Sept. 1, 2015, Charleston Gazette-Mail Legal Advertisements

1.
ADVERTISEMENT
FOR BIDS

The City of South Charleston, South Charleston, WV will receive bids for a new Fire Station No. 1 until 1:30 p.m., local prevailing time on the 15th day of September, 2015, at the office of South Charleston City Hall, Council Chambers, located at Fourth Avenue and D Street, South Charleston, WV, at which time and place all bids will be publicly opened and read aloud. Bids will be received for the following packages:

BP#2 –
General Construction

BP#5 –
Automatic Fire
Suppression

BP#3 –
Mechanical

BP#6 –
Casework

BP#4 –
Electrical
BP#7 –
Combination

A MANDATORY Pre-Bid Conference has been scheduled for August 26, 2015, at 10:00 a.m. at the office of South Charleston City Hall, Council Chambers, located at Fourth Avenue and D Street, South Charleston, WV. A site visit will be conducted following the meeting.

The contract documents including plans and specifications are on file at the Office of the City of South Charleston; Office of Williamson Shriver Architects, Inc., 717 Bigley Avenue, Charleston, WV 25302; Ohio Valley Construction Employer’s Council, Inc., Wheeling, WV; Contractor’s Association of WV, Charleston, WV; Kanawha Valley Builders Association, Charleston, WV; Construction Employers Association of NC WV, Fairmont, WV; Parkersburg/Marietta Contractors Association, Parkersburg, WV.

Copies of the documents may be obtained by Prime Contractors by depositing $200.00 with the Architect for each set of documents so obtained. Prime Contractors may obtain two (2) sets of documents. The amount of the deposit will be refunded to each actual bidder who returns the plans and specifications in good condition within ten (10) days after the date of opening bids. The deposits will be refunded if documents are returned in good condition; otherwise, deductions will be made in an amount not to exceed the actual cost of reproduction. Those who do not submit bids will forfeit deposit unless sets are returned in good condition at least five (5) days before the bid date. Subcontractors and suppliers may obtain documents at their expense from Charleston Blueprint, Charleston, WV, 304-343-1063. These sets or partial sets of documents are not refundable.

Each Bidder must be registered with the West Virginia Department of Tax and Revenue prior to the time and date for Receipt of Bids in order for his Bid to be considered. Each Bidder’s registration certificate number shall be written in the space provided on the Form of Proposal. The successful bidder must have or apply for a License in the City of South Charleston.

All bidders are required to be licensed to perform work in the State prior to submitting a bid for this project as required by Chapter 21, Article 11, of the Code of West Virginia. Each Bidder’s Contractor license number shall be written in the space provided on the Form of Proposal. All bidders will be required to meet all City, State Fire Codes, Fire Building Codes and All OSHA regulations pertaining to the construction of the new building.

The City of South Charleston, South Charleston, WV affords a 2{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c} competitive advantage to bidders with mercantile establishments situated within the City.

The City of South Charleston, South Charleston, WV reserves the right to reject any or all bids and to waive any informalities in the bidding.

A satisfactory bid bond furnished by a solvent surety company authorized to do business in the State of West Virginia, in an amount equal to five (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total amount of bid, payable to the City of South Charleston, shall be submitted with each Bid. The successful bidder will be required to furnish a satisfactory Performance Bond and Payment Bond and the fee for the same shall be included in their bid.

No bid may be withdrawn after the scheduled closing time for the receipt of bids for at least thirty (30) days.
THE CITY OF
SOUTH CHARLESTON
Frank A. Mullens,
Mayor
(607205)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

2.
ADVERTISEMENT
FOR BIDS

The City of South Charleston, South Charleston, WV will receive bids for Bid Package #1 Demolition Work for a new Fire Station No. 1 until 1:30 p.m., local prevailing time on the 3rd day of September, 2015, at the office of South Charleston City Hall, Council Chambers, located at Fourth Avenue and D Street, South Charleston, WV, at which time and place all bids will be publicly opened and read aloud

Copies of the documents may be obtained by Prime Contractors by depositing $200.00 with the Architect for each set of documents so obtained. Prime Contractors may obtain two (2) sets of documents. The amount of the deposit will be refunded to each actual bidder who returns the plans and specifications in good condition within ten (10) days after the date of opening bids. The deposits will be refunded if documents are returned in good condition; otherwise, deductions will be made in an amount not to exceed the actual cost of reproduction. Those who do not submit bids will forfeit deposit unless sets are returned in good condition at least five (5) days before the bid date. Other Subcontractors and suppliers may obtain documents at their expense from Charleston Blueprint, Charleston, WV, 304-343-1063. These sets or partial sets of documents are not refundable.

The City of South Charleston, South Charleston, WV reserves the right to reject any or all bids and to waive any informalities in the bidding.

No bid may be withdrawn after the scheduled closing time for the receipt of bids for at least thirty (30) days.
THE CITY OF SOUTH
CHARLESTON
Frank A. Mullens,
Mayor
(607200)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

3.
ADVERTISEMENT
FOR BIDS
For Replacement of
Chain Link Fence

Sealed proposals marked “Crum PSD – Tank Fence Repair Project” will be received at the Crum Public Service District (CPSD) Office; 414 Crum Road; Crum, WV 25669, until 10:00 a.m., Wednesday, September 9th, 2015, for replacement of approximately 120 LF of chain link fence. A Pre-Bid meeting will be held at the Crum PSD office at 10:00 a.m. on Wednesday, September 2nd, 2015. This project will include the temporary stabilization of the hillside adjacent to the chain link fence to allow the fence to be safely replaced. Work shall be as specified in the details/specifications prepared by E.L. Robinson Engineering Company.

Specifications and proposal forms may be obtained at the E.L. Robinson Engineering Company Office, 5088 Washington Street, West; Cross Lanes, WV 25313. Phone – 304-776-7473 (ext. 235)

All bids must be on the proposal forms furnished.

A certified check, cashier’s check or bidder’s bond shall accompany each bid in an amount equal to five percent (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the bid, made payable to the Crum Public Service District, which shall be forfeited to the District in the event the successful bidder fails to enter into a contract with the District.

The Crum PSD reserves the right to reject any and all bids and to waive informalities.
(607783)

Class: 983 Gazette Legal Ads Last appeared: 08-26-2015

4.
ADVERTISEMENT FOR BIDS

The City of South Charleston, South Charleston, WV will receive bids for Owner Purchased Materials for Fire Station No. 1 until 1:30 p.m., local prevailing time on the 15th day of September, 2015, at the office of South Charleston City Hall, Council Chambers, located at Fourth Avenue and D Street, South Charleston, WV, at which time and place all bids will be publicly opened and read aloud. Bids will be received for the following packages:

Package A – Masonry
(Bid Bond and Supply
Bond will be required)

Package B – Metals (Bid Bond and Supply
Bond will be required)

Package C – Openings
and Finishes
(Bid Bond and Supply
Bond will be required)

Package D – Bay Doors (Bid Bond, Performance
& Payment Bond will be
required)
Package E – Aluminum
Openings
(Bid Bond and Supply
Bond will be required)

Package F – Electrical
(Bid Bond and Supply
Bond will be required)

Copies of the documents may be obtained by Material Suppliers and Prime Contractors by depositing $200.00 with the Architect for each set of documents so obtained. The amount of the deposit will be refunded to each actual bidder who returns the plans and specifications in good condition within ten (10) days after the date of opening bids. The deposits will be refunded if documents are returned in good condition; otherwise, deductions will be made in an amount not to exceed the actual cost of reproduction. Those who do not submit bids will forfeit deposit unless sets are returned in good condition at least five (5) days before the bid date. Bidders may obtain documents at their expense from Charleston Blueprint, Charleston, WV, 304-343-1063. These sets or partial sets of documents are not refundable.

All applicable bidders are required to be licensed to perform work in the State prior to submitting a bid for this project as required by Chapter 21, Article 11, of the Code of West Virginia. Applicable Bidder’s Contractor license number shall be written in the space provided on the Form of Proposal. All applicable bidders will be required to meet all City, State Fire Codes, Fire Building Codes and All OSHA regulations pertaining to the construction of the new building.

The City of South Charleston, South Charleston, WV reserves the right to reject any or all bids and to waive any informalities in the bidding.

All bidders, for the named Packages, shall furnish a satisfactory Bid Bond by a solvent surety company authorized to do business in the State of West Virginia, in an amount equal to five (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total amount of bid, payable to the City of South Charleston, shall be submitted with each Bid. The successful bidder for Package D will be required to furnish a satisfactory Performance Bond and Payment Bond and the fee for the same shall be included in their bid. All other Packages will be required to furnish a satisfactory Supply Bond and the fee for the same shall be included in their bid

No bid may be withdrawn after the scheduled closing time for the receipt of bids for at least thirty (30) days.
THE CITY OF
SOUTH CHARLESTON

Frank A. Mullens,
Mayor
(608129)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

5.
Announcement of Bid acceptance on Oil and Gas Resources beneath the following areas, leasing for production.

The state of West Virginia, Department of Commerce Division of Natural Resources, offers by bid award the exclusive right and privilege to lease for production purposes, certain of the State’s oil and gas resources underlying the following properties:

1. 32.08 acres, Lewis Wetzel Wildlife Management Area, Wetzel County;

2. 13.25 acres, Underwood Wildlife Management Area, Marshall Wetzel County

3. 54.56 acres, Burches Run Wildlife Management Area, Marshall County, West Virginia.

4. Ohio River Mile point 117 to 118, Marshall County, West Virginia.

5. 6.39 acres, Middle Island Creek, Tyler County, West Virginia

Interested parties may submit their interest in the subject properties electronically by visiting www.wvmineraldevelopement.com or write for a copy of the Division of Natural Resources bid procedure and prospectus package at the following address
WEST VIRGINIA
DIVISION OF NATURAL
RESOURCES
OFFICE OF LAND
AND STREAMS
324 4TH AVENUE,
ROOM 200
SOUTH CHARLESTON,
WEST VIRGINIA 25303

The bidding procedure and prospectus package generally describes the area to be leased, including location maps, contains a list of specifically required information of each bidder and sets out the minimum bid requirements. The DNR must receive bids from interested parties for these properties no later than 3:30 pm on September 10, 2105.
(608292)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

6.
CIRCUIT COURT OF
KANAWHA COUNTY,
WEST VIRGINIA

AEP WEST VIRGINIA
TRANSMISSION
COMPANY, INC.
a West Virginia corporation,
Petitioner,

vs.
Civil Action
No. 15-P-337
Honorable
Carrie L. Webster

FRANCES ROUSE,
UNKNOWN HEIRS OF
MARY DEANNA FRAME,
DAVID LAWRENCE,
JEFF LAWRENCE,
JANNA BERLIN,
and JOHN RUTHERFORD,
SHERIFF OF
KANAWHA COUNTY,
WEST VIRGINIA,
Respondents.

LEGAL NOTICE
OF PUBLICATION
AND NOTICE TO
APPEAR ON
SEPTEMBER 17, 2015

TO:
RESPONDENTS,
FRANCES ROUSE,
UNKNOWN HEIRS OF
MARY DEANNA FRAME,
DAVID LAWRENCE,
JEFF LAWRENCE,
JANNA BERLIN, and
JOHN RUTHERFORD,
SHERIFF OF
KANAWHA COUNTY,
WEST VIRGINIA.

Notice is hereby given to Frances Rouse, Unknown Heirs Of Mary Deanna Frame, David Lawrence, Jeff Lawrence, Janna Berlin, and John Rutherford, Sheriff of Kanawha County, West Virginia, that a Petition for Condemnation and for Right of Entry has been filed in the Circuit Court of Kanawha County, West Virginia and is known as Civil Action No. 15-P-337, and styled AEP West Virginia Transmission Company, Inc., a West Virginia corporation vs. Frances Rouse, Unknown Heirs Of Mary Deanna Frame, David Lawrence, Jeff Lawrence, Janna Berlin, and John Rutherford, Sheriff of Kanawha County, West Virginia.

Said Petition for Condemnation and for Right of Entry under the West Virginia laws of eminent domain seeks condemnation and right of entry on behalf of AEP West Virginia Transmission Company, Inc. for property in Jefferson District, Kanawha County, West Virginia, identified as Tax Map 16, Parcel 35, and also being further described as that certain tract or parcel of land owned by the Marino heirs lying on the Mud Fork of Davis Creek in a Deed to Lydia Mae Marino and Frank Marino from Villa Marino, Inc. dated October 22, 1964, of record in Deed Book No. 1420, at page 725.

Frances Rouse, Unknown Heirs Of Mary Deanna Frame, David Lawrence, Jeff Lawrence, Janna Berlin, and John Rutherford, Sheriff of Kanawha County, West Virginia are hereby notified a copy of said Petition for Condemnation and for Right of Entry may be obtained from the Kanawha County Circuit Clerk’s office at the Kanawha County Judicial Annex, 111 Court Street, Charleston, West Virginia, 25301, for the purposes of appearing and defending. The Petition for Condemnation and for Right of Entry may also be obtained from the attorney for AEP West Virginia Transmission Company, Inc., Marsha W. Kauffman, 700 Virginia Street East, Suite 400, Charleston, West Virginia, 25301.

Frances Rouse, Unknown Heirs Of Mary Deanna Frame, David Lawrence, Jeff Lawrence, Janna Berlin, and John Rutherford, Sheriff of Kanawha County, West Virginia are further notified that a hearing on the said Petition for Condemnation and for Right of Entry will occur on September 17, 2015, at 2:30 p.m., in the Circuit Court of Kanawha County, West Virginia, before the Honorable Carrie L. Webster. You may appear for hearing as stated above, and are notified that any failure to appear may result in the waiver of any defenses or claims, if any, you may have.
ROBINSON &
McELWEE PLLC

Marsha W. Kauffman
(WV State Bar #6979)
Jeffrey A. Kimble
(WV State Bar #4928)
Robinson & McElwee PLLC
Post Office Box 1791
Charleston,
West Virginia 25326
(304) 347-8330
Attorneys for Petitioner
(608401)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

7.
CITY OF CHARLESTON
ADVERTISEMENT
FOR BIDS
STORM SEWER
REHABILITATION
PROJECT
CURED IN PLACE
PIPE (CIPP) LINING,
VARIOUS LOCATIONS
PROJECT NUMBER
E3 08/15-094

The City of Charleston, West Virginia will receive sealed bids for the installation of CIPP within storm sewer pipes at various locations until 10:00 a.m., Wednesday, September 16, 2015 in the City Manager’s Office on the first floor of City Hall. Immediately following the scheduled closing time for the receipt of bids, all proposals which have been submitted in accordance with the project requirements will be publicly opened and read aloud. The City reserves the right to reject any or all bids, to waive any informalities in bidding, and to accept the bid considered to be in its best interest from the lowest responsible bidder. All interested parties are invited to attend the bid opening.

Plans and specifications may be obtained from the City Manager’s Office. Plans and specifications may be examined at the following locations:

Contractor’s Association
of West Virginia
2114 Kanawha Blvd.,
East
Charleston, WV 25311 City of Charleston
City Manager’s Office
501 Virginia St., East;
Room 101
Charleston, WV 25301

The Contractor will be required to comply with all applicable Federal requirements pertaining to Affirmative Action, Employment Opportunity, Federal Labor Standards, Copeland Anti-Kickback Act, and DBE/WBE goals as described in the Specifications.

A mandatory pre-bid conference for the purpose of discussing and clarifying the project plans and specifications will be held at 10:00 a.m. on Wednesday, September 9, 2015, in the City Engineer’s Office located at 114 Dickinson Street.

All bidders shall include a cashier’s or certified check or a satisfactory bid bond furnished by a solvent surety company authorized to do business in the state of West Virginia in an amount equal to five percent (5{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total amount of the bid. A West Virginia Contractor’s License Number must be included in the bid submission.

The successful bidder will be required to furnish Performance and Payment Bonds each equal to one-hundred percent (100{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the contract amount; the fee for all bonds shall be included in the bid proposal.

No bid may be withdrawn after the scheduled closing time for the receipt of bids for at least thirty (30) days.
(608785)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

8.
FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

ORDER OF
PUBLICATION

Bobbi J. Johnson
Plaintiff(s)

Nicholas Collins
Defendant(s)

Civil Action #: 09-D2766

The object of this suit is to obtain a Modification

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the Defendant(s) used due diligence to ascertain the whereabouts of Bobbi J. Johnson without effect is here by ordered that Bobbi J. Johnson serve upon Nicholas Collins, plaintiff, whose address is 801 Woodrow Wilson Place, Apt B, Charleston, WV 25302, an answer, including any related counter claim or defense you may have to the petition filed in this action on or before September 23, 2015. If you fail to do so, thereafter, upon proper hearing being held 9/23/15 at 9:30 a.m., and trial, may be taken against you for the relief demanded in the complaint.

A copy of said Petition can be obtained from the undersigned Clerk at her office.

Entered by the Clerk of Said CourtAugust 12, 2015.
Cathy S. Gatson
Clerk of Court
(607944)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

9.
FAMILY COURT OF KANAWHA COUNTY, WEST VIRGINIA

ORDER OF
PUBLICATION

IN THE MATTER OF:

Shirley Hudson

Civil Action # 15-FIG-191

James Bostic
Mercadies Bostic

The object of this suit is to obtain Guardianship of an infant

TO THE ABOVE NAMED DEFENDANT:
It appearing by affidavit filed in this action that the Petitioner used due diligence to ascertain the whereabouts of James M. Bostic & Mercadies Bostic without effect is here by ordered that James M. Bostic & Mercadies Bostic serve upon Shirley Hudson, whose address is 404 Wiseacer Dr., Charleston, WV 25311 an answer, including any related counter claim or defense you may have to the petition filed in this action on or before September 26, 2015. If you fail to do so, thereafter, upon proper hearing. Petitioner will be granted relief demanded in their Petition being appointed Guardians of said infant.
A copy of said Petition can be obtained from the undersigned Clerk a her office.
Entered by the Clerk of Said Court August 24, 2015.
Cathy S. Gatson
Clerk of Court
(608456)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

10.
IN THE CIRCUIT
COURT OF
KANAWHA COUNTY,
WEST VIRGINIA

IN RE:

SHIRLEY GRAY, AS ADMINISTRATRIX OF THE ESTATE OF LANAVIA GRAY Petitioner.
MISC. ACTION NO. 15-P-305
JUDGE: Bloom

NOTICE OF HEARING
FOR PETITION FOR
APPROVAL OF
WRONGFUL DEATH
SETTLEMENT

TO:Shirley Ann Gray;
Jessie “Stevie” Gray;
Shenika Holmes;
Swanetta NaShay Holmes;
Sidney Antoine Holmes; Raven Somone Holmes; Ta’Naija Seirra Holmes; Dementrius Tyrone
Wesley, Jr.; and Any
and All Other Uknown
Heirs or Beneficiaries of
the Estate of Lanavia Gray.

PLEASE TAKE NOTICE that Petitioner’s “PETITION FOR APPROVAL OF WRONGFUL DEATH SETTLEMENT” will be brought on for hearing before the Honorable Louis “Duke” Bloom, Judge of the Circuit Court of Kanawha County, located at the Kanawha County Judicial Building, 111 Court Street, Charleston, West Virginia, on Wednesday, September 9, 2015 at 10:00 a.m., or as soon thereafter as may be heard. Petitioner, Shirley Gray, by and through her legal counsel, has negotiated a proposed settlement of the Estate’s claims against Adam Lee and Progressive Insurance for a confidential sum of money, only to be disclosed by the Court, upon its sound judgment. This settlement is a final settlement of all claims of the Estate against Adam Lee and Progressive Insurance in this matter. Upon approval of the settlement by the Court and the subsequent execution of the settlement documents including a release and dismissal order, any other claims the Petitioner, the Estate, or the heirs of the Estate of Lanavia Gray may have against Adam Lee or Progressive Insurance related to the death of Lanavaia Gray are forever barred and may no longer be pursued by them. All known individual heirs and beneficiaries referenced above as well as any and all other unknown heirs and/or beneficiaries of the Estate of Lanavia Gray are invited to attend the scheduled hearing in person to protect their individual interests in the Estate of Lanavia Gray or file a written response with the Kanawha County Circuit Clerk, Cathy Gatson, Kanawha County Judicial Building, 111 Court Street, Charleston, West Virginia 25301 by September 9, 2015 at 10:00 a.m.
(607913)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

11.
IN THE CIRCUIT
COURT OF
KANAWHA COUNTY,
WEST VIRGINIA

STATE OF WEST VIRGINIA
Petitioner

v.
CASE NO. 15-C-1462

$ 1,717.00 (ONE THOUSAND, SEVEN HUNDRED AND SEVENTEEN DOLLARS) In United States Currency.
(Mario Pearson)
Respondent

On May 5, 2015, Officers of the Metropolitan Drug Enforcement Network Team seized $1,717.00 (One Thousand Seven Hundred and Seventeen Dollars), in United States Currency, at or near 109 Dooley Lane, Charleston, Kanawha County, West Virginia. $1,717.00 (One Thousand Seven Hundred and Seventeen Dollars), in United States Currency, constitutes moneys furnished or intended to be furnished, in violation of West Virginia Code, Chapter 60A, by any person in exchange for a controlled substance and/or proceeds traceable to such an exchange, and/or moneys used, or which have been used, or which are intended to be used to facilitate any violation of West Virginia Code, Chapter 60A, and/or the laws of the State of West Virginia. $1,717.00 (One Thousand Seven Hundred and Seventeen Dollars), in United States Currency, was found in the possession and/or control of Mario Pearson and at the time of the seizure, he claimed ownership of the said currency. The State of West Virginia has filed a Forfeiture Petition wherein it has asked the Circuit Court of Kanawha County, West Virginia to forfeit the above-described $1,717.00 (One Thousand Seven Hundred and Seventeen Dollars), in United States Currency, to the State and to vest title to ownership of the in the State of West Virginia. A copy of said Forfeiture can be obtained from the Kanawha County Clerk’s Office. Any person having a claim upon the above-described $1,717.00 (One Thousand Seven Hundred and Seventeen Dollars), in United States Currency, shall make a claim on said property on or before the passing of 30 days from the first publication of this legal publication. Any claim must clearly identify the claimant and the address at which legal process can be served upon the claimant. All claims shall be delivered to Reagan E. Whitmyer, Assistant Prosecuting Attorney, 301 Virginia Street East, Charleston, WV, 25301.

