WEST VIRGINIA DEPARTMENT OF TRANSPORTATION DIVISION OF HIGHWAYS NOTICE TO CONTRACTORS Bids will be received electronically by the West Virginia Department of Transportation Division of Highways through the Bid Express Bidding Service (www.bidx.com) and by sealed proposals (only when prequalification is waived) being received at its office in Building 5, Room 843, 1900 Kanawha Boulevard East, Charleston, West Virginia until September 09, 2025 at 10:00 AM (Eastern Standard Time). The bids will be downloaded and/or opened and read publicly thereafter for the constructions of the following project(s): CALL: 006 CONTRACT: 2021310001 STATE PROJECT: U331-MOR/GA-21. 00 FEDERAL PROJECT: TAP-2022(133)D DESCRIPTION: PEDESTRIAN/BIKE FACILITIES MORGANTOWN MUNICIPAL AIRPORT STREETSCAPE COUNTY: MONONGALIA DBE GOAL: 8% OF CONTRACT BID AMOUNT. BIDDER MUST PROVIDE WRITTEN ASSURANCE OF MEETING GOAL ON FORM IN PROPOSAL. REMARKS: Proposals will be received from prequalified and West Virginia licensed contractors only except that on Federal-Aid Projects a contractors’ license is not required at time of bid, but will be required before work can begin. Registration is required with the Department of Administration, Division of Purchasing, in accordance with Chapter 5A, Article 3, Section 12 of the West Virginia Code. All contractors submitting bids on project(s) must submit electronically with their bid a Proposal Guaranty Bond for $500.00 or 5% of the total bid, whichever is greater. The West Virginia Department of Transportation Division of Highways reserves the right to defer, delay or postpone the date for receiving and publicly opening proposals for any project designated in this advertisement, without the necessity of renewing such advertisement. The deferment, delay, postponement, and the date that proposals will be received and publicly opened will be available on www.bidx.com. The West Virginia Department of Transportation Division of Highways hereby notifies all bidders that it will affirmatively ensure that in any contract entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, religion, sex or national origin in consideration for an award. LH-322245 07-31;2025
Legal Notices
IN THE CIRCUIT COURT OF CABELL COUNTY, WEST VIRGINIA CIVIL ACTION NO.: 25-P-214 Honorable Judge Hammers STEPHEN ADKINS, Petitioner, v. TERRI LYNN ADKINS, JOSH PAUL ADKINS-MOORE PATRICK NICHOLAS ADKINS-MOORE and NATHANIEL ADKINS, Respondents. To: Terri Lynn Adkins THE OBJECT OF THIS ACTION IS TO PARTITION REAL ESTATE It appearing by affidavit filed in this action that the residence of Terri Lynn Adkins is unknown. It is hereby ordered that Terri Lynn Adkins, serve upon Paul E. Biser, counsel for Petitioners, at 511 Eighth Street, Huntington, WV 25701 and upon the Circuit Court of Cabell County, West Virginia, at 750 5th Avenue, #114, Huntington, WV 25701, an answer including any related counterclaim or defense you may have to the petition filed in this action on or before August 28, 2025. If you fail to do so, thereafter judgment, upon proper hearing and trial may be taken against you. This Order shall be published as a Class II Legal Advertisement in the Herald Dispatch, a newspaper in the publication area of Cabell County, West Virginia. A copy of said petition can be obtained from the undersigned Clerk at his office. Entered by the Clerk of said Court on July 29, 2025. MICHAEL J. WOELFEL CLERK LH-323041 07-31,08-07;2025