maintain the most current and complete set of drawings, Project Manual and addenda. Examination of Plans, Project Manual and Addenda at plan rooms are not guaranteed to be the latest issues. Bidder may also examine bid documents at the following locations Charleston – Kanawha Housing Charleston-Kanawha Housing 1525 Washington St. West Charleston, West Virginia 25387 Attn: Mr. Robert Shamblin Kanawha Valley Builders Association http: ww.kvba.com Adkins Design, Inc. 1522 Clearview Heights Charleston, West Virginia 25312 Attn: Larry Adkins, AIA McGraw Hill Construction-Dodge Reports On-Line Plan room- http:/www.fwdodge.com lans/l Construct Connect https:/www.constructconnect.com fm] Contractors Association of West Virginia http:/www.cawv.org A Pre-bid Conference will be held at 10:00 AM on EST the 12th day of March, 2024 at the Administrative Office Building located at 1525 Washington Street, West, Charleston, West Virginia. The scope and details of the proposed work will be covered. Attendance is recommended. Site visitation is mandatory and will be conducted immediately after the pre-bid meeting. Charleston-Kanawha Housing reserves the right to reject any or all bids or to waive any informalities in the bidding process. The Housing Authority is an Equal Opportunity Employer and does not discriminate on the basis of race, color, creed, national origin, sex, familial status, disability, religion or age. A certified check or bank draft, payable to Charleston-Kanawha Housing Par Value U. S. Government bonds or a satisfactory bid bond executed by the acceptable sureties in an amount equal to five percent of the bid shall be submitted with each bid. CHARLESTON- KANAWHA HOUSING By: Mark E. Taylor Chief Executive Officer AN EQUAL HOUSING OPPORTUNITY LC-169297 02-27,28/l 03-05,06;2024
Legal Notices
In the Circuit Court of Cabell County, West Virginia Case No. CC-06-2023-C-324 Judge Alfred E. Ferguson WESBANCO BANK INC, Plaintiff, V. Wesley Sutphin, Defendant Order of Publication ON THE 22nd DAY OF FEBRUARY, 2024, Wesbanco Bank, Inc., the Plaintiff herein, by counsel, Andrew R. Thalman, Esq., and the law firm of Phillips, Gardill, Kaiser & Altmeyer, PLLC, filed its Affidavit Pursuant to W.Va. R. Civ. P. 4(e)(1) requesting an Order of Publication against Defendant WESLEY SUTPHIN. WHEREFORE, as mandated by W.Va. R. Civ. P. 4(e)(1), the requested Order of Publication is hereby ISSUED, as follows: TO WESLEY SUTPHIN, DEFENDANT: 1. The title of the civil action at bar is Wesbanco Bank, Inc. v. Wesley Sutphin, Defendant, Civil Action No. 2023-C-324; 2. The object of the pending suit is the collection of certain monies owed to Wesbanco Bank, Inc. by Wesley Sutphin, by virtue of a Retail Installment Contract between Wesley Sutphin and Wesbanco Bank, Inc.; 3. The name, address and telephone number of the Plaintiff’s attorney is Andrew R. Thalman, Esq., Phillips, Gardill, Kaiser & Altmeyer, PLLC, 61 Fourteenth Street, Wheeling, WV 26003, (304) 232-6810; 4. A copy of the Complaint made in this civil action may be obtained from the Circuit Court Clerk of Cabell County, West Virginia; 5. The Defendant, Wesley Sutphin, must appear and defend on or before April 15 2024 a date which is not fewer than 30 days after the first publication hereof, otherwise a judgment by default will be rendered against you at any time thereafter. s Alfred E. Ferguson Circuit Court Judge 6th Judicial Circuit LH-169356 02-27,03-05;2024