STATE OF WEST VIRGINIA
and METROPOLITAN
DRUG ENFORCEMENT
NETWORK TEAM
CHARLES T. MILLER
Prosecuting Attorney
By: Reagan Whitmyer,
Assistant Prosecuting
Attorney
for Kanawha County,
West Virginia
(608024)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

12.
IN THE CIRCUIT COURT OF
KANAWHA COUNTY, WEST VIRGINIA

IN RE: CHANGE OF NAME FROM: Nyola Pauline Day TO : Nyola P DeBolt

CIVIL ACTION
NO.: 15-P-339
LEGAL NOTICE OF PUBLICATION
CHANGE OF NAME PROCEEDING

Notice is hereby given that on the 4th day of September, 2015 at 1:30 p.m. on said day, or as soon thereafter as the matter may be heard, Nyola Pauline Day will apply by Petition to the Circuit Court of Kanawha County, West Virginia for the entry of an order by said Court changing his/her name from Nyola Pauline Day to Nyola P. DeBolt, at which time and place any interested party may appear and be heard, if they so desire.
You are hereby notified that this matter may be rescheduled without further notice or publication.
A copy of said Petition can be obtained from the undersigned Clerk’s Office at: 111 Court Street, Charleston, West Virginia, 25301.
Entered by the Clerk of said Court this 13th day of August, 2015.
Cathy S. Gatson
Kanawha County Circuit Clerk
(607868)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

13.
IN THE CIRCUIT COURT OF KANAWHA COUNTY,
WEST VIRGINIA

THE ESTATE OF
ELIZABETH COBBS,
by and through the Sheriff of Kanawha County, West Virginia, in his capacity as Administrator of the Estate of Elizabeth Cobbs,
Plaintiff,

CASEY L. COBBS; STACY L. HOLLOWAY; CITY OF SOUTH CHARLESTON, WEST VIRGINIA; VALLEY CENTER, a GENESIS HEALTHCARE CORPORATION FACILITY; KELLER FUNERAL HOME, INC.; STATE OF WEST VIRGINIA; WELLS HOME FURNISHINGS, INC.; AND PERSONS UNKNOWN,
Defendants.

Civil Action Number
14-P-534
JUDGE TOD
KAUFMAN
NOTICE TO
CREDITORS

To all creditors of Elizabeth Cobbs, deceased, including those holding liens by judgment or otherwise on her real estate, or any part thereof.
In pursuance of a decree of the Circuit Court of Kanawha County, West Virginia, made in a cause therein pending, to subject the real estate of the said Elizabeth Cobbs to the payment of her debts, including those which are liens on such real estate, or any part of it, you are hereby required to present your claims to the undersigned for adjudicaiton, at Stephen P. Swisher, PLLC, 1230 Ohio Avenue, Dunbar, West Virginia 25064, Phone (304) 768-3800, on or before the 25th day of September; otherwise you may by law be excluded from all benefit of such real estate.
Given under my hand this 18th day of August, 2015
Stephen P. Swisher,
Special Commissioner
1230 Ohio Avenue
Dunbar, WV 25064
(304) 768-3800
(608077)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

14.
IN THE CIRCUIT
COURT OF
PUTNAM COUNTY,
WEST VIRGINIA

ORDER OF
PUBLICATION

IN RE:
The Name Change of: KENSINGTON PAIGE RADFORD MARSALEK, AN INFANT CHILD, BY DAVID JAMES MARSALEK AND KRISTIN RADFORD MARSELAK, her next of kin, FOR A CHANE OF HER NAME TO KENSINGTON PAIGE MARSALEK

CASE NO. 15-P-54

The object of this Petition is to change the name of the above Petitioner from KENSINGTON PAIGE RADFORD MARSALEK TO KENSINGTON PAIGE MARSALEK. A Hearing is to be held 23, 2015, at 2:30 pm at the Putnam County Judicial Building, Courtroom B, 12093Winfield Road, Winfield, West Virginia, 25213.

A copy of the Petition for Change of Name can be obtained by the undersigned Clerk at his office.

Entered by the Clerk of said Court on August 6, 2015.
RONNIE W. MATTHEWS
CLERK OF THE
CIRCUIT COURT OF
PUTNAM COUNTY
(608532)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

15.
IN THE CIRCUIT
COURT OF
WYOMING COUNTY,
WEST VIRGINIA

IN RE: IN THE
CIRCUIT COURT OF
WYOMING COUNTY,

WEST VIRGINIA

IN THE INTEREST
OF: A MALE CHILD,
DOB: 09/28/2012,
BORN TO JADE LYNN
WOODRUM-HOLDREN
AND KENDRICK CONRAD

CASE NO. 13-JA-13

ORDER OF
PUBLICATION
AND NOTICE
OF HEARING

TO:Kendrick Conrad
5397 Doc Bailey Road
Cross Lanes,
Kanawha County, WV

AND TO ANY PERSON who claims or may claim a parental or other interest in and to a male child, born September 28, 2012, in Thomas Memorial Hospital, Charleston, Kanawha County, West Virginia, and whose birth mother is Jade Lynn Woodrum-Holdren:

You have been named as the father of a male child born September 28, 2012, in Thomas Memorial Hospital, Charleston, Kanawha County, West Virginia:

A petition has been filed in the Circuit Court of Wyoming County, West Virginia in which the West Virginia Department of Health and Human Resources seeks to terminate the parental rights of any or all of the parents or other parties, and which further seeks temporary and permanent custody of the child or children.

This case is scheduled for hearing before the Honorable Warren R. McGraw, Judge of the Circuit Court, Wyoming County Courthouse, Pineville, West Virginia, on Thursday, October 1, 2015, at 9:00 o’clock a.m., or as soon thereafter as the case may be heard. THIS HEARING MAY BE RESCHEDULED BY THE COURT WITHOUT FURTHER NOTICE OR PUBLICATION.

You are required to attend this hearing if you want to claim or keep your rights as a parent. You should also notify the Court and the Office of the Prosecuting Attorney of Wyoming County, West Virginia in writing of your wishes. An attorney may be appointed by the Court to represent you in this matter.

IF YOU DO NOT SHOW UP FOR THE HEARING, YOU MAY LOSE ALL RIGHTS TO CUSTODY, OR TO SEE, VISIT, OR CLAIM KINSHIP TO THE CHILD OR CHILDREN. You need to act immediately to preserve any legal rights you may have.

A copy of the Petition may be obtained from the Office of the Prosecuting Attorney of Wyoming County, West Virginia, at the address below.

Dated this 26th day of August, 2015.
Micheal Cochrane
Prosecuting Attorney of
Wyoming County,
West Virginia
P O Box 462
Pineville, WV 24874-0462
Phone: 304-732-8000 ext 243
FAX: 304-732-6052
(608786)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

16.
IN THE FAMILY COURT OF
GREENBRIER
COUNTY,
WEST VIRGINIA

To: ABDUL RAHEEM ZAYEED
Respondent’s Name

Magistrate Court
Case No: 15-M13D-00145

Family Court Civil
Action: 15-DV-132
ORDER OF
PUBLICATION
PROTECTION ORDER

1. The object of this suit is to obtain protection from the Respondent.
2. The object of this publication by Class I legal advertisement is to notify Respondent of the PROTECTIVE ORDER prohibiting the above-named Respondent from having contact with certain individuals. This Order may affect property and other rights of the Respondent. Violating this Order may subject the Respondent to criminal sanctions. The Respondent is strongly encouraged to obtain a copy of this Protective Order from the Circuit Clerk of the county listed above.

TO THE ABOVE-NAMED RESPONDENT:

The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.

Issued this 19th day of August, 2015 at 1:57 P.M.
Louvonne Arbuckle
Circuit Clerk
(607975)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

17.
IN THE
FAMILY COURT OF
KANAWHA COUNTY,
WEST VIRGINIA

ORDER OF
PUBLICATION

IN THE MATTER OF:

Olivia Leavye Hodges

Civil Action #:
12-FIG-236

Kerstin VandeCosteele
William Bowen

The object of this suit is to obtain Guardianship of an infant.

TO THE ABOVE NAMED DEFENDANT:
It appearing by affidavit filed in this action that the Petitioners used due diligence to ascertain the whereabouts of Kerstin VandeCastelle and William Bowen without effect is here by ordered that Kerstin VandeCasteele and William Bowen serve upon Rhonda Burgess, whose address is 186 Hillsview Dr., Charleston, , West Virginia 25312, an answer, including any related counter claim or defense you may have to the petition filed in this action on or before September 8, 2015. If you fail to do so, thereafter, upon proper hearing being held 9/18/15 at 9:00 a.m., Petitioners will be granted relief demanded in their Petition being appointed Guardians of said infant.
A copy of said Petition can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court this the 25th day of August, 2015.
Cathy S. Gatson
Clerk of Court
(608485)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

18.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Billy Steven Casto
Respondent’s Name
711 Ferrell Rd, Pine Meadows Apts #103
Tornado, WV 25202
Address
07/24/79
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1211

Family Court Civil
Action: 15-DV-1159
ORDER OF
PUBLICATION
PROTECTION ORDER

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 02/13/2016.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 26, 2015
Cathy S. Gatson
Circuit Clerk
(608704)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

19.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Brandon E. Bailey
Respondent’s Name
600 Shrewsbury Street
Charleston, WV 25301
Address
06/20/86
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1178

Family Court Civil
Action: 15-DV-1127
ORDER OF
PUBLICATION
PROTECTION ORDER

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 02/11/2016.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 26, 2015
Cathy S. Gatson
Circuit Clerk
(608703)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

20.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Christina Roselma Taylor
Respondent’s Name
30 Four Mile Creek
Branchland, WV 25506
Address
06/03/83
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-761

Family Court Civil
Action: 15-DV-727
ORDER OF
PUBLICATION
PROTECTION ORDER

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 02/10/2016.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 26, 2015
Cathy S. Gatson
Circuit Clerk
(608702)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

21.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Michael Scott Mackenzie
Respondent’s Name
7156 Reynolds Crossing
Dr.
Reynoldsburg, WV 43068
Address
1/24/82
Respondent’s Date of
Birth

Magistrate Court
Case No: 15-D-1265

Family Court Civil
Action: 15-DV-1210
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/04/2015.
A final hearing is scheduled for the 4th day of September, 2015., at 9:45 am before the Kanawha County Family Court.
Issued this August 19, 2015.
Cathy S. Gatson
Circuit Clerk
(608052)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

22.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Nicole Deaton
Respondent’s Name
5002 Sandstone Drive
Cross Lanes, WV 25313
Address
12/19/74
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1209

Family Court Civil
Action: 15-DV-1157
ORDER OF
PUBLICATION
PROTECTION ORDER

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 2/13/16.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 26, 2015
Cathy S. Gatson
Circuit Clerk
(608707)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

23.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Nicole Deaton
Respondent’s Name
5002 Sandstone Drive
Cross Lanes, WV 25313
Address
12/19/74
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1210

Family Court Civil
Action: 15-DV-1158
ORDER OF
PUBLICATION
PROTECTION ORDER

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of which may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 11/13/15.
The Respondent may appeal this Protective Order pursuant to W.Va Code § 48-27-510, within 10 days of the date of the Order was entered.
Issued this August 26, 2015
Cathy S. Gatson
Circuit Clerk
(608706)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

24.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Richie Lee Workman
Respondent’s Name
505 Leon Sullivan Way
Charleston, WV 25301
Address
02/12/78
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-461

Family Court Civil
Action: 15-DV-441
ORDER OF
PUBLICATION
PROTECTION ORDER

TO THE ABOVE-NAMED RESPONDENT:

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

25.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Stephan Devon
Sayles
433 Baird Drive
Charleston, WV 25302
Respondent’s Name
Address
7/10/90
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1264

Family Court Civil
Action: 15-DV-1209
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/03/2015.
A final hearing is scheduled for the 3rd day of September, 2015., at 1:30 pm before the Kanawha County Family Court.
Issued this August 19, 2015.
Cathy S. Gatson
Circuit Clerk
(608051)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

26.
IN THE FAMILY COURT OF KANAWHA COUNTY,
WEST VIRGINIA

To: Terrance Jarrold Allen
Respondent’s Name
Columbus, OH
Address
01/13/76
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1270

Family Court Civil
Action: 15-DV-1215
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/04/2015.
A final hearing is scheduled for the 4th day of September, 2015., at 9:30 am before the Kanawha County Family Court.
Issued this August 19, 2015.
Cathy S. Gatson
Circuit Clerk
(608053)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

27.
IN THE SUPERIOR
COURT OF THE STATE
OF WASHINGTON IN
AND FOR
THE COUNTY OF KING,
JUVENILE DEPARTMENT

IN RE THE
DEPENDENCY OF:
Holten Reudink
DOB: 06-08-10
NO: 15-7-01440-2KNT

NOTICE OF HEARING

TO: *Scott Johnson Meador, alleged father; Unknown father, and/or anyone claiming parental/paternal rights or interest in the child and to all whom it may concern:

On May 4, 2015, a petition for Dependency was filed in the above entitled Court, pursuant to RCW 13.34.080 and/or RCW 26.33.310 regarding the above named child, whose parents are Jessica Reudink, mother and *.

[FOR FURTHER INFORMATION, CALL 253-372-5738, 8:00 a.m. – 4:30 p.m.]

Said Petition will be heard on October 5, 2015, at the hour of 8:15 a.m., at King County Superior Court, Juvenile Department, 401 4th Ave North, Kent, WA before a judge of the above entitled court, at which time you are directed to appear and answer the said petition or the petition will be granted and action will be taken by the court such as shall appear to be for the welfare of the said child.

Dated August 6, 2015.
BARBARA MINER
KING COUNTY
SUPERIOR COURT
CLERK

BY:BLB, Deputy Clerk
(606947)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

28.
INVITATION
FOR BIDS
for
POLYMERS

THE SANITARY
BOARD OF THE CITY
OF CHARLESTON
CHARLESTON,
KANAWHA COUNTY,
WEST VIRGINIA

The Sanitary Board of the City of Charleston, West Virginia (CSB) will receive sealed Bids for POLYMERS at the CSB office located at 208 26th Street W, Charleston, WV 25387, until 10:00 a.m., E.S.T., Friday, October 2, 2015. The Bidding will then be closed and the Bids will be publicly opened and read aloud. All Bidders are invited to attend.

The CSB will consider incomplete any Bid not prepared and submitted in accordance with the provisions herein outlined, and may reject any or all Bids. Any Bid may be withdrawn by the Bidder prior to the scheduled time for the opening of Bids or authorized postponement thereof provided the Bidder’s written request for withdrawal is delivered to the CSB before the Bids are opened. Any Bid received after the time and date specified will not be opened. No Bidder may withdraw their Bid after the actual Bid opening thereof. A Bid that has been withdrawn will be returned to the Bidder unopened at the time of the opening of the other Bids. No conditional Bids will be accepted.

Bid Documents may be obtained at the above address or by calling Jeremy Frye @ (304) 348-1084 Ext. 256.
(608400)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

29.
Invitation for
Public Comment on
Marshall University

Marshall University is seeking comments from the public about the university in preparation for its periodic evaluation by its regional accrediting agency. The University will host a visit October 12-13, 2015, with a team representing the Higher Learning Commission of the North Central Association. Marshall University has been accredited by the Commission since 1928. The team will review the institution’s ongoing ability to meet the Commission’s Criteria for Accreditation.

The public is invited to submit comments regarding the university:

Public Comment on
Marshall University
The Higher Learning
Commission
230 South LaSalle Street,
Suite 7-500
Chicago, IL 60604-1411

The public may also submit comments on the Commission’s website at:

www.hlcommission.org/HLC-Institutions/third-party-comment.html.

Comments must address substantive matters related to the quality of the institution or its academic programs. Comments must be in writing.

All comments must be received by September 12, 2015.
(608789)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

30.
LEGAL NOTICE
RFP 16005 –
Security System
North Central WV
Advanced Technology
Center

The Community and Technical College System of WV seeks to engage a highly qualified security integrator for the installation and maintenance of an Access Control and Alarm Monitoring System, Video Surveillance System and security communications system at the North Central WV Advanced Technology Center, I-79 Technology Park, 500 Galliher Drive, Fairmont, WV 26554.

RFP 16005 is available at the follow URL: https://wvhepc.org/purchasing/

A non-mandatory prebid meeting is scheduled for 10:30 AM, Eastern Time, September 2, 2015, at:

Robert H. Mollohan
Research Center
Room 234
I-79 Technology Park
1000 Galliher Drive
Fairmont, WV 26554

Proposals will be received until 3:00 PM, Eastern Time, September 15, 2015, by:

Chief Procurement Officer
RFP 16005
Community and
Technical College
System of WW
1018 Kanawha Boulevard,
East, Suite 700
Charleston, WV 25301
(607790)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

31.
LEGAL NOTICE
RFP 16006 –
Structured Cabling
North Central WV
Advanced Technology Center

The Community and Technical College System of WV seeks to engage a highly qualified communications systems integrator for the installation and maintenance of a Structured Cabling System at the North Central Advanced Technology Center (ATC).at the North Central WV Advanced Technology Center, I-79 Technology Park, 500 Galliher Drive, Fairmont, WV 26554.

RFP 16006 is available at the follow URL: https://wvhepc.org/purchasing/

A non-mandatory prebid meeting is scheduled for 1:00 PM, Eastern Time, September 2, 2015, at:

Robert H. Mollohan
Research Center
Room 234
I-79 Technology Park
1000 Galliher Drive
Fairmont, WV 26554

Proposals will be received until 3:00 PM, Eastern Time, September 15, 2015, by:

Chief Procurement Officer
RFP 16006
Community and
Technical College
System of WW
1018 Kanawha Boulevard,
East, Suite 700
Charleston, WV 25301
(607791)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

32.
Legal Notice of State
Purchasing Division

The State of West Virginia Purchasing Division will accept sealed bids for:

Buyer
BC-23

RFQ No.
DEP1500000002

Spending Unit
WVDEP/AML

Commodity
Expression of interest from qualified firms to provide architectural /engineering services as defined here in and bid documents on behalf of WV Department of Environmental Protection, BICKMORE REFUSE #2: Design of drainage conveyances. Installation of mine seals. Reclamation of refuse. Installation of streambank protection and re-vegetation of disturbed areas.

Bids/Expression of Interest must be submitted to the Purchasing Division located at 2019 Washington Street East Post Office Box 50130, Charleston, WV 25305-0130 as instructed in the specifications prior to the bid opening date and time scheduled for 09/23/2015 at 1:30 P.M. Telephone inquiries may be made to Buyer designated in the specifications or 304-558-2157
(607764)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

33.
Legal Notice of State
Purchasing Division

The State of West Virginia Purchasing Division will accept sealed bids for:

Buyer
BC-23

RFQ No.
DEP1500000003

Spending Unit
WVDEP/AML

Commodity
Expression of interest from qualified firms to provide architectural/ engineering services as defined herein and bid documents on behalf of WV Department of Environmental Protection, PENDLETON CREEK STRIP PHASE #2: Design of drainage conveyances. Re-grading of mine spoil to eliminate highwall. Establishment of access across site and re-vegetation of disturbed areas.

Bids/Expression of Interest must be submitted to the Purchasing Division located at 2019 Washington Street East Post Office Box 50130, Charleston, WV 25305-0130 as instructed in the specifications prior to the bid opening date and time scheduled for 09/24/2015 at 1:30 P.M. Telephone inquiries may be made to Buyer designated in the specifications or 304-558-2157
(607765)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

34.
Legal Notice of State
Purchasing Division

The State of West Virginia Purchasing Division will accept sealed bids for:

Buyer
BC-23

RFQ No.
DEP1600000004

Spending Unit
WVDEP/AML

Commodity
Expression of Interest from qualified firms to provide architectural/ engineering services as defined herein and bid document on behalf of W V Department of Environmental Protection, (WVDEP/AML). CHAFFEY RUN STRIP: Design of drainage conveyances. Installation of bat gate mine seal. Refuse reclamation. Re-grading of mine spoil to eliminateHighwall. Access road upgrade. Installation of Aggregate Plugs. Re-vegetation of disturbed areas.

Bids/Expression of Interest must be submitted to the Purchasing Division located at 2019 Washington Street East, Post Office Box 50130, Charleston, WV 25305-0130 as instructed in the specifications prior to the bid opening date and time scheduled for 09/24/2015 at 1:30 P.M. Telephone inquiries may be made to Buyer designated in the specifications.
(607800)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

35.
Legal Notice of State
Purchasing Division

The State of West Virginia Purchasing Division will accept sealed bids for:

Buyer
BC-23

RFQ No.
DEP1600000006
Spending Unit
WVDEP/AML

Commodity
Expression of Interest from qualified firms to providearchitectural/engineering services as defined herein and bid documents on behalf of West Virginia Department of Environmental Protection (WVDEP/AML). ED GOWER HW#2: Design of drainage conveyances. Installation of mine seals. Re-grading of mine spoil to eliminate high- wall. Access road construction. Off-site disposal of unsuitable material. Re-vegetation of disturbed areas.

Bids/Expression of Interest must be submitted to the Purchasing Division located at 2019 Washington Street, East, Post Office Box 50130, Charleston, WV 25305-0130 as instructed in the specifications prior to the bid opening date and time scheduled for 09/15/2015 at 1:30 P.M. Telephone inquiries may be made to Buyer designated in the specifications.
( 607802)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

36.
Legal Notice of State
Purchasing Division

The State of West Virginia Purchasing Division will accept sealed bids for:

Buyer
BC-23

RFQ No.
DEP1600000008

Spending Unit
WVDEP/AML

Commodity
Expression of Interest from qualified firms to provide architectural /engineering services as defined herein and bid documents on behalf of West Virginia Department of Environmental Protection (WVDEP/AML). LAUREL BRANCH (WEAVER) PORTALS: Design of drainage conveyances. Installation of mine seals and bat gate mine seals. Re-vegetation of disturbed areas.

Bids/Expression of Interest must be submitted to the Purchasing Division located at 2019 Washington Street, East, Post Office Box 50130, Charleston, WV 25305-0130 as instructed in the specifications prior to the bid opening date and time scheduled for 09/29/2015 at 1:30 P.M. Telephone inquiries may be made to Buyer designated in the specifications.
(607804)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

37.
Legal Notice of State
Purchasing Division

The State of West Virginia Purchasing Division will accept sealed bids for:

Buyer
BC-23

RFQ No.
DEP1600000005

Spending Unit
WVDEP/AML

Commodity
Expression of Interest from qualified firms to provide architectural /engineering services as defined herein and bid documents on behalf of West Virginia Department of Environmental Protection (WVDEP/AML). MTN VIEW PORTALS: Design of drainage conveyances. Installation of mine seals and bat gate mine seals. Refuse reclamation. Re-vegetation of disturbed areas.

Bids/Expression of Interest must be submitted to the Purchasing Division located at 2019 Washington Street, East, Post Office Box 50130, Charleston, WV 25305-0130 as instructed in the specifications prior to the bid opening date and time scheduled for 09/22/2015 at 1:30 P.M. Telephone inquiries may be made to Buyer designated in the specifications or 304-558-2157.
(607801)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

38.
Legal Notice of State
Purchasing Division

The State of West Virginia Purchasing Division will accept sealed bids for:

Buyer
BC-23

RFQ No.
DEP1600000007

Spending Unit
WVDEP/AML

Commodity
Expression of Interest from qualified firms to provide architectural/ engineering services as defined herein and bid documents on behalf of West Virginia Department of Environmental Protection (WVDEP/AML). MONARCH PORTALS: Design of drainage conveyances. Installation of mine seals and bat gate mine seals. Small slide/erosion area. Re-vegetation of disturbed areas.

Bids/Expression of Interest must be submitted to the Purchasing Division located at 2019 Washington Street, East, Post Office Box 50130, Charleston, WV 25305-0130 as instructed in the specifications prior to the bid opening date and time scheduled for 09/23/2015 at 1:30 P.M. Telephone inquiries may be made to Buyer designated in the specifications.
(607803)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

39.
NOTICE

Please be advised that on Tuesday, October 13, 2015 at 9:00 a.m. in its Chambers on the 2nd Floor of the Putnam County Courthouse, 12093 Winfield Road, Winfield, WV, the Putnam County Commission will consider entry of an Order merging Precinct 24 of Magisterial District II into Precincts 29-1 and 29-2 of Magisterial District III, and changing the polling place of Precinct 24 from Camp Happy Valley to Mountain View Elementary School.

Upon said consolidation, Magisterial District II shall include the following precincts: 11, 25-1, 25-2, 26-1, 26-2, 27-1, 27-2, 28-1, 28-2, 31, 32, 33-1, 33-2, 41, and 47; and Magisterial District III shall include the following precincts: 6-1, 6-2, 7, 8-1, 8-2, 9, 10-1, 10-2, 29-1, 29-2, 42, 43-1 and 43-2. Further, Executive Committee Districts shall be the same as the magisterial districts (comprised of the same precincts).

This will be a permanent change effect with the Primary Election of May 2016.
(607788)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

40.
NOTICE OF
TRUSTEE’S SALE

NOTICE OF TRUSTEE’S SALE is hereby given pursuant to and by virtue of the authority vested in the Substitute Trustee, Pill & Pill, PLLC, by that certain Deed of Trust dated January 27, 2005, executed by Borrowers Matthew S. Shamblin and Tara R. Shamblin, to Turley Law Office, the Trustee of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3213, at Page 6. At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 1106 Wilkie Dr, Charleston, WV 25314. Pill & Pill, PLLC was appointed as Substitute Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated June 5, 2015, of record in the Clerk’s Office in Book 4108, Page 602. The borrowers defaulted under the Note and Deed of Trust and the Substitute Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Substitute Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on the following date:
August 26, 2015
at 5:38 p.m.

The property is described as of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Loudon District, Kanawha County, West Virginia, and being more particularly described as follows:

All that certain lot, piece or parcel of land, situate in Loudon District, Kanawha County, West Virginia, being known and designated as all that certain part of Lot One Hundred Seventy-two (172), of Forest Hills, Section Five Addition to the City of Charleston, as laid down and shown upon the map hereof, made by E. H. Venable, E. 6., dated August, 1947, of record in the office of the Cleric of the County Commission of Kanawha County, West Virginia, in Photostatic Map Book 14, at page 37, and more particularly bounded and described as follows:

BEGINNING at an iron pin on the south side of Wilkie Drive, a common corner of Lots Nos. 171 and 172; thence running with the south side, of said Drive with a curve having a radius of 321.6 feet and a chord bearing N. 82° 54′ E. 52.0 feet to an iron pin, corner to Lot No. 173; thence running with the common dividing line between Lots Nos. 172 and 173, S., 11° 28′ E. 120.0 feet to an iron pin; thence running across the rear of Lot No. 172 N. 88° 56′ W. 70.2 feet to an iron pin in the common dividing line between Lots Nos. 171 and 172; thence with said common dividing line N. 2° 44′ W. 110.0 feet to the place of beginning.

And being the same property conveyed to Thomas Gregory Wegmann from Ella Mae Coleman and Charles F. Coleman, her husband and George W. Nichols and Wanda L. Nichols, his, wife, by deed dated December 2, 1992 of record in the aforesaid Clerk’s office in Deed Book 2306, at page 654. And also being the same property conveyed to Mathew S. Shamblin and Tara R. Shamblin, husband and wife, from Thomas Gregory Wegmann by deed dated January 7, 2005, to be recorded concurrently, to which map and deed reference is here made for a more particular description of the property herein conveyed.

This conveyance is made subject to such rights of way, easements, restrictions, covenants, conditions and reservations as may be found in prior deeds of record in the chain of title.

Being the same property conveyed to Matthew S. Shamblin by the Deed dated June 6, 2012 and recorded in Deed Book 2837, at Page 315 in the Office of the Clerk of the County Commission of Kanawha County, West Virginia.
TERMS OF SALE:

1)The property will be conveyed in an “AS IS” physical condition by Deed containing no warranty, express or implied, subject to the Internal Revenue Service right of redemption, all property taxes, prior Deeds, liens, reservations, encumbrances, restrictions, rights-of-ways, easements, covenants, conveyances and conditions of record in the Clerk’s office or affecting the subject property.

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-1.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

5)The Trustee shall be under no duty to cause any existing tenant or person occupying the property to vacate said property, and any personal property and/or belongings remaining at the property after the foreclosure sale will be deemed to constitute ABANDONED PROPERTY AND WILL BE DISPOSED OF ACCORDINGLY.

6)The total purchase price is payable to the Trustee within thirty (30) days of the date of sale, with ten (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the total purchase price payable to the Trustee at sale.
Pill & Pill, PLLC,
Substitute Trustee

BY:_
Pill & Pill, PLLC
85 Aikens Center
Edwin Miller Boulevard
P.O. Box 440
Martinsburg, WV 25402
(304) 263-4971
[email protected]
(606792)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

41.
NOTICE OF
TRUSTEE’S SALE

NOTICE OF TRUSTEE’S SALE is hereby given pursuant to and by virtue of the authority vested in the Substitute Trustee, Pill & Pill, PLLC, by that certain Deed of Trust dated July 3, 2000, executed by Borrower Richard L. Bowling, to Edward C. Goldberg, the Trustee of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 2637, at Page 76. At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 705 Green Valley Drive, St Albans, WV 25177. Pill & Pill, PLLC was appointed as Substitute Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated June 29, 2015, of record in the Clerk’s Office in Book 4112, Page 403. The borrower defaulted under the Note and Deed of Trust and the Substitute Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Substitute Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on the following date:
September 10, 2015
at 5:30 p.m.

The property is described as of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Jefferson District, Kanawha County, West Virginia, and being more particularly described as follows:

All that certain parcel of land, together with the improvements thereon and the appurtenances thereunto belonging situate in the District of Jefferson, Kanawha County, West Virginia, and being more particularly bounded and described as follows:

BEGINNING at a iron pin formerly located on the easterly side of Green Valley Drive formerly Tow and Three Quarter Mile Creek Road, being West Virginia Secondary Route 8 at intersection with Poplar Lane; thence leaving Green Valley Drive and running with the southerly right-of-way line of Poplar Lane and binding thereon S. 80° 00′ E 120.00 feet to point; thence S 67° 05′ E 50.00 feet to a steel pin; thence leaving Poplar Lane and running S. 14° 23′ W. 163.13 feet to a steel pin; thence running through the original 1.37 acre tract N. 80° 54′ W 161.25 feet to a steel pin in the easterly right-of-way line of Green Valley Drive N. 11° 40′ E 176,42 feet to the place of beginning, containing 0.658 acres, more or less, as shown upon a plat or map entitled “Plat Showing Survey For Walter M. Sayre, Jr. Map 10 Parcel 10 on 2 ¾ Mile Creek Jefferson District, Kanawha County, West Virginia”, dated November 26,1992, prepared by Jack L. Roy LLS W Va No. 18.

Being the same property that was conveyed unto Richard L. Bowling by Richard L. and Kimberly D. Bowling, by quitclaim deed dated August 8,1999, of record in the aforesaid Clerk’s Office in Deed Book 2477, at page 605. Reference is hereto made to the aforesaid map and deed for a more particular description of the property herein conveyed.
TERMS OF SALE:

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-1.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

Pill & Pill, PLLC,
Substitute Trustee

BY:Pill & Pill, PLLC
85 Aikens Center
Edwin Miller Boulevard
P.O. Box 440
Martinsburg, WV 25402
(304) 263-4971
[email protected]
(607683)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

42.
NOTICE OF
TRUSTEE’S SALE

NOTICE OF TRUSTEE’S SALE is hereby given pursuant to and by virtue of the authority vested in the Substitute Trustee, Pill & Pill, PLLC, by that certain Deed of Trust dated June 25, 2005, executed by Borrowers Jennifer Lenore Walker and Nathaniel Edward Walker, to Tommy J. Dixon, the Trustee of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3258, at Page 364. At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 70 Chestnut Road, Elkview, WV 25071. Pill & Pill, PLLC was appointed as Substitute Trustee by APPOINTMENT OF SUCCESSOR TRUSTEE dated June 19, 2015, of record in the Clerk’s Office in Book 4109, Page 876. The borrowers defaulted under the Note and Deed of Trust and the Substitute Trustee has been instructed to foreclose under the Deed of Trust. Accordingly, the Substitute Trustee will sell the following described property to the highest bidder at the front door of the Courthouse of Kanawha County, in Charleston, West Virginia, on the following date:
September 10, 2015
at 5:36 p.m.

The property is described as of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in Elk District, Kanawha County, West Virginia, and being more particularly described as follows:

ALL THAT CERTAIN PROPERTY SITUATED IN THE DISTRICT OF ELK, COUNTY OF KANAWHA AND STATE OF WEST VIRGINIA, LOT #24, “MOUNTAINEER HEIGHTS”, BEING MORE FULLY DESCRIBED IN A DEED VOLUME 2527 AND PAGE 777, MAP# 47A AND PARCEL #19.

TAX MAP OR PARCEL ID NO. : 47A/19

Being the same property conveyed to Jennifer Lenore Walker and Nathaniel Edward Walker by the Deed dated June 4, 2001 and recorded in Deed Book 2527, at Page 777 in the Office of the Clerk of the County Commission of Kanawha County, West Virginia.
TERMS OF SALE:

2)The Purchaser shall be responsible for the payment of the transfer taxes imposed by the West Virginia Code § 11-22-1.

3)The Beneficiary and/or the Servicer of the Deed of Trust and Note reserve the right to submit a bid for the property at sale.

4)The Trustee reserves the right to continue sale of the subject property from time to time by written or oral proclamation, which continuance shall be in the sole discretion of the Trustee.

BY:_Pill & Pill, PLLC
85 Aikens Center
Edwin Miller Boulevard
P.O. Box 440
Martinsburg, WV 25402
(304) 263-4971
[email protected]
(607682)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

43.
NOTICE OF HEARING

UNKNOWN FATHER

You have been named as the father of K. Briscoe, born to Ashley Briscoe. A petition has been filed in the Circuit Court of Kanawha, West Virginia, and this petition requests the Court to grant permanent custody of this child to the West Virginia Department of Health and Human Resources.

This case is set for a hearing on September 30th, 2015, at 9:30 o’clock a.m. This hearing may result in the termination of all of your rights as the parent of above listed children. This hearing will be held before the Honorable Louis H. Bloom, Circuit Judge, at the Kanawha County Judicial Annex, 111 Court Street, 5th Floor, Courtroom C, Charleston, West Virginia.

If you want to keep your rights as a parent of the children listed above you should attend this hearing. An attorney has been appointed by the Court to represent you if you attend the hearing. IF YOU DO NOT SHOW UP FOR THE HEARING, you may lose all rights to see, visit or claim kinship to this child.

August 15, 2015
Ariana Kincaid
Assistant Prosecuting
Attorney
(607686)

Class: 983 Gazette Legal Ads Last appeared: 08-26-2015

44.
NOTICE OF
OPEN MEETING –
CHARLESTON AREA
MEDICAL CENTER, INC.
BOARD OF TRUSTEES
PLANNING AND PUBLIC
POLICY COMMITTEE

Notice is hereby given that the Planning and Public Policy Committee of the Board of Trustees of Charleston Area Medical Center Inc. (“CAMC”) will hold a regular meeting at 7:30 a.m. on Wednesday, September 2, 2015, in the corporate boardroom of CAMC General Hospital, 501 Morris St., Charleston, West Virginia. Members of the public wishing to address the committee must sign up no later than 7:15 a.m. the day of the meeting.
(607911)

Class: 983 Gazette Legal Ads Last appeared: 08-26-2015

45.
NOTICE OF
PROPOSED LEASE OF
SCHOOL PROPERTY

NOTICE is hereby given to all whom it may concern that pursuant to the terms of W. Va. Code § 18-5-7(e), the BOARD OF EDUCATION OF THE COUNTY OF KANAWHA, acting by its duly authorized agents, will offer to lease the real property described below to the highest responsible bidder. It has been ascertained that the real property described below is not needed for school purposes.

REAL PROPERTY
TO BE LEASED:
The property to be leased consists of a parcel of land approximately one hundred feet (100′) by one hundred feet (100′) located within the City of Charleston, and being part of the George Washington High School property, together with appropriate easements for ingress and egress and for utility services. The exact location and legal description will be ascertained later. The auction may include an offer or option to lease to be exercised at a later date.

DATE/TIME OF
AUCTION SALE:
September 14, 2015 at 9:30 A.M. The Kanawha County Board of Education will also accept written sealed bids so long as they are received prior to the date and time of the auction.

PLACE OF
AUCTION SALE:
Room 219 in the offices of the Board of Education of the County of Kanawha, 200 Elizabeth Street, Charleston, West Virginia

The property to be leased may be inspected prior to the sale by arrangement with agents of the Board.

The property to be leased shall be used solely for the purpose of acquisition, construction, maintenance of a cell phone tower, and related structures. No other improvements may be placed or erected on the property without the prior written consent of the Board of Education.

The term of lease shall be for five years and may contain an option or options to renew. Either party may elect to terminate the lease by giving not less than one hundred eighty days’ notice of intent to terminate the lease prior to end of any lease term. There are no known or suspected hazards associated with the subject property. The Lessee shall be required to provide reasonable maintenance and upkeep of the property and to keep the same free of trash and debris.

The successful bidder shall maintain a general liability insurance policy with at least One Million Dollar ($1,000,000.00) policy limit for any single incident and the Board of Education shall be named as an additional insured on said policy.

The lease may contain such other terms and conditions as may be mutually agreed between the successful bidder and the Board of Education.

The Kanawha County Board of Education reserves the right to reject any and all bids, and the right to cancel or postpone the auction upon public outcry only at the time and place set out above.

DATED:
August 27, 2015.
THE BOARD OF
EDUCATION OF THE
COUNTY OF KANAWHA
200 Elizabeth Street
Charleston, WV 25311
(608787)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

46.
NOTICE OF
PUBLIC HEARING
CITY OF ST. ALBANS
WEST VIRGINIA

ORDINANCE
AUTHORIZING
APPLICATION
UNDER HOME RULE
PILOT PROGRAM

Notice is hereby given by the City of St. Albans, West Virginia, that the City Council it will hold a public hearing on Tuesday, September 8, 2015 at 7:15 p.m. at the St. Albans City Council Chambers, 51 Sixth Avenue, St. Albans, West Virginia 25177.

The purpose of this public hearing is to provide members of the public an opportunity to speak either in favor of, or in opposition to, the proposed ordinance authorizing the City of St. Albans to submit its Application to participate in the West Virginia Home Rule Pilot Program entitled:

AN ORDINANCE AUTHORIZING THE GOVERNING BODY OF THE CITY OF ST. ALBANS TO SUBMIT ITS MUNICIPAL HOME RULE PILOT PROGRAM APPLICATION AND PLAN TO THE MUNICIPAL HOME RULE BOARD PURSUANT TO THE PROVISIONS OF WEST VIRGINIA CODE § 8-1-5a, GENERALLY, AND § 8-1-5a(f), PARTICULARLY.

A copy of the City of St. Albans proposed Application to the West Virginia Home Rule Pilot Program has been available for inspection by the public at the office of the Clerk of the City of St. Albans at 1499 MacCorkle Avenue, St. Albans, West Virginia 25177, Monday through Friday (except legal holidays), between the hours of 8:00 a.m. and 4:30 p.m.

All interested residents of the City are invited to attend the public hearing scheduled on Tuesday, September 8, 2015 at 7:15 p.m. and to present oral or written comments concerning the City’s proposed ordinance. Written comments may be addressed to Mayor Richard Callaway, City of St. Albans, 1499 MacCorkle Avenue, St. Albans, West Virginia 25177.

The first reading of the ordinance approving the City of St. Albans Application to the West Virginia Home Rule Pilot Program was held at the regularly scheduled meeting of the City Council of the City of St. Albans at 7:30 p.m. on Monday, August 17, 2015. Immediately following the aforementioned public hearing, the Governing Body shall conduct the second reading of the ordinance which shall be considered for final roll call vote, at the regularly scheduled meeting of the City Council. The second reading of the ordinance, as well as the public hearing, will take place in the St. Albans City Council Chambers, 51 Sixth Avenue, St. Albans, West Virginia 25177.
(608530)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

47.
NOTICE OF
PUBLIC HEARING

The Board of Zoning Appeals of the City of Charleston, West Virginia, will hold a public hearing at 8:30 a.m., Thursday, September 24, 2015, in the City Service Center Conference Room located at 915 Quarrier Street, Charleston, WV, on the following:

VAR-15-2877-Application of Highland Hospital requesting a fence height variance in order to a 12 foot tall steel privacy fence surrounding outdoor facilities at the hospital on the property located at 300 56th Street.

Interested persons are requested to appear and voice opinions with respect thereto. The file is available for your inspection in the Planning Department, City Service Center, 915 Quarrier Street, Suite 1. If you have any questions or concerns, please contact the Planning Department at (304) 348-8105.
(607785)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

48.
NOTICE OF
PUBLIC HEARING

The Municipal Planning Commission of the City of Charleston, West Virginia, will hold a public hearing at 3:00 p.m., Wednesday, September 9, 2015, in the Conference Room of the City Services Center on the first floor of the Municipal Parking Building at 915 Quarrier Street, Charleston, WV, on the following:

Street Dedication: Application of Kanawha County Schools to dedicate Hawks Ridge as a city street.

Text Amendment: A Bill amending the Zoning Ordinance of the City of Charleston, West Virginia, adopted January 1, 2006, as amended, and the map thereof, by adding section 2-060 Slack Plaza Overlay District, for the purpose of creating an overlay district that requires the selling of alcoholic beverages for off-premise consumption to be a Conditional Use Permit and delineating said overlay district on the Zoning Map.

Interested persons are requested to appear and voice opinions with respect thereto. If you have any questions or concerns, please contact the Planning Department at (304) 348-8105. These files are available for your inspection at the Planning Department, City Services Center, 915 Quarrier Street, Suite 1, Charleston, WV 25301.
(607916)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

49.
NOTICE OF REQUEST
FOR ENGINEERING
QUALIFICATIONS

The Town of Cowen pursuant to WV Code 5G-1-3 is in the process of obtaining architectural and engineering services to provide design, construction and inspection services for a sidewalk project (insert street locations if known). Professional services will include (1) preliminary design and schematic drawings, (2) cost estimations (3) design, (4) preparation of bidding and contracting documents (5) participation in the evaluation of construction bids received, and (6) monitoring and inspection of construction activities to insure compliance with plans and specifications.

All consultants interested in being considered for this project must submit 3 copies each including the following: (1) Letter of Interest, (2)Statement of Qualifications and Technical Expertise, (3) Experience of Management and Personnel who will be in charge of the project, (4) Examples of Similar Related Projects, and (5) References.

The aim of the competitive process is to objectively select the firm who will provide the highest quality of service at a realistic fee. Accordingly technical qualifications and experience will be weighed heavily. Selected respondents will be interviewed and the firm judged most qualified will be asked to prepare a final proposal, which would include fees for said services.

Please submit all requested information to Mayor Tammy Crue-Hawkins, Town of Cowen P.O. Box 446, Cowen WV 26206 to arrive No Later Than 1:00 P.M. Monday, August 31, 2015.

Attention is directed to the fact that the proposed project is to be undertaken through various state and federal government grants and loans, and that all work will be performed in accordance with the regulations issued by those agencies. The selected firm will be required to comply with Title VI of the Civil Rights Act of 1964, Executive Order 11246, Section 109 of the Housing and Urban Development Act of 1974, Section 3 of the Housing and Urban Development Act of 1968, Conflict of Interest and Statement and Access to Records provisions and any other agency-specific requirements, and all other requirements as they relate to HUD funded projects.

Each firm must fully comply with the requirements, terms and conditions to achieve Minority-owned/women owned Business Enterprise (MBE/WBE) participation during the performance of this contract. The firm commits itself to the program for MBE/WBE participation and all other requirements, terms, and conditions of the bid conditions.

The Town will afford full opportunity to disadvantaged and minority business enterprises to submit a show of interest in response to this invitation and will not discriminate against any interest firm or individual on the grounds of race, creed, color, sex, age, handicap or national origin in the contract award.

For more details, contact Mayor Tammy Crue-Hawkins at (304) 226-3101 (Town Hall) or (304) 644-0700 (cell).
Tammy Crue-Hawkins,
Mayor
(608107)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

50.
NOTICE OF SALE
UNDER DEED
OF TRUST

Under authority of a certain Deed of Trust from Edison Chad Lude and Tiffany L. Lude, dated the 27th day of June, 2011 and recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book 3805, at page 921; default having been made in the payment of the obligations secured by said Deed of Trust and sale having been requested by the beneficial owner, that also appointed a Substitute Trustee under a Notice of Appointment of Substitute Trustee dated June 3, 2015 and recorded in the said County Clerk’s Office in Book 4118, at page 336, the undersigned will offer for sale at the front door of the Courthouse of Kanawha County (Virginia Street Entrance), Charleston, West Virginia, on Friday, September 11, 2015 at 9:30 o’clock a.m., that certain real estate conveyed by said Deed of Trust as described on the Exhibit “A” attached hereto and made a part hereof.

And being the same property heretofore acquired by Edison Chad Lude and Tiffany L. Lude by Deed dated September 6, 2001 from Edison Chad Lude, and of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia in Book 2534, at page 362.

The above described real estate will be conveyed by the undersigned to the purchaser by Deed without warranty of any kind, express or implied, and made subject to all property taxes, prior liens, including any liens for sewer service assessed by any municipality or public service district, reservations, encumbrances, restrictions, right of way, easements, covenants, conveyances and conditions of record in said Clerk’s Office and affecting the subject property.

The subject property will be sold in AS IS condition. The undersigned shall be under no duty to cause any existing tenant or person occupying the subject property to vacate said property.
TERMS OF SALE

Cash in hand on day of sale. The above-described real estate will be sold by the undersigned by auction to the highest bidder subject to the right of the undersigned to reject all bids if in his opinion they are inadequate. The owner of the indebtedness secured by the above described deed of trust and the owner of any other interest in the property to be sold shall have the right to bid.
CONTINUANCE –
ADJOURNMENT
OF SALE

The undersigned reserves the right to continue the sale, or to adjourn the sale, for a time, or from time to time, without further notice than announcement of the time and the place of sale as hereinabove set forth for any continuance or adjournment thereof.

Dated this the 31st day of July, 2015.
A. David Abrams, Jr.,
Substitute Trustee
(607440)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

51.
NOTICE OF TRUSTEE
SALE OF VALUABLE
REAL ESTATE

Pursuant to the authority vested in the undersigned by deed of trust dated the 26th day of January 2007, signed by David Jones and Dareen Jones, husband and wife, as joint tenants with the right of survivorship, to E. Dennis White, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 3438, at page 859, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor and present holder of the note, said Trustee will sell at public auction at 10:45 o’clock A.M. on the
8th day of SEPTEMBER 2015

at the front doors of the Courthouse in Kanawha County in Charleston, West Virginia the following described real estate:

All that parcel of land in Poca District on the waters of Tuppers Creek of the Pocatalico River, Kanawha County, State of West Virginia, as more fully described in Deed Book 2525, Page 206, being more particularly described as a metes and bounds property with plat of record in Deed Book 2379 at page 852 and containing 1.223 AC more or less.

Excepting: Point .330 AC which was originally conveyed out to Patrick E. & Bonnie L. Shamblin in Deed Book 2682-340 and then conveyed back in in Deed Book 2719-834 and thereafter conveyed back out to Eric D. & Denise L. McKinney in Deed Book 2724-964.

Reference is also made to the aerial photograph of the residence upon the hearing of described realty as shown in the Kanawha County Assessors’ Office tax map with Poca district 30A-34 leaving this property according to the assessor with a residue of .73 AC.

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:
1998 Tolley Dr.,
Sissonville,
West Virginia 25320

TERMS OF SALE: Cash in hand on day of sale or within 30 days of date of sale upon terms to be agreed upon between Trustee and successful bidder, time being of the essence; payment for unpaid real estate taxes to be assumed by the purchaser. The Trustee does not warrant title or fitness to this property; it is being purchased as is; this is a buyer beware sale and any buyer is advised to retain counsel before the sale. If there is any part of the process of sale which is found to be objectionable, the Trustee reserves the right to cancel the sale. No purchaser should take possession or make improvements in the premises until the Trustee deed is delivered or recorded. A third party purchaser at sale will be required to pay the purchase price plus all recording and transfer fees.

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

FEDERAL TAX LIEN: In the event that there are Federal Tax Liens against the property, the United States would have the right to redeem the property within a period of 120 days from the date of such sale or the period allowable for redemption under local law, whichever is longer.

The party(ies) secured by the Deed of Trust reserve the right to purchase the property at such sale. If the purchaser at sale is unable to complete the terms of purchase within 30 days, the Trustee reserves the right to transfer the property to the next highest bidder.

Any sale hereunder may be adjourned from time to time without any notice other than oral proclamation at the time and place appointed for this sale or by posting of a notice of same. Should the Trustee not appear at the time appointed for the sale and there is no notice posted of a continuance please contact the office of the Trustee to make further inquiry. Any sale may be conducted or adjourned by the designated agent or attorney of the Trustee. The undersigned is fully vested with the authority to sell said property as Trustee by instrument of record.

Should any party have any inquires, objections to the sale or protests regarding the sale, or requests regarding the sale, please notify the trustee below by one of the means of communications set forth below.
GOLDEN & AMOS, PLLC,
TRUSTEE
543 Fifth Street,
P.O. Box 81
Parkersburg, WV 26102
Telephone (304) 485 3851
Fax (304) 485-0261
E-mail: vgolden@
goldenamos.com

Lender: Green Tree
Processor: Victor / Ext. 12
JonesDavid NTS / cclem
/ foreclosure notices – 2105

(607915)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

52.
NOTICE OF TRUSTEE
SALE OF VALUABLE
REAL ESTATE

Pursuant to the authority vested in the undersigned by deed of trust dated the 27th day of May, 2003, signed by Patrick Cottrell to Nicholas W. Johnson, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 2991, at page 346, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor/Servicer, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor/Servicer and present holder of the note, said Trustee will sell at public auction at 10:45 o’clock, a.m. on the
8th day of SEPTEMBER 2015

at the front doors of the Courthouse in Kanawha County in Charleston, West Virginia the following described real estate:

All that certain lot, tract or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the City of Charleston, Kanawha County, West Virginia, consisting of all of the lot laid down and designated as Lot Number Eighty-nine (89) bounded as follows:

On its southern line by Lot Number Eighty-eight (88), on its northern line of Lot Number Ninety (90), on its western line by Summit Drive, formerly Fairview Drive, and on its eastern line by a walkway and Edgewood Drive, on the map of Fairview, entitled, “Second Revision of Fairview”, made by Plumley-Walters Engineering Company, dated June 28, 1924, and filed and recorded in the aforesaid Clerk’s Office in Map Book 5, at pages 36 and 37, and more particularly described as follows:

BEGINNING at a point in the easterly line (erroneously described westerly line in the prior deed) of Summit Drive, formerly Fairview Drive, common corner of Lots 88 and 89, said point bearing N. 1° 00′ E. 6.04 feet from an iron pipe shown as station “500” on the map entitled, “Second Revision of Fairview, Charleston, W.Va., by Plumley Walters Engineering Company, revised June 28, 1924”, filed and recorded in the aforesaid Clerk’s Office in Map Book 5, at page 36 and 37, thence with said Summit Drive, N. 1° 00′ E. 56.12 feet to common corner of Lots 89 and 90; thence leaving said Drive and with line of said Lot 90, S. 62° 00′ E. 224.88 feet to an iron pipe in the southerly line of Edgewood Drive; thence with said Drive S. 31° 30′ E. 8 feet to an iron pipe, corner to a walkway; thence with said walkway, S. 28° 00′ W. 45.94 feet to corner of Lot No. 88; thence with the line of said Lot No. 88, N. 62° 00′ W. 206.29 feet to the beginning, and containing one-quarter of an acre, more or less.

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:
1231 Edgewood Drive
Charleston, WV 25302

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

Lender: Fifth Third
Mortgage Company
Processor: Liz/Ext. 34
CottrellPatrick.ntc/kj
CottrellPatrick NTS / cclem
/foreclosure notices – 2015

(608018)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

53.
NOTICE OF TRUSTEE
SALE OF VALUABLE
REAL ESTATE

Pursuant to the authority vested in the undersigned by deed of trust dated the 28th day of May, 2010, signed by Cameron M. Welch and Sagit Welch, husband and wife, to Douglas McElwee, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 3727, at page 965, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor and present holder of the note, said Trustee will sell at public auction at 10:45 o’clock, a.m. on the
8TH DAY OF
SEPTEMBER 2015

at the front doors of the Courthouse in Kanawha County in Charleston, West Virginia the following described real estate:

Land situated in the City of South Charleston in the County of Kanawha in the State of West Virginia:

All that certain lot[s] or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in what is known as the “Park Addition” in the City of South Charleston, South Charleston District, Kanawha County, West Virginia, being all of Lot No Four Hundred Twenty Six (426), as shown and designated on the map of the L.C. Massey Park Addition to Montrose, filed and recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Map Book 5, at page 65, fronting forty (40) feet on the southerly line of Forest Circle (formerly Forest Avenue).

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:
408 Forest Circle,
Charleston,
West Virginia 25303

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

Lender: Bank of America
Processor:Kristi/Ext. 27
(WelchCameron.nts/mbaker/
finishedforeclosure2015)

(607792)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

54.
NOTICE OF TRUSTEE
SALE OF VALUABLE
REAL ESTATE

Pursuant to the authority vested in the undersigned by deed of trust dated the 29th day of December 2010, signed by Lizzette M. Torres, an unmarried woman, to Dru A. Shope, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 3770, at page 659, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor and present holder of the note, said Trustee will sell at public auction at 10:45 o’clock A.M. on the

8th day of SEPTEMBER 2015

at the front doors of the Courthouse in Kanawha County in Charleston, West Virginia the following described real estate:

All those two certain tract or parcels of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the City of St. Albans, Kanawha County, West Virginia, and being all of Lots Numbers Twenty Three (23) and Twenty Four (24), in Block “D”, of Section Five (5) of the High Lawn, also in previous deeds called Highlawn Addition to St. Albans, as set out, shown, laid down and designated upon a map or plat entitled “High Lawn Addition to ST. Albans Section 5”, which said map or plat is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Photostatic Map Book 3, at pages 178; said lots combined form a tract of land which fronts sixty (60) feet on the southerly line of Cleveland Avenue, and extends back therefrom in a southerly direction, between parallel lines, one hundred ten (110) feet to the northerly line of a ten (10) foot alley.

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:

2321 Cleveland Ave.,
Saint Albans,
West Virginia 25177

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

Lender: Fifth Third
Processor: Liz / Ext. 34
TorresLizzette NTS / cclem /
foreclosure notices – 2015

(608023)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

55.
NOTICE OF TRUSTEE
SALE OF VALUABLE
REAL ESTATE

Pursuant to the authority vested in the undersigned by deed of trust dated the 30th day of April 2013, signed by William A. Gannon and Marsha R. Gannon, husband and wife, to Dru A. Shope, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 3954, at page 568, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor and present holder of the note, said Trustee will sell at public auction at 10:45 o’clock a.m. on the
8th day of SEPTEMBER 2015

at the front doors of the Courthouse in Kanawha County in Charleston, West Virginia the following described real estate:

All of the following described real estate, together with the improvements thereon and the appurtenances thereunto belonging, situate in Jefferson District, Kanawha County, West Virginia, and being all of Lot Number Fifty Six (56), Indian head Phase II, Section Two as shown upon the map of Indian head Phase II Section II dated November 30, 1998, recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia in Map Book 54 at page 71.

For the consideration aforesaid, the party of the first part does further GRANT and CONVEY unto the parties of the second part, their heirs, assigns and successors in title, the right to use the streets and roads in said subdivision, as shown upon maps recorded in the aforesaid Clerk’s Office for purposes of ingress and egress to and from the real estate herein conveyed.

This conveyance is made subject to the terms and conditions of the Declaration of Protective Covenants and Restrictions dated December 19, 1997, recorded in the aforesaid Clerk’s office in Deed Book 2431, Page 818.

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:
6 Indian TRL,
Saint Albans,
West Virginia 25177

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

Lender: Fifth Third
Processor: Liz / Ext 34
GannonWilliam NTS / cclem
/foreclosure notices – 2105

(608013)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

56.
NOTICE OF TRUSTEE SALE
OF VALUABLE REAL ESTATE

Pursuant to the authority vested in the undersigned by deed of trust dated the 26th day of November, 2007, signed by Janet L. Vinyard, to Metz Law Offices, Trustee, which said deed of trust is of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 3523, at page 384, and Golden & Amos, PLLC, Trustee having been requested so to do by the Secured Creditor, and default having been made under the terms and conditions of said deed of trust, and the provisions in said deed of trust concerning acceleration having been complied with by the Secured Creditor and present holder of the note, said Trustee will sell at public auction at 10:45 o’clock, a.m. on the
8TH DAY OF SEPTEMBER 2015

at the front doors of the Courthouse in Kanawha County in Charleston, West Virginia the following described real estate:

Situate in the City of Charleston, Kanawha County, West Virginia, in Charleston South Annex Tax District, and being known and designated as all of Lot B-3 of HAMLET TOWNHOUSES, as the same is shown upon that certain map or plat thereof entitled, “PLAT OF SURVEY SHOWING THE ‘HAMLET TOWNHOUSES’ A TOWNHOUSE SUBDVISISION BEING A PART OF SECTION THREE OAKWOOD ADDITION TO THE CITY OF CHARLESTON, CHARLESTON SOUTH ANNEX, KANAWHA COUNTY, WEST VIRGINIA, SCALE: 1″=30′ March 3, 1987, JAMES F. HORES & SANDRA P. HORES, OWNERS AND DEVELOPERS, PREPARED BY J. BRUCE HAGER, W.V.L.L.S. NO. 577”, which map is recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Map Book 42, at page 5.

Along with an undivided interest in and to the “Common Area” of said Hamlet Townhouses, said “Common Area” to include the right of way of the private road delineated upon the aforesaid recorded subdivision in plat and referred to thereon as Hamlet Way, or any portion thereof, utility lines and easements therefore, refuse storage areas, parking areas, and utilization of light poles, which interest is more particularly set forth in the Declaration hereinafter referred to.

Along with certain easement and right of way, in, on, over and under the Lot B-4 of HAMLET TOWNHOUSES for the installation, construction, repair and maintenance of wires, lines, conduits and the necessary of proper attachments to and in connection with certain air conditioning equipment located upon said lot B-4 of HAMLET TOWNHOUSES, which right of way and easement is for the benefit of the owner or owners of Lot B-3 of Hamlet Townhouses, and their respective heirs and assigns.

Subject to that certain “DECLARATION OF PROTECTIVE COVENANTS, CONDITIONS, RESTRICTIONS AND RESERVATIONS PERTAINING TO HAMLET TOWNHOUSES, CITY OF CHARLESTON, CHARLESTON SOUTH ANNEX TAX DISTRICT, KANAWHA COUNTY, WEST VIRGINIA” dated the 5th day of June, 1987, and recorded in the aforesaid Clerk’s Office in Deed Book 2167, at page 13.

It is understood and agreed that the wall separating the divisions of the townhouse with Hamlet Townhouse shall be and are party walls for the use and benefit of the property herein conveyed, and the properties adjoining the same on either side. The provisions of this instrument as well as those contained in the aforesaid Declaration for such party wall shall be deemed to be covenants running with the land herein conveyed, and shall be be valid and binding upon the party of the first part herein, her heirs and assigns, and the said party of the second part herein, his heirs and assigns.

It is the intention of this notice to sell the secured property by proper description as was intended to be transferred and conveyed in the aforesaid deed of trust.

The above described real estate is reported to have a mailing address of:
203 Hamlet Way,
Charleston, West Virginia 25314-2022

Trustee at sale is under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

GOLDEN & AMOS, PLLC, TRUSTEE
543 Fifth Street, P.O. Box 81
Parkersburg, WV 26102
Telephone (304) 485 3851
Fax (304) 485-0261
E-mail: [email protected]

Lender: Nationstar Mortgage LLC
Processor: Kristi/Ext. 27
(VinyardJanet.nts/mbaker/finishedforeclosure2015)

(607793)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

57.
NOTICE

Please be advised that on Thursday, September 24, 2015, at 6:00 p.m., the Kanawha County Commission will consider an Order permanently moving Precinct 147 from Upper Kanawha Valley Enterprise Community, to Chelyan Methodist Church, 105 Church Street, Chelyan, WV 25305.
This will be a permanent change and will be effective immediately.
KANAWHA COUNTY COMMISSION
W. Kent Carper,
President
Henry C. Shores,
Commissioner
Dave Hardy,
Commissioner
(608146)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

58.
NOTICE

Please be advised that on Thursday, September 24, 2015, at 6:00 p.m., the Kanawha County Commission will consider an Order permanently moving Precincts 365 and 366from the Department of Health & Human Resources to God’s Lighthouse Church, 4151 Washington Street West, Charleston, WV 25313.
This will be a permanent change and will be effective immediately.
KANAWHA COUNTY COMMISSION
W. Kent Carper,
President
Henry C. Shores,
Commissioner
Dave Hardy,
Commissioner
(608144)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

59.
NOTICE

Please be advised that on Thursday, September 24, 2015, at 6:00 p.m., the Kanawha County Commission will consider an Order permanently moving Precincts 435, 436, and 436A from the WV National Guard Armory to Capital High School, 1500 Greenbrier Street, Charleston, WV.
This will be a permanent change and will be effective immediately.
KANAWHA COUNTY COMMISSION
W. Kent Carper,
President
Henry C. Shores,
Commissioner
Dave Hardy,
Commissioner
(608143)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

60.
ORDER OF
PUBLICATION
FAMILY COURT OF
KANAWHA COUNTY

Tia Dawn Bennett
Plaintiff

Civil Action No.
15-D-1217

Jonathan Edward
Bennett
Defendant

The object of this suit is to obtain a divorce from the bonds of matrimony.

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the plaintiff has used due diligence to ascertain the whereabouts of Jonathan E. Bennett without effect it is hereby ordered that Jonathan E. Bennett, serve upon Tia D. Bennett, plaintiff, whose address is 4633 Washington St. W, Charleston, WV 25313 an answer, including any related counter claim or defense you may have to the complaint filed in this action on or before September 26, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the complaint.
A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court August 17, 2015.
Cathy S. Gatson
Clerk of Court
(607815)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

61.
ORDER OF
PUBLICATION
FAMILY COURT OF
KANAWHA COUNTY

Jessica White
Plaintiff

John Ray White
Defendant

Civil Action No.
15-D- 1273

The object of this suit is to obtain a divorce from the bonds of matrimony.

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the plaintiff has used due diligence to ascertain the whereabouts of John Ray White without effect it is hereby ordered that John Ray White, serve upon Jessica White, plaintiff, whose address is 1321 Moore Ave., Dunbar, WV 25064, an answer, including any related counter claim or defense you may have to the complaint filed in this action on or before October 1, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the complaint.
A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court August 25, 2015.
Cathy S. Gatson
Clerk of Court
(608552)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

62.
ORDER OF
PUBLICATION
FAMILY COURT OF KANAWHA COUNTY

Lisa Conley
Plaintiff(s)

Civil Action # 15-FIG-215

Amanda Shaffer
Defendant(s)

The object of this suit is to obtain Guardianship
TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the plaintiff has used due diligence to ascertain the whereabouts of Amanda Shaffer without effect is hereby ordered that Amanda Shaffer serve upon Lisa Conley, plaintiff, whose address is 312 30th St., West, Charleston, WV 25387, an answer, including any related counter claim or defense you may have to the complaint filed in this action on or before September 25, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the complaint.
A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court August 20, 2015.
Cathy S. Gatson
Clerk
(608313)

Class: 983 Gazette Legal Ads Last appeared: 08-26-2015

63.
ORDER OF
PUBLICATION
FAMILY COURT OF
KANAWHA COUNTY

Susanne Cornish
Plaintiff

Civil Action No.
15-D-1256

Norman Stanley Cornish
Defendant

The object of this suit is to obtain a divorce from the bonds of matrimony.

TO THE ABOVE NAMED DEFENDANT:

It appearing by affidavit filed in this action that the plaintiff has used due diligence to ascertain the whereabouts of Norman Stanley Cornish without effect it is hereby ordered that Norman Stanley Cornish, serve upon Susanne Cornish, plaintiff, whose address is 606 Rambling Hill Rd., Elkview, WV 25071 an answer, including any related counter claim or defense you may have to the complaint filed in this action on or before October 3, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the complaint.
A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court August 24, 2015.
Cathy S. Gatson
Clerk of Court
(608376)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

64.
ORDER OF
PUBLICATION

FAMILY COURT OF
KANAWHA COUNTY
WEST VIRGINIA

IN RE:
THE MARRIAGE OF:
Kimberly June Miller
Petitioner
And
Patrick Lee Evans
Respondent.

Civil Action No.
15-D-1188

THE OBJECT OF THIS SUIT IS TO OBTAIN A DIVORCE.

TO THE ABOVE NAMED RESPONDENT:

It appearing by affidavit filed in this action that Patrick Lee Evans is a non-resident of the State of West Virginia, it is hereby ordered that Patrick Lee Evans serve upon Kimberly June Miller, Petitioner, whose address is 2157 21st Street, Nitro, WV 25143, an Answer, including any related counterclaim or defense you may have to the Petition for Divorce filed in this action on or before September 29, 2015. If you fail to do so, thereafter judgment, upon proper hearing and trial, may be taken against you for the relief demanded in the Petition.
A copy of said Petition can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court August 19, 2015.
Cathy S. Gatson
Clerk of Court
(608050)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

65.
ORDER OF
PUBLICATION

IN THE CIRCUIT COURT OF KANAWHA COUNTY,
WEST VIRGINIA

DANNY D. CARPENTER,
Plaintiff,

Civil Action No. 15-C-870

KELLIE RAINES, Individually and as Guardian for AIDEN PRATT
Defendant.

The object of the above entitled action is partition of jointly owned real estate situate on the waters of Aarons Branch, Union District,, Kanawha County, West Viriginia, and being Lot Fifteen-A (15-A) of the Re-subdivision of Wood Krest, all as further described in Deed Book 1326, at Page 669, which said Deed is recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia.
And it appearing by affidavit filed in this action that respondent, Kellie Raines, individually and as Guardian for Aiden Pratt, cannot be located, it is hereby ordered that KELLIE RAINES do serve upon STEPHEN P. SWISHER
, Petitioners’ attorney, whose address is 1230 Ohio Avenue, Dunbar, WV 25064, an Answer or other defense to the Petition filed in this action on or before October 5, 2015, otherwise judgment by default will be taken against you at anytime thereafter.
A copy of said Petition can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court August 19, 2015.
Cathy S. Gatson,
Clerk
(608186)

Class: 983 Gazette Legal Ads Last appeared: 08-26-2015

66.
ORDER OF
PUBLICATION
IN THE MAGISTRATE COURT OF KANAWHA COUNTY,
WEST VIRGINIA

EAB DMM LLC
84 Silver Maple Ridge
Charleston, WV 25306
PLAINTIFF
V.
Tom Kessel
105 Silver Maple Ridge Apt 6
Charleston, WV 25306

Civil Action No. 15C-2072

The object of the above entitled action is To obtain a judgment against the Defendants Tom Kessel and possession of property located at 105 Silver Maple Ridge Apt 6, Charleston, WV 25306
And it appearing by an affidavit filed in this action that DEFENDANTS WAS NOT SERVED, EITHER PERSONALLY OR BY WAY OF SERVICE UPON AN APPROPRIATE FAMILY MEMBER, EVEN AFTER USING DUE DILIGENCE THE PLAINTIFF WAS UNABLE TO DISCOVER THE RESIDENCE OR WHEREABOUTS OF THE DEFENDANT.

it is ordered that Tom Kessel do serve upon KANAWHA CO. MAGISTRATE COURT, magistrate, whose address is 111 COURT ST. CHARLESTON, WV 25301, an answer or other defense to the complaint filed in this action on or before 30 DAYS, otherwise judgment by default will be taken against Tom Kessel at any time thereafter. A copy of said complaint can be obtained from the undersigned Clerk at her office.
Entered by the Clerk of said Court August 21, 2015.
Angela Cincinnati
Magistrate Court Clerk
(608157)

Class: 983 Gazette Legal Ads Last appeared: 08-25-2015

67.
PUBLIC NOTICE

The next meeting of the Board of Directors and Board Committees of the West Virignia University Hospitals, Inc. will convene on Friday, August 28, 2015 at the following times and locations:
• Board of Directors
meeting at 12:30 p.m. at
the Erickson Alumni
Center, Room 203,
Morgantown, WV.
• Finance Committee
meeting at 9:00 a.m. at
the Erickson Alumni
Center, Room 203,
Morgantown, WV.
• Quality & Patient
Safety Committee
meeting at 10:00 a.m. at
the Erickson Alumni
Center, Room 115,
Morgantown, WV.

All meeting are open to the public.
(605496)

Class: 983 Gazette Legal Ads Last appeared: 08-25-2015

68.
PUBLIC NOTICE
DR-4236-WV

The Federal Emergency Management Agency (FEMA) hereby gives notice to the public of its intent to reimburse eligible applicants for eligible costs to repair and/or replace facilities damaged by Severe Storms, Straight-line Winds, Flooding, Landslides, and Mudslides occurring from July 10, 2015 to July 14, 2015. This notice applies to the Public Assistance (PA) and Hazard Mitigation Grant (HMGP) programs implemented under the authority of the Robert T. Stafford Disaster Relief and Emergency Assistance Act, 42 U.S.C. §§ 5121-5207.

Under a major disaster declaration (FEMA 4236-DR-WV) signed by the President on August 7, 2015, the following counties have been designated adversely affected by the disaster and eligible for PA: Braxton, Clay, Lincoln, Logan, Nicholas, Roane, Webster, and Wood. Additional counties may be designated at a later date. All counties in the State of West Virginia are eligible for HMGP.

This public notice concerns activities that may affect historic properties, activities that are located in or affect wetland areas or the 100-year floodplain, and critical actions within the 500-year floodplain. Such activities may adversely affect the historic property, floodplain or wetland, or may result in continuing vulnerability to flood damage.

Presidential Executive Orders 11988 and 11990 require that all Federal actions in or affecting the floodplain or wetlands be reviewed for opportunities to relocate, and evaluated for social, economic, historical, environmental, legal and safety considerations. Where there is no opportunity to relocate, FEMA is required to undertake a detailed review to determine what measures can be taken to minimize future damages. The public is invited to participate in the process of identifying alternatives and analyzing their impacts.

FEMA has determined that for certain types of facilities there are normally no alternatives to restoration in the floodplain/wetland. These are facilities that meet all of the following criteria: 1) FEMA’s estimate of the cost of repairs is less than 50{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c} of the cost to replace the entire facility, and is less than $100,000; 2) the facility is not located in a floodway; 3) the facility has not sustained major structural damage in a previous Presidentially declared flooding disaster or emergency; and 4) the facility is not critical (e.g., the facility is not a hospital, generating plant, emergency operations center, or a facility that contains dangerous materials). FEMA intends to provide assistance for the restoration of these facilities to their pre-disaster condition, except that certain measures to mitigate the effects of future flooding or other hazards may be included in the work. For example, a bridge or culvert restoration may include a larger waterway opening to decrease the risk of future washouts.

For routine activities, this will be the only public notice provided. Other activities and those involving facilities that do not meet the four criteria referenced above are required to undergo more detailed review, including study of alternate locations. Subsequent public notices regarding such projects will be published if necessary, as more specific information becomes available.

In many cases, an applicant may have started facility restoration before Federal involvement. Even if the facility must undergo detailed review and analysis of alternate locations, FEMA will fund eligible restoration at the original location if the facility is functionally dependent on its floodplain location (e.g., bridges and flood control facilities), or the project facilitates an open space use, or the facility is an integral part of a larger network that is impractical or uneconomical to relocate, such as a road. In such cases, FEMA must also examine the possible effects of not restoring the facility, minimize floodplain/wetland impacts, and determine both that an overriding public need for the facility clearly outweighs the Executive Order requirements to avoid the floodplain/wetland, and that the site is the only practicable alternative. The State of West Virginia and local officials will confirm to FEMA that proposed actions comply with all applicable State and local floodplain management and wetland protection requirements.

FEMA also intends to provide HMGP funding to the State of West Virginia to mitigate future disaster damages. These projects may include construction of new facilities, modification of existing, undamaged facilities, relocation of facilities out of floodplains, demolition of structures, or other types of projects to mitigate future disaster damages. In the course of developing project proposals, subsequent public notices will be published if necessary, as more specific information becomes available.

The National Historic Preservation Act requires Federal agencies to take into account the effects of their undertakings on historic properties. Those actions or activities affecting buildings, structures, districts or objects 50 years or older or that affect archeological sites or undisturbed ground will require further review to determine if the property is eligible for listing in the National Register of Historic Places (Register). If the property is determined to be eligible for the Register, and FEMA’s undertaking will adversely affect it, FEMA will provide additional public notices. For historic properties not adversely affected by FEMA’s undertaking, this will be the only public notice.

As noted, this may be the only public notice regarding the above-described actions under the PA and HMGP programs. Interested persons may obtain information about these actions or a specific project by writing to the Federal Emergency Management Agency, Disaster Field Office, 426 Leon Sullivan Way, Charleston WV 25301or by calling 304-348-4200 or by faxing 304-345-6617.

Comments should be sent in writing to Federal Coordinating Officer Regis Phelan, at the above address within 15 days of the date of this notice.
(608114)

Class: 983 Gazette Legal Ads Last appeared: 08-25-2015

69.
PUBLIC NOTICE OF CHANGE IN RATES
WITH PROPOSED EFFECTIVE DATE

NOTICE is hereby given that Malden Public Service District (the “District”), a public utility, has filed with the PUBLIC SERVICE COMMISSION OF WEST VIRGINIA, a tariff containing increased rates, tolls and charges for furnishing sewerage service to approximately 3,357 customers near Malden, Campbells Creek, Rand, Dupont City, George’s Creek, Dry Branch, all in Kanawha County, West Virginia.

The proposed increased rates and charges will become effective September 16, 2015 unless otherwise ordered by the Public Service Commission and will produce approximately $248,759 annually in additional revenue, an increase of 15.33{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}. The average monthly bill for the various classes of customers will be changed as follows:

TYPE OF CUSTOMER ($) INCREASE INCREASE ({4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c})
Residential (3,320 gallons) $5.32 16.01{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}
Commercial (11,029 gallons) $17.65 15.99{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}

The District has no resale customers.

The increases shown are based on averages of all customers in the indicated class. Individual customers may receive increases that are greater or less than average. Furthermore, the requested rates and charges are only a proposal and are subject to change (increases or decreases) by the Public Service Commission in its review of this filing. Any increase in rates and charges will not become effective until authorized and approved by the Public Service Commission. (If a hearing is scheduled, notice will be given of the time and place of hearing.)

Anyone desiring to protest or intervene should file a written protest or petition to intervene prior to September 16, 2015 unless otherwise modified by Commission order. Failure to timely protest or intervene can affect your rights to protest any rate increases and to participate in future proceedings. All protests or requests to intervene should briefly state the reason for the protest or intervention. Requests to intervene must comply with the Commission’s rules on intervention set forth in the Commission’s Rules of Practice and Procedure. All protests and petitions to intervene should be addressed to the Executive Secretary, Public Service Commission of West Virginia, Post Office Box 812, Charleston, West Virginia, 25323.

A complete copy of this tariff, as well a representative of the District to provide any information requested concerning it, is available to all customers, prospective customers, or their agents at any of the following offices of the District: 100 PSD Drive, Tad, West Virginia.

A copy of the proposed rates is available for public inspection at the office of the Executive Secretary of the PUBLIC SERVICE COMMISSION at 201 Brooks Street, Charleston, West Virginia.
(607794)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

70.
Public Sale

Notice is here by given that on September 3rd 2015 John S. Davis Auctioneer, license # 1373 Executive Administer for U-haul Company of WV will be offering for sale under Judicial Lien process, by public auction the following units. The goods to be sold are generally described as household goods. The terms of the sale will be cash only. U-haul Company of WV reserves the right to refuse any and all bids. The sale will be conducted at the following location and will begin at or after 9:00 am and continue day-by-day until all units are sold.

U-haul Center of St. Albans
6114 MacCorkle Ave
St.Albans, WV 25177

Steven Sanders # 1000
Katinamarie Mendoza # 1007
Melissa Ford # 1018
Brittney Smalley # 2003
Greg Moore # 2008
(606194)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

71.
REQUEST FOR
PROPOSALS

Audit/Review Services

The Kanawha County Commission seeks proposals, from those CPA firms appointed to conduct audits and reviews of local government entities (“qualified firms”) in accordance with the provisions of West Virginia Code 6-9-7, to perform a Single Audit of its records for the Fiscal Year 2014-15.

To determine if you are qualified and to obtain a Request for Proposals- Audit Engagement RFP, please contact Kim Fleck at:

Kanawha County
Commission
P.O. Box 3627
407 Virginia Street, East
Charleston, WV 25336
Phone: (304) 357-0179

Proposals will be accepted until 11:00 a.m. Friday, September 18, 2015.
KANAWHA COUNTY
COMMISSION
Charleston, West Virginia
(607795)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

72.
REQUEST FOR
QUOTATIONS

The West Virginia Parkways Authority will accept sealed proposals for the following:
Contract TB-1-16
REPLACEMENT OF
TAMARACK BOILERS

Bid proposals will be received at the office of the WV Parkways Authority, Administration Building, 3310 Piedmont Road, Charleston, WV until 3PM on Tuesday, September 1st, 2015.

Specifications are available by at www.wvturnpike.com.

The WVPA is an Equal Opportunity Employer
(607441)

Class: 983 Gazette Legal Ads Last appeared: 08-25-2015

73.
REQUEST FOR
QUOTATIONS FOR
ANRITSU MODEL
S412E LMR MASTER,
500 KHZ TO 6 GHZ
LAND MOBILE RADIO
ANALYZER AND
SIGNAL GENERATOR,
VECTOR ANALYZER,
SPECTRUM ANALYZER
AND ACCESSORIES
FOR THE KANAWHA
COUNTY COMMISSION

Take notice that the Kanawha County Commission will accept sealed quotations for Anritsu Model S412E LMR Master, 500 kHz to 6 GHz Land Mobile Radio Analyzer and Signal Generator, Vector Analyzer, Spectrum Analyzer and Accessories for the Kanawha County Commission. Quotations must be received on or before Wednesday, September 9, 2015, at 11:00 a.m. in the Kanawha County Commission Purchasing Department located at 407 Virginia Street, East, Third Floor, Room 229, Charleston, West Virginia 25301 (P.O. Box 3627, Charleston, WV 25336).

Specifications may be obtained from the Kanawha County Commission Purchasing Department, 407 Virginia Street, East, Third Floor, Room 229, Charleston, West Virginia 25301 (P.O. Box 3627, Charleston, WV 25336), 304-357-0115 or at http://www.kanawha.us/Commission/Purchasing.

The Kanawha County Commission reserves the right to reject any and/or all quotations that do not meet the specifications and to waive any informality in bidding.
KANAWHA COUNTY
COMMISSION

KANAWHA COUNTY,
WEST VIRGINIA
(607912)

Class: 983 Gazette Legal Ads Last appeared: 08-26-2015

74.
REQUEST FOR
QUOTATIONS FOR
COMMUNITY OUTDOOR
WARNING SIRENS
FOR THE KANAWHA
COUNTY COMMISSION

Take notice that the Kanawha County Commission will accept sealed quotations for community outdoor warning sirens for the Kanawha County Commission. Quotations must be received on or before Tuesday, September 15, 2015, at 11:00 a.m. in the Kanawha County Commission Purchasing Department located at 407 Virginia Street, East, Third Floor, Room 229, Charleston, West Virginia 25301 (P.O. Box 3627, Charleston, WV 25336).

The Kanawha County Commission reserves the right to reject any and/or all quotations that do not meet the specifications and to waive any informality in bidding.
KANAWHA COUNTY
COMMISSION
KANAWHA COUNTY,
WEST VIRGINIA
(608407)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

75.
REQUEST FOR
QUOTATIONS FOR
THREE NEW 2015
CHEVROLET TAHOE’S
FOR THE KANAWHA
COUNTY COMMISSION

Take notice that the Kanawha County Commission will accept sealed quotations for three (3) new 2015 Chevrolet Tahoe’s for the Kanawha County Commission. Quotations must be received on or before Tuesday, September 15, 2015, at 11:15 a.m. in the Kanawha County Commission Purchasing Department located at 407 Virginia Street, East, Third Floor, Room 229, Charleston, West Virginia 25301 (P.O. Box 3627, Charleston, WV 25336).

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

76.
REQUEST FOR
QUOTATIONS TO
REPLACE THE
FRONT STEPS OF THE
BOONE MAXWELL
LODGE LOCATED
AT CAMP VIRGIL TATE

Take notice that the Kanawha County Commission will accept sealed quotations to replace the front steps at the Boone Maxwell Lodge located at Camp Virgil Tate. A mandatory pre-bid conference will be held on Thursday, September 10, 2015, at 11:00 am, at the Boone Maxwell Lodge located at Camp Virgil Tate, 1400 Camp Virgil Tate Road, Charleston, WV 25312. Quotations must be received on or before Thursday, September 17, 2015, at 11:00 a.m. in the Kanawha County Commission Purchasing Department located at 407 Virginia Street, East, Third Floor, Room 229, Charleston, West Virginia 25301 (P.O. Box 3627, Charleston, WV 25336).

The Kanawha County Commission reserves the right to reject any and/or all quotations that do not meet the specifications and to waive any informality in bidding.
KANAWHA COUNTY
COMMISSION

KANAWHA COUNTY,
WEST VIRGINIA
(608113)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

77.
Solicitation of Bids

The City of Dunbar WV will be accepting bids to remove and replace a rubber roll roof, remove existing skylights and close openings, re-route vents as needed and make any other necessary repairs to the roofing system.

Roof requirements:

The material shall be EPDM 60 mil minimum.

Bid shall include all necessary materials including fiber board, fasteners, adhesives, plates, seam tape, straps or any other items necessary for the proper installation of the roof.

Roofing materials shall be installed per Manufactures requirements.

Contractor requirements:

-A building permit is required. Building permit will be issued at no charge.

-All contractors (bidders) shall have a valid West Virginia Contractors license.

-A current Dunbar City contractor’s license.

-General liability insurance of $1,000,000.00 or more.

-Provide proof of Workers Compensation insurance or waiver.

-Be current on all Dunbar City taxes and fees.

-The project shall be completed within thirty (30) days of commencing.

Bids shall be submitted in a sealed envelope with “BINGO BUILDING ROOF” written on the outside of the envelope.

Bids will be received until 4:00 pm September 18, 2015. Bids received late will not be opened.

Bids may be either hand delivered or sent via post to:

City Clerk
210 12th Street
Dunbar, WV 25064

The City reserves the right to reject any and all bids at their discretion.

Bid opening will be 10:00 am September 21, 2015 at Dunbar City Hall Council Chamber.

To gain access to the roof contact Hokey Young at 304-546-4474 weekdays between 9:00 am & 6:00 pm.

Any questions should be directed to Hugh Leishman at 304-766-0217 M-F; 8:30-4:40
(607805)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

78.
STATE OF WEST VIRGINIA
DEPARTMENT OF
ENVIRONMENTAL
PROTECTION
DIVISION OF WATER
AND WASTE
MANAGEMENT

PUBLIC NOTICE

WEST VIRGINIA DEPARTMENT OF ENVIRONMENTAL PROTECTION’S, PUBLIC INFORMATION OFFICE, 601 57TH STREET, CHARLESTON SE, WEST VIRGINIA 25304-2345 TELEPHONE: (304) 926-0440.

APPLICATION FOR A WEST VIRGINIA NATIONAL POLLUTANT DISCHARGE ELIMINATION SYSTEM WATER POLLUTION CONTROL PERMIT

Public Notice No.:
L-78-15
Public Notice Date:
August 28, 2015

Paper:
Charleston Gazette Mail

The following has applied for a WV NPDES Water Pollution Control Permit for this facility or activity:

Appl. No.:
WV0116416

Applicant:
KUREHA CORPORATION
901 WEST DUPONT
AVENUE
BELLE, WV 25015

Location:
BELLE,
KANAWHA COUNTY

Latitude:
38:14:33
Longitude:
81:29:21

Receiving Stream:
Kanawha River

Activity:
To operate, and maintain a disposal system and best management practices for the direct discharge of untreated non-contact cooling water and storm water runoff via Outlet No. 001 into the Kanawha River.

Tier 2 and Tier 1 protection are afforded for the designated uses specified in 47 CSR 2, Section 6.

Business conducted:
Manufacturer of
polyglycolic acid.

Implementation:
NA

On the basis of review of the application, the “Water Pollution Control Act (Chapter 22, Article 11-8(a)),” and the “West Virginia Legislative Rules,” the State of West Virginia will act on the above application.

Any interested person may submit written comments on the draft permit and may request a public hearing by addressing such to the Director of the Division of Water and Waste Management within 30 days of the date of the public notice. Such comments or requests should be addressed to:

Director,
Division of Water and
Waste Management, DEP
ATTN: Lori Derrick,
Permitting Section
601 57th Street SE
Charleston, WV 25304-2345

The public comment period begins August 28, 2015 and ends September 27, 2015.

Comments received within this period will be considered prior to acting on the permit application. Correspondence should include the name, address and the telephone number of the writer and a concise statement of the nature of the issues raised. The Director shall hold a public hearing whenever a finding is made, on the basis of requests, that there is a significant degree of public interest on issues relevant to the Draft Permit(s). Interested persons may contact the public information office to obtain further information.

The application, draft permit and any required fact sheet may be inspected, by appointment, at the Division of Water and Waste Management Public Information Office, at 601 57th Street SE, Charleston, WV 25304-2345, between 8:00 a.m. and 4:00 p.m. on business days. Copies of the documents may be obtained from the Division at a nominal cost. Calls must be made 8:30 a.m. to 4:30 p.m. Monday through Friday.
(608663)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

79.
The City of Nitro will accept sealed bids for a New Magnum RHB304 550 ft. lb. Hammer (for Kubota SVL75) complete with bracket cap and installation and a Coneqtec AP 400HD 16″ Cold Planer complete with hoses and installation for SVL75 Kubota. Bids will be accepted at Nitro City Hall, 20th Street and 2nd Avenue, Nitro, WV or mailed to P. O. Box 308 Nitro, WV 25143. Bids will be accepted until 3:00 pm, September 11, 2015.
(608289)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

80.
The City of Nitro will conduct a public hearing on Tuesday, September 1, 2015 at 7:00 pm in Nitro City Council Chambers, 20th Street and Second Avenue, Nitro, WV. The purpose of the hearing is to hold public comment on Part Seven-Business and Taxation Code-Article 742- Emergency Services User Fee, Fire Protection Service Fee, Fire Service User Fee, Incident Response User Fee. The rates and charges for properties located outside the corporate limits of the city but within the city’s first due area are: (a)owner single family residential unit of any size-$150.00 per year or $37.50 per quarter; (b) owner of any residential unit with one or more detached structures exceeding 1000 square feet-an additional $75.00 or $18.75 per quarter; (c) owner-nonresidential unit structure-$.0675 per square foot.

Fire service contracts for non-resident businesses and residences: $250 plus $75 for each fire department apparatus on the scene for each half hour increment; fire service contract with owner of any business or residence located outside of but within three miles of the city fire service district, an annual assessed fee of $25 plus an amount equal to 60{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c} of the annual tax levied for current municipal purposes.

Charges for responding to fire calls outside the city when there is no fire service contract: $100 plus $100 per hour or part thereof for each fire department apparatus at the scene and $50 per hour or part thereof for each member of the fire department at the scene of the fire. False alarm response: $250 plus $100 per hour for each fire department apparatus at the scene, and $50 per hour or part thereof for each member of the fire department at the scene.

Charges for manufacturing, commercial, professional or other business establishment shall be calculated as follows: $2000 plus $500 per hour for each fire department apparatus at the scene and $200 per hour for each member of the fire department at the scene. False alarm response charges: $1000 plus $500 per hour for each fire department apparatus and $200 per hour for each member of the fire department at the scene.

A copy of the Ordinance Part 7-Business and Taxation Code-Article 742 is available in Nitro City Hall, 20th Street and 2nd Avenue, Nitro or by calling Nitro City Hall, 304-755-0707.
(608025)

Class: 983 Gazette Legal Ads Last appeared: 08-24-2015

81.
The Logan County Board of Education, 506 Holly Avenue, Logan, WV 25601, will accept sealed bids for paving projects at both Man High School’s football field and Chapmanville Middle School until 12 PM, September 11, 2015 at which time they will be publicly opened and read aloud. Bid documents may be obtained by emailing Ray Ellis at [email protected] or by calling 304-792-2044. The Logan County Board of Education reserves the right to reject any or all bids.
(608781)

Class: 983 Gazette Legal Ads Last appeared: 09-01-2015

82.
To:
Joshua Wayne Piscopo

In the Matter of
Aaron D. Walker

To Adopt N.J.H. an
Infant Under the Age 12
Case No. 15-A-63

Final Adoption Hearing
10-13-2015
11:30 am

4th Floor Judicial Annex
111 Court Street
Charleston, WV 25301

(607564)

Class: 983 Gazette Legal Ads Last appeared: 08-25-2015

83.
To: Venture One
Properties LLC
c/o West Virginia
Secretary of State
Building 1, Suite 157-K
1900 Kanawha Blvd., East
Charleston, WV 25305

Timothy S. Sizemore
PO Box 44
Nitro, WV 25143

Angela D. Sizemore
PO Box 44
Nitro, WV 25143
NOTICE OF
PUBLIC SALE

Under authority of a certain Deed of Trust dated December 16, 2005, from Timothy S. Sizemore and Angela D. Sizemore to Anthony Marks and Randall S. Coleman, Trustees, securing First Bank of Charleston, Inc., in the original principal amount of $359,550.00, of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Trust Deed Book 3313, at page 496, default having been made in the payment of the promissory note secured by said Deed of Trust, and sale having been requested in writing by the holder of the indebtedness secured, the undersigned, Raymond G. Dodson, Substitute Trustee, by virtue of Notice of Substitution of Trustee dated January 29, 2015, of record in the aforesaid Clerk’s Office in Book 4081, at page 479, and will offer for sale at the front door of the Kanawha County Courthouse in Charleston, West Virginia, on the 15th day of September, 2015, at 10:00 o’clock, the certain real estate conveyed in said Deed of Trust, as described as follows:

All of that certain lot or parcel of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the City of Nitro, Kanawha County, West Virginia and being known and designated as Lot 1829 18th Street in Area P of the Nitro Reservation as shown upon a map of the same of record in the office of the Clerk of the County Commission of Kanawha County, West Virginia, located, bounded and described by reference to the co-ordinate survey called “A Primary Reference System”: established by the United States Government (1918) covering Explosive Plant C, and being the same property as shown on a map prepared by Field Engineering Company entitled, “Map of Lot No. 1829, 18th Street, in Area “P” of the Nitro Reservation”, which is recorded in the Clerk’s office in Deed Book 1948, at page 126.

Being the same property conveyed unto Timothy S. Sizemore and Angela D. Sizemore, his wife, by deed dated November 30, 1999, from James W. Morris by Donnie M. Morris, his Committee, and Donnie M. Morris, his wife, of record in the Clerk’s office in Deed Book 2486, at page 407.

This Notice of Public Sale is made pursuant to an Order entered in the United States Bankruptcy Court for the Southern District of West Virginia.

This conveyance will be made subject to any and all reservations, exceptions, restrictions, rights of way and easements contained in prior deeds affecting said property of record in said Clerk’s office or visible on the ground.

This property will be conveyed by Trustee together with the hereditaments thereof and all building, structures and improvements now or hereafter situate thereon and all fixtures, materials, supplies, equipment, machinery and other property as is now or may hereafter be an accession thereto, be a fixture thereto, or be otherwise treated or deemed as a part of the land described herein, all of which is included in the term “property” as used herein. By way of example and not by way of limitation, such fixtures and accessions shall include heating, cooling and air-conditioning units, plumbing and electrical fixtures and equipment, built-in appliances of every kind, boilers, machinery, motors, wall-to-wall carpeting, storm doors and windows, awnings and all furnishings attached to the property.

The above-described real estate will be conveyed by the undersigned Trustee to the purchaser by deed containing a Covenant of Special Warranty and subject to all liens, reservations and exceptions appearing in the record of title, and to the lien of all unpaid taxes, if any, which are entitled to priority over the lien of the aforesaid deed of trust. Purchaser must pay all transfer taxes, real estate taxes and any costs related to the recording of any Deed from the Trustee herein.
TERMS OF SALE

Any successful bidder shall pay 10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c} of the sales price as a deposit in Certified Funds or Cash at the time of sale with the balance to be paid within 30 days from date of sale. The above-described real estate will be sold by the undersigned Substitute Trustee by auction to the highest bidder subject to the right of the Trustee to reject all bids if in his opinion they are inadequate. The owner of the indebtedness secured by the above-described deeds of trust and the owner of any other interest in the properties to be sold shall have the right to bid.
CONTINUANCE OR
ADJOURNMENT
OF SALE

The Substitute Trustee reserves the right to continue the sale, or adjourn the sale for a time, or from time to time, and the place of sale, as hereinabove set forth, or any continuance or adjournment thereof.

Dated this 14th day of August, 2015.
________________________
Raymond G. Dodson
Substitute Trustee
(607684)

Class: 983 Gazette Legal Ads Last appeared: 08-26-2015

84.
TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated December 2, 2002, and duly recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book No. 2913, at Page 528 and re-recorded in Book No. 2940, at Page 746, David M. Cossin and Angela D. Anderson did convey unto M. Glenn Turley, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated June 17, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by Wells Fargo Bank, N.A. to foreclose thereunder, will offer for sale at public auction at the front door of the Kanawha County Courthouse in Charleston, West Virginia, on
September 1, 2015
at 2:45 PM

the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Clendenin District, Kanawha County, West Virginia, and more particularly described as follows:

all those certain lots or parcels of land, together with the improvements thereon and the appurtenances thereunto belonging, situate in the Town of Clendenin, Kanawha County, West Virginia, and being the westerly forty (40) feet of Lot No. Ninety-seven (97) and all of Lots Nos. Ninety-eight (98) and Ninety-nine (99) of the Carnes Addition to the Town of Clendenin as shown and designated upon a map of the same of record in the Office of the Clerk of the County Commission of Kanawha County, West Virginia in Map Book 1, at page 126, and being the same property conveyed unto the parties of the first part by the following two deeds: (1) deed to Larry R. Bailey and Lillian H. Bailey from Cathy Aliff Samples and Garrett D. Samples, Jr., dated October 18, 1983, of record in the aforesaid Clerk’s office in Deed Book 2047, at page 488, and (2) deed to Larry R. Bailey from Zackery B. Samples and Kimberly Samples dated October 19, 1992, of record in the aforesaid Clerk’s office in Deed Book 2303, at page 880; to which deeds and map reference is hereby made for a more particular description of the property herein conveyed; and being also the same property conveyed unto David M. Cossin and Angela D. Anderson by Larry R. Bailey and Lillian H. Bailey by deed dated November 26, 2002, to be recorded in the aforesaid Clerk’s office.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 110 N. Point Drive, Clendenin, WV 25045.

The referenced real estate will be conveyed with no covenants of warranty, and subject to all covenants, restrictions, easements, rights of way and reservations which may be a matter of record in the aforesaid Clerk’s Office or visible upon the ground, all prior liens and encumbrances, including, without limitation, liens for real estate taxes, incinerator, sanitary and sewer charges. The purchasers at the sale shall be responsible for paying the recording costs and also the tax on the privilege of transferring real property (the cost of the tax stamp to be affixed to the deed). The purchasers shall be responsible for payment of all real estate taxes.

The subject property will be sold in “AS IS” condition. The Substitute Trustee shall be under no duty to cause any existing tenant or person occupying the subject property to vacate said property.

TERMS: $5,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Pursuant to the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated or by posting a notice of the same, and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.
SENECA TRUSTEES, INC.
5000 Coombs Farm Drive,
Suite 104
Morgantown, WV 26508
(304) 413-0044
(304) 292-2918
Toll free: (888) 534-3132
Reference File No. 26931
(607561)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

85.
TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated July 5, 2005, and duly recorded in the Office of the Clerk of the County Commission of Putnam County, West Virginia, in Document No. 000211340020, in Book No. 752, at Page 200, Kevin W. Oldham and Linda D. Oldham did convey unto Metz Law Offices, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated December 5, 2013 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by JPMorgan Chase Bank, National Association to foreclose thereunder, will offer for sale at public auction at the front door of the Putnam County Courthouse in Winfield, West Virginia, on
September 1, 2015
at 1:30 PM

the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Scott District, Putnam County, West Virginia, and more particularly described as follows:

All of those certain lots or parcels of real estate together with the buildings and improvements thereon, situate in Scott District, Putnam County, West Virginia, and being all of Lot No. Six Hundred Fifty-Six (656) and Lot No. Six Hundred Fifty-Seven (657), Six Hundred Fifty-Eight (658), Six Hundred Fifty-Nine (659), Six Hundred Sixty (660), Seven Hundred Fifty-Two (752), Seven Hundred Fifty-Three (753), and Seven Hundred Fifty-Four (754), Section Five Ranch Lake Estates, as said lots area shown and designated upon that certain map entitled, “Ranch Lake Estates, Section Five, Scott District, Putnam County, W.Va. Developed by West Virginia Land Corporation, Scale 1″ = 100′ – July, 1969”, said map prepared by W.C. Fuller, Registered Professional Land Surveyor, said map being duly of record in the Office of the Clerk of the County Commission of Putnam County, West Virginia.

Map # 204G

Parcel # 81 & 84

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 136 Circle Way, Scott Depot, WV 25560.

TERMS: $9,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

86.
TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated March 19, 2007, and duly recorded in the Office of the Clerk of the County Commission of Putnam County, West Virginia, in Book No. 823, at Page 770, Mary A. Carney did convey unto Richard A. Pill, Esq, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated July 20, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by Wells Fargo Bank, N.A. to foreclose thereunder, will offer for sale at public auction at the front door of the Putnam County Courthouse in Winfield, West Virginia, on
September 8, 2015
at 1:30 PM

the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Eleanor Town District, Putnam County, West Virginia, and more particularly described as follows:

Real property belonging, situate in the Town of Eleanor, Union District, Putnam County, West Virginia, and being more particularly bounded and described as follows:

Beginning at a ½” Re-bar in the southerly right-of-way line East “C” Street, said ½” Re-bar marking the northeasterly corner of Lot No. 5 of the Jack E. Kelley Subdivision; thence running with the original line of said Lot No. 5 and the line of the property now or formerly owned by Hoffman, S. 30 degrees 00′ W. 81.73 feet to a ½” Re-bar in the northerly right of way line of the railroad; thence running with said northerly railroad right of way line N. 56 degrees 11′ W. 42.46 feet to a 1″ stainless steel pipe; thence running with the common division line of Lots 5-A and the property conveyed herein, being Lot 5-B, N. 30 degrees 00’E. 82.22 feet to a 1″ stainless steel pipe in the southerly right of way line of said East “C” Street; thence running with the line of said East “C” Street, S. 55 degrees 31′ E. 42.50 feet to the place of beginning and estimated to contain 3,500 square feet and being designated as Lot 5-B on that certain map entitled “Map of Lot 5-B Being a Parcel Formed From The Resubdivision of Lot 5 of the Jack E. Kelley Subdivision Located in the Town of Eleanor, On the waters of the Kanawha River, Putnam County, W.Va”, which said map is attached hereto, made a part hereof, and is to be recorded herewith, and being a part of the same property conveyed unto Myrtle L. Leach, widow party of the first part herein, by Jack E. Kelley and Josephine H. Kelley, his wife, by deed dated the 24th day of October, 1979, and duly of record in the office of the Clerk of the County Commission of Putnam County, West Virginia, in Deed Book 247, at page 453.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 108 E Chestnut St, Eleanor, WV 25070.

TERMS: $5,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

87.
TRUSTEE’S SALE OF
VALUABLE REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated June 30, 2010, and duly recorded in the Office of the Clerk of the County Commission of Putnam County, West Virginia, in Document No. 002880780012, in Book No. 941, at Page 350, Melinda F. Boggess did convey unto Lisa Moye, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated July 9, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by JPMorgan Chase Bank, National Association to foreclose thereunder, will offer for sale at public auction at the front door of the Putnam County Courthouse in Winfield, West Virginia, on
September 1, 2015 at 1:30 PM

the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Poca District, Putnam County, West Virginia, and more particularly described as follows:

ALL THAT CERTAIN LOT, TRACT OR PARCEL OF LAND, TOGETHER WITH THE IMPROVEMENTS THEREON AND THE APPURTENANCES THEREUNTO BELONGING, SITUATE IN POCA DISTRICT, PUTNAM COUNTY, WEST VIRGINIA, BEING MORE PARTICULARLY BOUNDED AND DESCRIBED AS FOLLOWS:

BEGINNING AT 5/8″ REBAR SET IN THE LINE OF DAVID H. THOMAS CORNER TO PARCELS “B” AND “C” ALSO BEING LOCATED AT THE TERMINUS OF A 40′ RIGHT OF WAY EASEMENT THROUGH PARCEL “B”; THENCE WITH THE THOMAS LINE AND THE NORTHERLY LINE OF THE 40′ RIGHT OF WAY EASEMENT N. 71° 08′ 45″ E. 41.00′ TO A CONCRETE MONUMENT (FOUND) CORNER TO PARCEL “B” AND IN THE WESTERLY LINE OF A 30′ DRIVEWAY EASEMENT TO BE RESERVED FOR INGRESS AND EGRESS BY MELINDA F. BOGGESS; THENCE CONTINUING WITH THE THOMAS LINE CROSSING SAID 30′ DRIVEWAY EASEMENT N. 76° 23′ 40″ E. Passing THE CORNER OF A 40′ RIGHT OF WAY EASEMENT TO HEIZER CREEK RD.(ERRONEOUSLY OMITTED) at 368.87 a total distance of 394.09′ TO A 5/8″ REBAR (FOUND) CORNER TO PARCEL “B” AND PARCEL “A”; THENCE WITH THE LINE OF PARCEL “A” S. 32° 00′ 23″ W. 70.62′ TO 5/8″ REBAR (FOUND) IN THE CENTER OF A 40′ RIGHT OF WAY CORNER TO PARCEL “A” AND “B”; THENCE WITH THE LINE OF PARCEL “A” AND THE CENTERLINE OF THE 40′ RIGHT OF WAY S. 32° 40′ 00″ E. 123.43′ TO A 5/8″ REBAR SET IN THE CENTER LINE OF SAID RIGHT OF WAY; THENCE WITH SAME S. 35 DEGREES 21′ 25′ E. 220.77 TO A 5/8″ REBAR SET IN THE WESTERLY RIGHT OF WAY LINE OF HEIZER CREEK ROAD CORNER TO PARCEL “A” AND “B”; THENCE WITH THE WESTERLY RIGHT OF WAY LINE OF HEIZER CREEK ROAD S. 14° 17′ 12″ W. 81.00′ TO A 2″ TALL PIPE (FOUND) CORNER TO PARCEL “B” AND DIANA S. RAINES; THENCE WITH THE RAINES LINE S. 78° 01′ 24″ W. PASSING A 5/8″ REBAR SET IN A DRAIN AT 433.36′ A TOTAL DISTANCE OF 578.26′ TO A 5/8″ REBAR WITH CAP (FOUND) IN THE LINE OF RAINES CORNER TO PARCELS “B” AND “C”; THENCE WITH THE LINE OF PARCEL “C” N. 00° 54′ 14″ E. 436.44′ TO THE PLACE OF BEGINNING, CONTAINING 5.00 ACRES, MORE OR LESS, AS THE SAME IS MORE PARTICULARLY DESCRIBED AND DESIGNATED ON THAT CERTAIN MAP ENTITLED, “PROPERTY MAP FOR, MELINDA F. BOGGESS, BEING PARCEL “B”, PART OF A 11.39 ACRE TRACT, ON THE WATERS OF HEIZER CREEK, POCA DIST., PUTNAM CO., WV, SCALE 1′ = 100″” DATED APRIL 27, 2010, PREPARED BY WILKINSON SURVEYING AND ENGINEERING, INC., AND DULY OF RECORD IN THE OFFICE OF THE CLERK OF THE COUNTY COMMISSION OF PUTNAM COUNTY, WEST VIRGINIA IN MAP CABINET E SLIDE 63.

AND BEING THE SAME PROPERTY CONVEYED UNTO MELINDA F. BOGGESS, BY SANFORD A. THOMAS AND HILDA A. THOMAS, BY DEED DATED THE 30TH DAY OF JUNE, 2010, SAID DEED TO BE SIMULTANEOUSLY RECORDED HEREWITH.

THE PARTIES OF THE SECOND PART DO FURTHER GRANT AND CONVEY UNTO THE SAID PARTY OF THE SECOND PART THE RIGHT TO USE, IN COMMON WITH SAID PARTIES OF THE PART, HER HEIRS, SUCCESSORS AND ASSIGNS, THAT CERTAIN FORTY (40′) RIGHT OF WAY, AS THE SAME IS MORE PARTICULARLY SHOWN ON THE AFOREMENTIONED PLAT SIMULTANEOUSLY RECORDED HEREWITH.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: Route 1 Box 193C, Poca, WV 25159.

TERMS: $9,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Pursuant to the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated or by posting a notice of the same, and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.
SENECA TRUSTEES, INC.
5000 Coombs Farm Drive, Suite 104
Morgantown, WV 26508
(304) 413-0044
(304) 292-2918
Toll free: (888) 534-3132
Reference File No. 22528
(607560)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

88.
TRUSTEE’S SALE OF VALUABLE REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated August 3, 2006, and duly recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book No. 3384, at Page 869, Freda G. Williamson did convey unto Robert L. Shuman, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated June 19, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by OneWest Bank N.A. to foreclose thereunder, will offer for sale at public auction at the front door of the Kanawha County Courthouse in Charleston, West Virginia, on
October 13, 2015 at 2:45 PM

the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Dunbar District, Kanawha County, West Virginia, and more particularly described as follows:

ALL THAT CERTAIN PIECE OR PARCEL OF LAND, TOGETHER WITH THE IMPROVEMENTS THEREON AND THE APPURTENANCES THEREUNTO BELONGING, SITUATE IN THE CITY OF DUNBAR, KANAWHA COUNTY, WEST VIRGINIA, AND BEING MORE PARTICULARLY DESIGNATED AND DESCRIBED AS PART OF LOT 21 OF BLOCK L OF SAID CITY OF DUNBAR, AS SHOWN UPON A MAP OF THE SAID CITY OF DUNBAR, OF RECORD IN THE OFFICE OF THE CLERK OF THE COUNTY COMMISSION OF KANAWHA COUNTY, WEST VIRGINIA, IN PHOTOSTATIC MAP BOOK 2 AT PAGE 89, AND ALSO BEING MORE PARTICULARLY DESIGNATED AND SHOWN UPON A PLAT THEREOF ENTITLED “PLAT OF SURVEY FOR EMMA RUTH E. REED 1311 MYERS AVENUE, DUNBAR, WEST VIRGINIA PART OF ORIGINAL LOT 21 BLOCK L, DUNBAR, WEST VIRGINIA DUNBAR CORPORATION, KANAWHA COUNTY, WEST VIRGINIA,” BEARING DATE JANUARY 13, 1993, WHICH SAID PLAT IS ATTACHED HERETO AND MADE A PART HEREOF, SAID PARCEL OF LAND BEING MORE PARTICULARLY BOUNDED AND DESCRIBED AS FOLLOWS: BEGINNING AT A POINT IN THE EASTERLY EDGE OF A CONCRETE DRIVEWAY, SAID POINT BEING LOCATED N. 86 DEGREES 27′ W., APPROXIMATELY 2 1/2 FEET FROM THE COMMON DIVISION LINE BETWEEN THE ORIGINAL LINES OF LOTS 23 AND 24 OF BLOCK L OF SAID DUNBAR; THENCE LEAVING THE SOUTHERLY LINE OF MYERS AVENUE AND RUNNING S. 3 DEGREES 33′ W., A DISTANCE OF 120 FEET, MORE OR LESS, TO A POINT IN THE NORTHERLY LINE OF AN ALLEY; THENCE RUNNING WITH THE NORTHERLY LINE OF SAID ALLEY N. 86 DEGREES (PREVIOUSLY AND ERRONEOUSLY REFERRED TO AS 85 DEGREES IN PREVIOUS SECURITY INSTRUMENT) 27′ W., S DISTANCE OF 34.09 FEET, MORE OR LESS, TO A 1/2 INCH IRON PIPE FOUND; THENCE LEAVING THE NORTHERLY LINE OF SAID ALLEY AND RUNNING N. 3 DEGREES 35′ E., A DISTANCE OF 120.0 FEET, MORE OR LESS, TO A 1/2 INCH IRON PIPE FOUND IN THE SOUTHERLY LINE OF MYERS AVENUE; THENCE RUNNING WITH THE SOUTHERLY LINE OF SAID MYERS AVENUE S. 86 DEGREES 27′ E., A DISTANCE OF 34.02 FEET, MORE OR LESS, TO THE PLACE OF BEGINNING, AND BEING PART OF LOT 21 OF BLOCK L OF SAID CITY OF DUNBAR, AS SHOWN ON THE AFORESAID MAPS. THE IMPROVEMENTS THEREON BEING COMMONLY KNOWN AS 1311 MYERS AVENUE, DUNBAR, WEST VIRGINIA 25084. BEING THE SAME LOT OR PARCEL OF GROUND WHICH BY DEED DATED JANUARY 7, 1994 AND RECORDED AMONG THE LAND RECORDS OF KANAWHA COUNTY IN BOOK 2334 PAGE 86, WAS GRANTED AND CONVEYED BY LINDA SUE REED, UNMARRIED, AND ROGER ALLEN REED AND ANGELA REED, HIS WIFE, UNTO HOWARD D. WILLIAMSON AND FREDA G. WILLIAMSON, HIS WIFE, AS JOINT TENANTS WITH RIGHT OF SURVIVORSHIP AND NOT AS TENANTS IN COMMON. THE SAID HOWARD D. WILLIAMSON HAVING DEPARTED THIS LIFE ON JANUARY 14, 2003 IN THE COUNTY OF KANAWHA, STATE OF WEST VIRGINIA.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 1311 Myers Ave, Dunbar, WV 25064.

TERMS: $7,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Pursuant to the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated or by posting a notice of the same, and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.
SENECA TRUSTEES, INC.
5000 Coombs Farm Drive, Suite 104
Morgantown, WV 26508
(304) 413-0044
(304) 292-2918
Toll free: (888) 534-3132
Reference File No. 32729
(607688)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

89.
TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust dated July 9, 2004, and duly recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed of Trust Book 3153, at Page 747, Clark E. Lucas, Jr. and Krista N. Lucas did convey unto D. Kevin Moffatt, Trustee, certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Pill & Pill, PLLC as Substitute Trustee by a Substitution of Trustee recorded in the aforesaid Clerk’s Office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by the secured party to foreclose thereunder, will offer for sale at public auction at the front door of the Kanawha County Courthouse, in Charleston, West Virginia, on
Thursday,
September 10, 2015,
at 5:33 PM

The following described real estate, with its improvements, easements and appurtenances thereunto belonging, situate in the Jefferson District, Kanawha County, West Virginia, and more particularly described as follows:

All of that certain lot or parcel of real estate, together with the improvements thereon and the appurtenances thereunto belonging, situate in Jefferson District, Kanawha County, West Virginia, being more particularly bounded and described as follows:

All of Lot No. 43 as the same is shown upon a map entitled, “Chestnut Point Subdivision, Phase II, Lots 41 through 58 located on the waters of Coal River off Secondary Route 3/4, Jefferson District, Kanawha County, West Virginia, Scale 1″=50′, April 9, 1979, prepared by Urban Engineering Company, Inc.”, recorded in Map Book 31, Page 47.

At the time of the execution of the Deed of Trust, this property was reported to have a mailing address of 5 Aspen Lane, Saint Albans, WV 25177.

AND BEING the same real estate which was conveyed to Clark E. Lucas, Jr. and Krista N. Lucas, by Deed dated July 9, 2004, from Sherry L. Reed McMillion, also known as Shelly L. McMillion, and formerly known as Sherry L. Reed, and recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Deed Book 2607, at Page 417.

The above-described property will be sold subject to any covenants, restrictions, easements, leases and conditions of record, and subject to any unpaid real estate taxes.

TERMS: Ten percent (10{4ceb532c6f579389df471c6c1e832caf2346b74dc60fcbf6aabd4d29df3baf9c}) of the purchase price as a cash deposit with the balance due and payable within 30 days of the day of sale.
Pill & Pill, PLLC,
Substitute Trustee

Richard A. Pill,
Member
P. O. Box 440,
85 Aikens Center,
Martinsburg, WV 25404
Phone (304) 263-4971,
Fax (304) 267-5840,
E-mail: foreclosures@
pillwvlaw.com
(607786)

Class: 983 Gazette Legal Ads Last appeared: 08-26-2015

90.
TRUSTEE’S SALE OF VALUABLE REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated August 20, 2009, and duly recorded in the Office of the Clerk of the County Commission of Kanawha County, West Virginia, in Book No. 3672, at Page 203, Noretta J. Mobley did convey unto Richard A. Pill, ESQ, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated June 23, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by Wells Fargo Bank, N.A. to foreclose thereunder, will offer for sale at public auction at the front door of the Kanawha County Courthouse in Charleston, West Virginia, on
September 8, 2015 at 2:45 PM

the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Union District, Kanawha County, West Virginia, and more particularly described as follows:

ALL THOSE CERTAIN LOTS OR PARCELS OF LAND, TOGETHER WITH THE IMPROVEMENTS THEREON AND THE APPURTENANCES THEREUNTO BELONGING, SITUATE ON THE WATERS OF KANAWHA TWO MILE CREEK, UNION TAX DISTRICT, KANAWHA COUNTY, WEST VIRGINIA, AND BEING MORE PARTICULARLY BOUNDED AND DESCRIBED AS FOLLOWS, TO-WIT:

PARCEL NO 1: BEING KNOWN AND DESIGNATED AS ALL OF LOT “I”, AS SHOWN ON A MAP ENTITLED “MAP SHOWING MAPLE ACRES, A SUBDIVISION, SECTION ONE, SITUATE: NORTH OF AND NEAR ABUTTING WOODWARD DRIVE, 3.3 MILES ± NORTH OF THE CITY LIMITS OF THE CITY OF CHARLESTON ON THE WATERS OF LEFT FORK OF KANAWHA TWO MILE CREEK, UNION DISTRICT, KANAWHA COUNTY, WEST VIRGINIA”, DATED JUNE 18, 1977, AS PREPARED BY CARL KINDER, SR., L.L.S., WHICH SAID MAP IS OF RECORD IN THE OFFICE OF THE CLERK OF THE COUNTY COMMISSION OF KANAWHA COUNTY, WEST
VIRGINIA.

PARCEL NO 2: BEGINNING AT A ½ INCH IRON PIN; SAID IRON PIN BEING THE NORTHEAST CORNER OF THE PROPERTY HEREIN CONVEYED AND ALSO BEING LOCATED IN A COMMON DIVISION LINE BETWEEN THE PROPERTY HEREIN DESCRIBED AND THE PROPERTY FORMERLY OWNED BY MOBLEY, ALL AS SHOWN ON THAT CERTAIN MAP ENTITLED “MAP SHOWING A TRACT OF LAND SEVERED FROM LANDS OWNED: CURTIS E. YOUNG AND EVON H. YOUNG, DEED BOOK 1816 PAGE 201 SITUATED: SOUTH AND EAST OF MAPLE ACRES, A SUBDIVISION EAST OF THE END OF WILDERNESS DRIVE, NORTHWEST OF WOODWARD DRIVE, WATERS OF LEFT FORK, KANAWHA 2 MI., UNION DISTRICT, KANAWHA COUNTY, WEST VIRGINIA, SURVEYED FOR: WILLIAM H. AND ILLIGENE YOUNG, SURVEY AND MAP BY CARL KINDER, SR., ST. ALBANS, WEST VIRGINIA, DATE JUNE 29, 1983, SCALE: 1″ = 30′”, THENCE RUNNING WITH THE COMMON DIVISION LINE BETWEEN THE PROPERTY DESCRIBED AND THE PROPERTY NOW OR FORMERLY OWNED BY MOBLEY, N. 83′ 15′ E. 34.26 FEET TO A ½ INCH IRON PIN; THENCE LEAVING SAID COMMON DIVISION LINE AND RUNNING S. 12′ 48′ W. 144.52 FEET TO A ½ INCH IRON PIN; THENCE RUNNING ON A CHORD, N. 44′ 54′ 21″ W. 47.37 FEET TO AN IRON PIN; THENCE N. 12° 48′ E. 106.60 FEET TO THE PLACE OF BEGINNING AND CONTAINING 4,166 SQUARE FEET OR 0.0956 ACRES MORE OR LESS.

AND BEING THE SAME PROPERTY CONVEYED TO SAMUEL D. MOBLEY AND NORETTA J. MOBLEY BY HOWARD D. CROUCH AND MARJORIE L. CROUCH, HIS WIFE, AND MADGE E. CROUCH BY DEED DATED AUGUST 17, 1998, OF RECORD IN THE AFORESAID CLERK’S OFFICE IN DEED BOOK 2449 AT PAGE 398. THE SAID SAMUEL D. MOBLEY DIED ON NOVEMBER 6, 2007, AND BY VIRTUE OF MANNER IN WHICH TITLE WAS HELD, NORETTA J. MOBLEY BECAME THE OWNER OF SAID PROPERTY HEREIN CONVEYED.

THIS CONVEYANCE IS MADE SUBJECT TO THE COVENANTS, RESTRICTIONS, RESERVATIONS, STIPULATIONS AND CONDITIONS AS SET FORTH AND MENTIONED IN THAT CERTAIN INDENTURE ENTITLED “DECLARATION OF PROTECTIVE COVENANTS PERTAINING TO LOTS IN MAPLE ACRES, A SUBDIVISION, SECTION ONE, UNION DISTRICT, KANAWHA COUNTY, WEST VIRGINIA”, DATED THE 11TH DAY OF OCTOBER, 1977, OF RECORD IN THE AFORESAID CLERK’S OFFICE.

EXCEPTED AND RESERVED FROM THIS CONVEYANCE IS ALL OF THE COAL, OIL, GAS AND OTHER MINERALS IN, UPON AND UNDERLYING THE AFOREMENTIONED LOT.

THIS CONVEYANCE IS MADE SUBJECT TO ALL OTHER RESERVATIONS AND RESTRICTIONS AS FOUND IN ALL PRIOR DEEDS IN THE CHAIN OF TITLE.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 833 Wilderness Drive, Charleston, WV 25312-9548.

TERMS: $9,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Pursuant to the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated or by posting a notice of the same, and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.
SENECA TRUSTEES, INC.
5000 Coombs Farm Drive, Suite 104
Morgantown, WV 26508
(304) 413-0044
(304) 292-2918
Toll free: (888) 534-3132
Reference File No. 31366
(608112)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

91.
TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated December 6, 2005, and duly recorded in the Office of the Clerk of the County Commission of Boone County, West Virginia, in Book No. 284, at Page 795, Gregory Weymes and Mechelle Weymes aka Michelle Weymes did convey unto Thomas H. Gilpin, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated July 14, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by JPMorgan Chase Bank, National Association to foreclose thereunder, will offer for sale at public auction at the front door of the Boone County Courthouse in Madison, West Virginia, on
September 9, 2015
at 4:15 PM

the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Scott District, Boone County, West Virginia, and more particularly described as follows:

The following described tracts, lots, or parcels of land, together with all appurtenances thereunto appertaining, situate, lying and being in Scott District, Boone County West Virginia, more particularly bounded and described as follows:

First Parcel: The following certain parcel of land located to the one-half (1/2) acre parcel containing the facility commonly known as Sargents Nursing Home situate in Camp Creek, in Scott District, Boone County, West Virginia, bounded and described as follows: Beginning at a point on the westerly right of way of Easter Road, said point being 104.25 feet more or less northerly from the intersection of Easter Road and Camp Creek Road, thence N 14-37-21 W 41.88 feet, running with the right of way of Easter Road Passing a common corner of a 1/2 acre parcel and the 20 acre parcel at 3.75 feet to a point; thence S 76 13 53 W 140.30 feet running through said 20 acre parcel to a point; thence S 15-01-35 E 41.89 feet, running through said 20 acre parcel, passing through the common line of the 1/2 acre parcel at 38.14 feet to a point thence N 76-13-53 E 140.00 feet to the point of Beginning, and containing 5, 868.69 square feet, more or less, as shown on that plat attached to the Deed dated August 23, 1995 of record in the Office of the Clerk of the County Commission of Boone County, West Virginia in Deed Book 209, at page 420; and being a part of the property excepted and reserved in a Deed dated August 23, 1995, of record in aforesaid Clerk’s Office in Deed Book 209, at Page 420.

SECOND PARCEL: All that certain lot or parcel of real estate situate, lying and being in Scott District, Boone County, West Virginia, and more particularly described as follows: Beginning at an Iron stake at the mouth of Easter Hollow and of Main Camp Creek Road; thence up and with the Easter Hollow Road exactly 108 feet to an iron stake; thence turning left exactly 150 feet to an iron stake; thence making another left, turning around the hill exactly 160 feet to an iron stake; thence making another left exactly 30 feet to an iron stake located on the Main Camp Creek Road; thence turning left exactly 170 feet to the place of BEGINNING, containing one-half (1/2) acre, more or less.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 33 Easter Hollow Rd, Camp Creek, WV 25820.

Subject to a Prior Deed of Trust recorded June 16, 2005 and duly recorded in the Office of the Clerk of the County Commission of Boone County, West Virginia, in Book No. 279, at Page 319.

TERMS: $3,500.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

92.
TRUSTEE’S SALE OF VALUABLE REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated October 8, 2001, and duly recorded in the Office of the Clerk of the County Commission of Putnam County, West Virginia, in Book No. 544, at Page 666, Violet Jeanette Oxley did convey unto James B. Crawford, III, Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated May 5, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by Bank of America, N.A. to foreclose thereunder, will offer for sale at public auction at the front door of the Putnam County Courthouse in Winfield, West Virginia, on
September 8, 2015 at 1:30 PM

ALL THAT CERTAIN LOT OR PARCEL OF REAL ESTATE, TOGETHER WITH THE IMPROVEMENTS THEREON AND THE APPURTENANCES THEREUNTO BELONGING, WHICH REAL ESTATE IS LOCATED IN SCOTT DISTRICT, PUTNAM COUNTY, WEST VIRGINIA, AND WHICH IS MORE PARTICULARLY DESCRIBED AS FOLLOWS:

THAT CERTAIN CONDOMINIUM UNIT SITUATE IN WHAT IS KNOWN AS OAKBRIDGE, A CONDOMINIUM, WHICH CONDOMINIUM UNIT IS MORE PARTICULARLY DESCRIBED AS FOLLOWS:

ALL OF UNIT NO. 12, IN BUILDING NO. 1, OF OAKBRIDGE, A CONDOMINIUM, AS THE SAME IS SHOWN UPON A DECLARATION PLAN FOR OAKBRIDGE, PHASE 1, ENTITLED, “DECLARATION PLAN OF OAKBRIDGE, A CONDOMINIUM, PHASE 1, LOCATED ON OAKBRIDGE DRIVE, IN SCOTT DISTRICT, PUTNAM COUNTY, WEST VIRGINIA, SCALE 1″=50”, DATED JULY 30, 1986, MADE BY BRADLEY S. LESLIE, R.P.E., AND OF RECORD IN THE OFFICE OF THE CLERK OF THE COUNTY COMMISSION OF PUTNAM COUNTY, WEST VIRGINIA (HEREINAFTER CALLED “DECLARATION PLAN”).

TOGETHER WITH UNDIVIDED INTEREST IN AND TO THE COMMON ELEMENTS WHICH ARE ASSIGNED TO SAID UNIT NO. 12, BUILDING NO.1, AND DESCRIBED IN THE DECLARATION FOR OAKBRIDGE, A CONDOMINIUM, DATED AUGUST 4, 1986, AND OF RECORD IN THE AFORESAID CLERK’S OFFICE IN MISCELLANEOUS BOOK 27, AT PAGE 334, AS AMENDED BY FIRST CORRECT AMENDMENT TO DECLARATION ESTABLISHING OAKBRIDGE, A CONDOMINIUM DATED AUGUST 26, 1986, AND OF RECORD IN THE AFORESAID COUNTY CLERK’S OFFICE, PURSUANT TO CHAPTER 36-B OF THE CODE OF WEST VIRGINIA OF 1931, AS AMENDED, ALSO KNOWN AS THE UNIFORM COMMON INTEREST OWNERSHIP ACT, AND WHICH IS HEREINAFTER CALLED THE “DECLARATION”.

BEING THE SAME PROPERTY CONVEYED UNTO VIOLET JEANETTE OXLEY BY BARBARA L. UTT, BY DEED DATED OCTOBER 8, 2001 TO BE RECORDED IN THE OFFICE OF THE CLERK OF THE COUNTY COMMISSION OF PUTNAM COUNTY, WEST VIRGINIA, SIMULTANEOUSLY HEREWITH AS PART OF THIS TRANSACTION.

FOR THE CONSIDERATION AFORESAID, THE PARTIES OF THE FIRST PART FURTHER CONVEY THE FOLLOWING APPURTENANT EASEMENTS:

(B) A RIGHT OF WAY OVER A THIRTY FOOT (30′) ROADWAY AND A TWENTY-TWO FOOT (22′) ROADWAY EXTENDING FROM OAKBRIDGE, A CONDOMINIUM, TO MT. VERNON ROAD FOR PURPOSES OF INGRESS AND EGRESS TO AN FROM SAID PROPERTY AND FOR INSTALLATION OF UTILITY LINES.

THIS CONVEYANCE IS MADE SUBJECT, HOWEVER, TO THE FOLLOWING:

(1) COVENANTS, CONDITIONS, RESTRICTIONS, RESERVATIONS (INCLUDING WITHOUT LIMITATION ALL RESERVED DEVELOPMENT RIGHTS) EASEMENTS AND LIMITATIONS ON TITLE CREATED BY PROVISIONS OF CHAPTER 36-B OF THE CODE OF WEST VIRGINIA OF 1931, AS AMENDED, (UNIFORM COMMON INTEREST OWNERSHIP ACT) AND AS SET FORTH IN THE DECLARATION DATED AUGUST 4, 1986, AND RECORDED IN THE AFORESAID CLERK’S OFFICE.

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 312 Oakbridge, Hurricane, WV 25526.

TERMS: $4,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Pursuant to the Deed of Trust, the Trustee may postpone the sale by public announcement at the time and place designated or by posting a notice of the same, and act by agent in the execution of the sale. The parties secured by the Deed of Trust reserve the right to purchase the property at such sale.
SENECA TRUSTEES, INC.
5000 Coombs Farm Drive, Suite 104
Morgantown, WV 26508
(304) 413-0044
(304) 292-2918
Toll free: (888) 534-3132
Reference File No. 29041
(608109)

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

93.
TRUSTEE’S SALE
OF VALUABLE
REAL ESTATE

The undersigned Substitute Trustee, by virtue of the authority vested in him by that certain Deed of Trust, dated September 16, 2011, and duly recorded in the Office of the Clerk of the County Commission of Putnam County, West Virginia, in Document No. 003094470017, in Book No. 981, at Page 824, Courtney M. Raynes and Colby N. Raynes did convey unto Richard A. Pill, Esq., Trustee(s), certain real property described in said Deed of Trust; and the beneficiary has elected to appoint Seneca Trustees, Inc., as Substitute Trustee by a Substitution of Trustee dated June 9, 2015 and recorded in the aforesaid Clerk’s office; and default having been made under the aforementioned Deed of Trust, and the undersigned Substitute Trustee having been instructed by Wells Fargo Bank, N.A. to foreclose thereunder, will offer for sale at public auction at the front door of the Putnam County Courthouse in Winfield, West Virginia, on
September 8, 2015
at 1:30 PM

the following described real estate, together with its improvements, easements and appurtenances thereunto belonging, situate in Hurricane Town District, Putnam County, West Virginia, and more particularly described as follows:

ALL OF THOSE CERTAIN TRACTS OR PARCELS OF LAND, TOGETHER WITH THE IMPROVEMENTSHTEREON AND THE AOPPURTENACNES THEREUNTO BELONGING, WHICH TRACTS OR PARCELS OF LAND SITUATE IN THE TOWN OF HURRICANE, PUTNAM COUNTY, WEST VIRGINIA, SITUATE ON THE SOUTH SIDE OF MIDLAND TRAIL ROAD, NOW WEST VIRGINIA STATE ROUTE 34A, 40 FEET WEST ODF A LOT NOW OR FORMERLY OWNED BY A.C. SMITH IN SAID TOWN OF HURRICANE AND BEING MORE PARTICULARLY BOUNDED AND DESCRIBED AS FOLLOWS:

PARCEL ONE:
BEGINNING AT A STAKE IN SAID ROAD, RUNNING WESTERLY WITH THE ROAD FIFTY (50) FEET TO A STAKE; THENCE SOUTH ABOUT EIGHTY-EIGHT (88) FEET TO A STAKE IN OLD VALLEY ROAD; THENCE EAST WITH SAID ROAD SIXTY (60) FEET TO A STAKE; THENCE NORTHERLY NINETY-SEVEN (97) FEET TO THE PLACE OF BEGINNING, CONTAINING ONE-TENTH (1/10) ACRE, MORE OR LESS.

SUBJECT TO THE EXCEPTION AND RESERVATION FROM PARCEL ONE A PARCEL PREVIOUSLY CONVEYED TO RICHARD E. AND BETTY M. CLARK BY DEED DATED JUNE 30, 1992 AND OF RECORD IN THE OFFICE OF THE CLERK OF THE COUNTY COMMISSION PUTNAM COUNTY, WEST VIRGINIA, IN DEED BOOK 341, AT PAGE 237.

PARCEL TWO:
BEGINNING AT AN IRON PIN IN THE COMMON LINE BETWEEN BROWN AND CLARK, SAID PIN BEING S. 27° 57 MIN, 35 SEC. E, 44.02 FEET FROM THE COMMON CORNER BETWEEN CLARK AND BROWN AND THE SOUTHERN RIGHT OF WAY WITH MAIN STREET (RT. 34 BUSINESS); THENCCE WITH THE LINE OF CLARK AND BROWN S. 27° 47 MIN, 35 SEC. E. 43.98 FEET TO THE COMMON CORNER OF BROWN AND CLARK AND THE RIGHT OF WAY FOR THE OLD COUNTRY ROAD; TEHNCE WITH THE NORTHERN RIGHT OF WAY FOR THE OLD COUNTRY ROAD S. 75° 14 MIN. 28 SEC. W. 6.93 FEET TO AN IRON PIN; THENCE DIVIDING THE LAND OF CLARK N. 18° 44 MIN, 59 SEC. W. 42.95 FEET TO THEPOINT OF BEGINNING AND CONTAINING 149 SQUARE FEET, MORE OR LESS.

Map No.:2

Parcel Nos.:1 and 1.0005

At the time of the execution of the Deed of Trust, this property was reported to have an address of: 2585 Main Street, Hurricane, WV 25526.

TERMS: $9,000.00 in cash and/or certified funds as deposit with the balance due and payable within 30 days of the day of sale.

Class: 983 Gazette Legal Ads Last appeared: 08-27-2015

94.
Under the provisions of AHERA and OSHA regulations this information will serve as notice of the existence and availability of an Asbestos Management Plan for all school facilities in Putnam County.

Individual school plans are available for review in the principal’s office at each school or the Board of Education Office in Winfield, West Virginia.
Board of Education
of the County of Putnam
County Schools

Harold Hatfield
Superintendent of Schools
(606811)

Class: 983 Gazette Legal Ads Last appeared: 08-28-2015

95.
ADVERTISEMENT
FOR BIDS

Putnam County
Development Authority

Re-Grading and Wetland
Mitigation/Repair
Services

BID September 22, 2015

Sealed Bids for Re-Grading and Wetland Mitigation/Repair Services, for an existing wetland mitigation cell located at the Putnam County Business Park will be received by TERRADON Corporation, 409 Jacobson Drive, Poca, West Virginia 25159, PO Box 519, Nitro, West Virginia, 25143 until 4:00 P.M., E.D.T., on Tuesday, September 22, 2015 as set forth in the Advertisement for Bids, Form of Proposal, Information for Bidders, General Conditions, Supplemental General Conditions, and Detail Specifications. Following the scheduled closing time for the reception of bids, all proposals which have been submitted in accordance with the conditions of this Project will be publicly opened and read aloud in the conference room at TERRADON at 4:15 P.M., E.D.T. All interested Bidders must attend the MANDATORY onsite pre-bid meeting at 9:00 A.M., E.D.T., on Tuesday, September 8, 2015.

The work to be bid upon is described as follows:

Clearing, Grubbing and Re-Grading of a 2.5 Acre existing wetland mitigation cell located at the Putnam County Business Park. Construction will also include constructing a new spillway in the existing berm as well as providing adequate and positive drainage channel to the wetland

Time limit for finishing this work under this contract is 33 calendar days from the issuance of a Notice to Proceed.

The sealed envelope containing the bid must have the following information in the lower left hand corner:

“Name and Address of Bidder, Bid on Re-Grading and Wetland Mitigation/Repair Services To be Opened 4:15 P.M., E.D.T., September 22, 2015.”

Copies of Specifications and Bidding Documents may be obtained from Terradon Corporation, 409 Jacobson Drive, Poca, WV 25159, Phone 304 755 8291, ask for Jason Asbury or Bill Hunt.

Bids received after the scheduled closing time for the reception of bids will be returned unopened to the Bidders.

TERRADON Corporation reserves the right to reject any and all bids and to waive any informalities. By submittal, of a Bid, Bidder agrees to hold its Bid Price for the duration of the Contract Time Limit.
(608128)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

96.
IN THE FAMILY COURT OF KANAWHA COUNTY, WEST VIRGINIA

To: Eric Jones
Respondent’s Name
Corvair Drive – Sugar Creek
Charleston, WV 25312
Address
03/14/76
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1290

Family Court Civil
Action: 15-DV-1233
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/30/2015.
A final hearing is scheduled for the 30th day of September, 2015., at 9:15 am before the Kanawha County Family Court.

Issued thisAugust 26, 2015
Cathy S. Gatson
Circuit Clerk
(608713)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

97.
IN THE FAMILY COURT OF KANAWHA COUNTY, WEST VIRGINIA

To: Kelly Ann Santanio
Respondent’s Name
1161 129th Street
Chesapeake, WV 25315
Address
01/09/89
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1291

Family Court Civil
Action: 15-DV-1234
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/30/2015.
A final hearing is scheduled for the 30th day of September, 2015., at 9:30 am before the Kanawha County Family Court.

Issued thisAugust 26, 2015
Cathy S. Gatson
Circuit Clerk
(608712)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

98.
IN THE FAMILY COURT OF KANAWHA COUNTY, WEST VIRGINIA

To: Tracy Yvonne Jividen-Haynes
Respondent’s Name
1515 Kearse Avenue
Charleston, WV 25312
Address
02/09/81
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1122

Family Court Civil
Action: 15-DV-1074
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/28/2015.
A final hearing is scheduled for the 28th day of September, 2015., at 1:15 pm before the Kanawha County Family Court.

Issued thisAugust 26, 2015
Cathy S. Gatson
Circuit Clerk
(608716)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

99.
IN THE FAMILY COURT OF KANAWHA COUNTY, WEST VIRGINIA

To:Blane Leonard Barker
Respondent’s Name
193 Federal Drive
Alum Creek, WV 25030
Address
10/31/83
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1306

Family Court Civil
Action: 15-DV-1249
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/30/2015.
A final hearing is scheduled for the 30th day of September, 2015., at 1:15 pm before the Kanawha County Family Court.

Issued thisAugust 26, 2015
Cathy S. Gatson
Circuit Clerk
(608719)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

100.
IN THE FAMILY COURT OF KANAWHA COUNTY, WEST VIRGINIA

To:Phillip Ronald Wright
Respondent’s Name
4561 Smith Creek Road
So. Charleston, WV 25309
Address
05/01/74
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1307

Family Court Civil
Action: 15-DV-1250
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/30/2015.
A final hearing is scheduled for the 30th day of September, 2015., at 1:30 pm before the Kanawha County Family Court.

Issued thisAugust 26, 2015
Cathy S. Gatson
Circuit Clerk
(608720)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

101.
IN THE FAMILY COURT OF KANAWHA COUNTY, WEST VIRGINIA

To:Timothy Joe Williams
Respondent’s Name
27 2nd Street
St. Albans, WV 25177
Address
11/15/62
Respondent’s Date of Birth

Magistrate Court
Case No: 15-D-1283

Family Court Civil
Action: 15-DV-1228
ORDER OF
PUBLICATION
PROTECTION ORDER/HEARING DATE

TO THE ABOVE-NAMED RESPONDENT:

If appearing by evidence duly taken in this action that you could not be found in or that you have left the State of West Virginia, you are hereby notified of the ORDER referenced above, a copy of the Petition and Order may be obtained at the Kanawha County, Circuit Clerk’s office. This PROTECTIVE ORDER will remain in effect until 09/29/2015.
A final hearing is scheduled for the 29th day of September, 2015., at 1:15 pm before the Kanawha County Family Court.

Issued thisAugust 26, 2015
Cathy S. Gatson
Circuit Clerk
(608718)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

102.
NOTICE OF SALE

STAR USA FEDERAL CREDIT UNION WILL HOLD A SALE ON SEPTEMBER 1, 2015 AT 10:00 AM AT WV AUTO ADJUSTMENT, 2344 PENNSYLVANIA AVE., CHARLESTON WV, 25302 AT THE FOLLOWING REPOSSESSED PROPERTIES:
2008 Volvo XC90
VIN YV4CZ852681483430

THIS PROPERTY IS TO BE SOLD AS IS WITHOUT WARRANTY. FINANCING IS AVAILABLE TO THE PERSON WHO SUBMITS THE HIGHEST ACCEPTED BID (WITH APPROVED CREDIT).

TERMS: CASH OR PRE-APPROVED FINANCING AT THE TIME OF THE SALE STAR USA FCU RESERVES THE RIGHT TO BID AND PURCHASE AT SAID SALE.

CONTACT 1-800-628-2120 OPTION 8 FURTHER INFORMATION.
(608554)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

103.
PUBLIC AUCTION

Contents of the following unit(s) located at Rent-A-Space Dunbar, LLC, 2727 Fairlawn Avenue, Dunbar, WV, will be sold at public auction. Terms: Cash only; at the facility at 10:00 am, Wednesday, September 23, 2015. Property may be inspected immediately prior to the auction. All bids are subject to manager’s approval.

The units are as follows:

NAME UNIT(S)

Andrew Adams 817
Tiffany Allen 303
Jerry Anderson, Jr 867
Krissa Bowers 927
Jackie Campbell 824
Elroy Cooper 444
Michael Deskins 311
Duty, William M. 337
Frances Hamilett 901
Jeanetta Hobbs 210
Lisa Holcomb 527
Sachonna Hugle 904
Marilyn Joslin 106
Robert Lynch 533
Alan McNeely 628
Robert Munday 915 Christopher Nelson 856
Shadava Toleito 534
Joseph Tuck 333
J. B. Turley 1004 & 1034 Vitalis Ukwuaba 908
Lawrence Washington 586 Earl L. Whitlock 630

Items to be auctioned include: household items; furniture; miscellaneous tools; and odds and ends.
(608659)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

104.
WEST VIRGINIA
HEALTH CARE
AUTHORITY
CERTIFICATE OF NEED
100 Dee Drive
Charleston,
West Virginia 25311-1600

August 24, 2015

LEGAL NOTICE

James L. Pitrolo, Jr., Chairman, West Virginia Health Care Authority, announces the following Certificate of Need activities for the week ending August 21, 2015.
CORRECTED LETTER
OF INTENT RECEIVED

August 4, 2015 – FMS Cabell Huntington Dialysis Centers, LLC d/b/a Fresenius Medical Care Hamlin, LLC, Raleigh, North Carolina, CON File #15-2-10570-R, for the establishment of a new nine (9) station dialysis facility in Hamlin, Lincoln County; capital expenditure: $1,288,766.

This applicant was previously incorrectly listed as FMS Cabell Huntington Dialysis Center, LLC d/b/a Fresenius Medical Care Hamlin, LLC.
LETTER OF INTENT
FOR EXPEDITED
REVIEW RECEIVED

August 17, 2015 – FMRS Health Systems, Inc., Beckley, Raleigh County, CON File #15-1-10589-P, for the provision of primary care services on the FMRS campus in Beckley, Raleigh County; capital expenditure: $15,000.
REQUEST FOR
EXEMPTION
RECEIVED FOR

August 17, 2015 – Camden-on-Gauley Medical Center, Inc., Camden on Gauley, Webster County, CON File #15-4-10583-X, request for exemption from Certificate of Need review pursuant to W.Va. Code § 16-20-5(m) to purchase the assets of Joseph F. Dawson, a sole Practitioner doing business as “Red Oak Primary Care” located in Richwood, Nicholas County, and hire Dr. Dawson. The primary care practice will remain at 58 Main Street, Richwood, Nicholas County.

The capital expenditure associated with the project is $55,000.

Any affected person may oppose this proposal by submitting a letter stating the reason for opposition within thirty (30) days of the first date of publication of the public notice to: Marianne Kapinos, General Counsel, West Virginia Health Care Authority, Certificate of Need Program, 100 Dee Drive, Charleston, West Virginia 25311-1600.

The last date upon which an affected party may file a letter of opposition to this proposal is September 28, 2015.
EXPEDITED
APPLICATION
RECEIVED

August 19, 2015 – The Heritage Center at Lesage, Huntington, Cabell County, CON File #15-2-10403-X/BH, for the development of a non-medical post detox residential drug and alcohol rehabilitation and recovery treatment program for adults over the age of twenty-one to be located at 8300 Ohio River Road, Lesage, Cabell County; capital expenditure: $465,000.
ORDER GRANTING
MOTION TO
DISMISS ISSUED

August 18, 2015 – Bio-Medical Applications of West Virginia, Inc. d/b/a Fresenius Medical Care Monongalia County (BMA), Morgantown, Monongalia County, CON File #15-6-10438-R, for the establishment of a new 10 station dialysis facility in Morgantown, Monongalia County.

The Authority finds that Total Renal Care is not an affected person in this matter. Accordingly, it is ORDERED that Total Renal Care’s request for affected person status in this proceeding is DENIED. It is further ORDERED, that BMA’s Motion to Dismiss Total Renal Care’s request for a public hearing is GRANTED.
AMENDED PROJECTS
DETERMINED NOT
REVIEWABLE

August 17, 2015 – Dazzy Vance Mountain Retreat, Logan, Logan County, CON File #15-2-10540-X, for the development of a 70-bed psychiatric residential treatment facility called Dazzy Vance Mountain Retreat. The target population is children/youth, ages 4-21, at risk for out-of-state placement in Logan County and the surrounding counties within the Department of Health and Human Resources’ Region II area.

The amendment is the name change of the petitioner from Trinity Health Care Services, Inc. to Dazzy Vance Mountain Retreat.
CERTIFICATE OF
NEED APPROVAL
ISSUED

August 20, 2015 – Bio-Medical Applications of West Virginia, Inc. d/b/a Fresenius Medical Care Monongalia County, Raleigh, North Carolina, CON File #15-6-10438-R, for the establishment of a new ten (10) station dialysis facility in Morgantown, Monongalia County; capital expenditure: $1,558,582.
LETTER OF
INTENT EXPIRED

W.Va. (C.S.R. § 65-7-11.3) states, in part, that letters of intent are effective for one year from the date of their filing. The following represents a letter of intent that has expired:

August 15, 2015 – Greenbrier Medical Institute, LLC, Akron, Ohio, CON File #14-4-10247-P, for the development of a free-standing medical complex in White Sulphur Springs, located in Greenbrier County on Kate’s Mountain Road; capital expenditure: $100,000,000.

Further information may be obtained on any of the above-referenced projects by contacting Timothy E. Adkins, Director, Certificate of Need Division.
(608527)

Class: 983 GazetteMail Legal Ads Last appeared: 08-29-2015

Find it Smarter
SMARTIE will continue this search for a month and email you the results. Click SMARTIE

Charleston Newspapers
1001 Virginia St. E. Charleston, WV 25301

More in Kanawha:

Counties